[Boutique] decoration agreement template

Article 1: Template of the renovation agreement

Principal: Undertaking:

After friendly negotiation and negotiation between Party A and Party B, Party A decides to entrust Party B to carry out the laying of floor tiles and wall tiles, and enter into this Agreement to jointly abide by it.

I. Project Location: ____ District ____ Street ____ Unit ____ Room

Second, the formal structure: ____ layer ____ room ____ hall ____ kitchen ____ health

Third, the project:

1. The floor of the four rooms is paved with 80*80 tiles, and the corners are required to be leveled; one kitchen, one bathroom wall 25*40 is paved to the top, leaving the ceiling space, the corners are polished, and the floor is paved with 30*30 tiles. Flatness is required; 30*30 tiles are laid on the two balconies and the floor is required to be level.

2. If there is no detail, Party A will propose a plan and discuss it.

IV. Contracting method: Party A must guarantee the required materials during the decoration period and the lunch supply during the construction period according to the requirements of Party B. Party B is responsible for the construction.

V. Quality standards: The construction quality should meet the safety requirements, and the decoration quality should not be lower than the decoration standard of the same construction type. After the completion of the project is completed and accepted, Party B shall be responsible for the free rework and repair due to the quality problems arising from the construction of Party B within 3 months.

6. Project cost: The material shall be provided by Party A, and Party A shall pay Party B's decoration labor fee _____ ____ yuan.

VII. Payment method: In order to ensure the quality of the project, the deposit of 500 yuan will be temporarily suspended. If there is no problem within the period from April _ _ _ XX to XX XX, the total amount will be returned to Party B. After the completion of the project, it shall be checked and accepted by Party A. If it meets the above construction project and design requirements, Party B shall pay the labor fee within three days.

8. This Agreement is made in two copies, one for each Party A and Party B, with the same effect. This Agreement shall enter into force on the date of signature by both parties.

person A person B:

Signature: Signature:

Contact number: Contact number:

Year, month, day, month, day

Part 2: Template of the renovation agreement

Contractor:

residence:

phone:

contractor:

residence:

phone:

In accordance with the "Contract Law of the People's Republic of China", "The Law of the People's Republic of China on the Protection of Consumer Rights and Interests", the Ministry of Construction's "Measures for the Management of Residential Interior Decoration" and the relevant laws and regulations, combined with the characteristics of the decoration of the family room decoration, in equality On the basis of voluntariness and consensus, the following agreements were reached on matters relating to the decoration and renovation of the family's family room:

Article 1, project overview

1. Project location:

2, the project content

3. Project contracting method: The two parties agree to adopt the following contracting methods.

Party B's labor and materials

Party B shall contract and part of the materials, and Party A shall provide some materials.

Party B's contract work, Party A's materials

4. Project date, date of commencement, date of completion, date of completion.

5. Contract price: The cost of the contract project is: yuan

Family room decoration project budget offer form

Article 2, construction drawings

The two parties agree that the construction drawings shall be provided in the following manner:

1. Party A shall design and provide construction drawings by itself, in two copies, one for each party;

2. Party A entrusts Party B to design and provide construction drawings. The drawings are in duplicate and one for each party.

Article 3, Party A’s obligations

1. The day before the start of construction, create conditions for the construction of Party B, so as not to affect the construction principle;

2. Provide water source and power supply during construction;

3. Responsible for coordinating the relationship between Party B and the neighbors;

4. Do not dismantle the indoor load-bearing structure. If it is necessary to dismantle the non-load-bearing structure or equipment pipeline of the original building, it is responsible for going through the relevant approval procedures to the relevant departments;

5. During the construction period, Party A still needs to use the room partially, and is responsible for coordinating with Party B to do security and fire protection work;

6. Participate in the supervision of project quality and construction progress, and completion acceptance.

Article 4, Party B’s obligations

1. Strictly implement safety construction operation specifications, fire protection regulations, construction specifications and related quality standards during construction, and complete the project on time and in quality;

2. Strictly implement the regulations on construction site management, and must not disturb the people and pollute the environment;

3. Protect the furniture and furnishings in the original room to ensure the smooth flow of the upper and lower water pipes in the living room;

4. Ensure the cleanliness of the construction site and clean the construction site after the project is completed.

Article 5, engineering changes

If the project and construction method need to be changed, both parties shall agree to sign a written change agreement and adjust the relevant project costs and construction period.

Article 6, provision of materials

1. The materials provided by Party A shall be notified to Party B before the materials are transported to the construction site, and both parties shall jointly accept and handle the handover procedures;

2. Party B shall notify Party A of the materials provided by Party B before the materials are delivered to the construction site and accept Party A's inspection.

Article VII, delay in construction period

1. The delay in completion date is caused by the following reasons. After confirmation by Party A, the construction period will be postponed accordingly:

Process variations and design changes;

Resilience

Agree to other circumstances in which the construction period is postponed.

2. If Party A fails to complete its work in accordance with the agreement and affects the construction period, the construction period shall be postponed;

3. Party A fails to pay the construction cost on time, and the contract construction period is postponed accordingly;

4. If Party B's responsibilities cannot be started on schedule or stop working without any reason, and the construction period will be affected, the construction period will not be postponed; if there is any problem in the quality of the project due to Party B's reasons, the rework costs will be borne by Party B, and the construction period will not be postponed.

Article 8, quality standards

1. Engineering quality

The two parties agree that the construction quality standards of this project are:

During the construction process, both parties have disputes over the quality of the project. They may apply to the professional testing unit approved by the construction administrative department to certify the quality of the project. The relevant expenses for the certification process shall be borne by the responsible person.

2, indoor air quality

In accordance with the "Household Interior Decoration Management Measures." After the completion of the project, the indoor air quality should meet the "Code for Indoor Environmental Pollution Control of Civil Building Engineering".

Party B shall provide Party A with the “Indoor Air Quality Test Report” issued by a professional environmental testing unit approved by the Quality and Technical Supervision Department during project acceptance.

Article 9, project acceptance and warranty

1. The two parties agree to check the quality of the project in the following stages during the construction process:

Party B shall notify Party A to accept the acceptance two days in advance, and the project acceptance form shall be completed after the stage acceptance is passed.

2. After the completion of the project, Party B shall notify Party A of the acceptance. Party A shall organize the acceptance and acceptance within two days after receiving the acceptance notice, and fill in the project acceptance form; after the project payment is settled, the handover procedure shall be completed.

3. The warranty period for this project is from the date of signing by both parties. After the acceptance of the qualified signature, Party B shall fill in the project warranty.

Article 10, payment method of project payment

1. The parties agree to pay the construction cost in the following way:

After the contract takes effect, Party A shall pay the construction cost directly to Party B as agreed in the following table:

Payment time payment time payment amount

Payment for the first three days before the first start

The second project progressed more than half of the payment

The third time the two sides accepted the qualified payment yuan

Project progress over half of the index

Other payment methods:

2. After the project is qualified, Party B may submit the project settlement to Party A and send the relevant materials to Party A. If Party A receives the information, if it has no objection within the day, it shall be deemed as consent. Both parties shall fill in the project settlement statement and sign. Party A shall settle the final payment of the project to Party B at the time of signature.

Article 11, Liability for breach of contract

1. If one of the parties to the contract fails to perform the contractual agreement or violates the national laws, regulations and relevant policies, the responsible party shall be liable for the fine or the loss caused to the other party, and shall compensate the other party for the economic loss.

2. If the contract fails to perform due to one reason, the party shall promptly notify the other party to complete the contract termination procedure, and the responsible party shall compensate the other party for the corresponding economic loss.

3. If Party A fails to pay the construction cost on time, the other party will pay the default amount for each delay.

4. Due to Party B's reasons, the project quality and indoor air quality will not meet the quality standards agreed by both parties. Party B is responsible for repair or rework, and the construction period will not be postponed.

5. Due to the delay of the construction period due to Party B's reasons, the default amount will be paid to the other party for each day of delay.

Article 12: The solution to the contract dispute

The disputes arising during the performance of this contract shall be settled by both parties through negotiation; or may be settled by the relevant departments; if the negotiation or mediation fails, the following methods shall be resolved:

1. Submit to the Arbitration Commission for arbitration;

2. File a lawsuit in the people's court according to law.

Article 13 and several specific provisions

1. The garbage generated by the construction of the project shall be transported by the Party B to the construction site and responsible for transporting the garbage to the designated place. Party A shall be responsible for paying the garbage clearance fee.

2. During the construction period, Party A will hand over the house key to Party B for safekeeping. After the completion of the project, Party A is responsible for providing new locks, which shall be installed and delivered by Party B on the spot.

3. During the construction period, Party B's daily working hours are: from the morning to the minute; from the afternoon to the minute.

Article 14 Other agreed matters

Article 15 and Supplementary Provisions

1. This contract shall become effective upon signature by both parties and shall terminate upon completion of the contract.

2. The project may not be subcontracted after the signing of this contract.

3. This contract is in one copy and each party holds each share.

4. The subsidiary file of the contract is an integral part of this contract and has the same legal effect as this contract.

Contract Attachment File:

Schedule 1: Confirmation Form for Construction Project of Family Room Decoration Project

Schedule 2: Family Room Decoration Project Budget Quotation Form

Schedule 3: Party B provides a list of decorative materials

Schedule 4: Party A provides a list of decorative materials

Schedule 5: Family Room Decoration Project Change Order

Schedule 6: Family Room Decoration Project Acceptance Form

Schedule 7: Family Room Decoration Project Warranty

Schedule 8: Family room decoration project settlement statement

person A person B:

Legal representative:

Year, month, day, month, day

Part 3: Template of the renovation agreement

In accordance with the "Contract Law of the People's Republic of China" and relevant laws and regulations, combined with the characteristics of the decoration of the family room decoration project, the two parties on the basis of equality, voluntariness and consensus, on the issue of the decoration and decoration of the family room of the contractor , reached the following agreement:

The first project overview

1.1 Project location: ___________________.

1.2 Project content and practices.

1.3 Project contracting method: Both parties agree to adopt the following ___ type of contracting method.

Contractor's contract work and materials;

The contractor shall contract labor and part of the materials, and the contractor shall provide some materials;

The contractor is contracted and the contractor is enrolled.

1.4 Project period ____ days, start date ____ year ____ month ____ day, completion date ____ year ____ month ____ day.

1.5 Contract price: The construction cost of this contract is: ____________ yuan.

Article 2 Engineering Supervision

If the project is supervised by the project, the contractor and the supervision company will sign the “Construction Supervision Contract” separately, and notify the contractor of the name, unit, contact information of the supervision engineer and the duties of the supervision engineer.

Article 3 Construction Drawings

The parties agree to submit the construction drawings in the following ___ ways:

The contractor designs and provides the construction drawings, the drawings are in duplicate, and the contractor and the contractor each have one copy;

The contractor entrusts the contractor to design the construction drawings. The drawings are in duplicate, one for the contractor and one for the contractor, and the design fee is ______ yuan, which is paid by the contractor.

Article 4 Obligation of the Employer

4.1 ____ days before the start of construction, create conditions for the contractor to enter the construction. Including: moving out indoor furniture, furnishings, or stacking and covering furniture that is difficult to move indoors, so as not to affect construction;

4.2 Provide water source and power supply during construction;

4.3 Responsible for coordinating the relationship between the construction team and the neighbourhood;

4.4 Do not dismantle the indoor load-bearing structure. If it is necessary to dismantle the non-load-bearing structure or equipment pipeline of the original building, it is responsible for going through the relevant approval procedures to the relevant departments;

4.5 During the construction period, the contractor still needs to use part of the living room, and is responsible for the security and fire protection work at the construction site;

4.6 Participate in the supervision of project quality and construction progress, and be responsible for material entry and completion acceptance.

Article 5 Contractor's Obligation

5.1 Strictly implement safety construction operation specifications, fire protection regulations, construction specifications and quality standards during construction, and complete the project on time and in good quality;

5.2 Strictly implement the regulations on construction site management, and must not disturb the people and pollute the environment;

5.3 Protect the furniture and furnishings in the original room to ensure the smooth flow of the upper and lower water pipes in the living room;

5.4 Ensure that the construction site is clean and tidy. After the project is completed, it is responsible for cleaning the construction site.

Article 6 Engineering Changes

If the project and construction method need to be changed, both parties shall agree to sign a written change agreement and adjust the relevant project costs and construction period.

Article 7 Delay in construction period

7.1 Delay in completion date for the following reasons, confirmed by the contractor, the construction period shall be postponed accordingly:

Engineering volume changes and design changes;

force majeure;

The Employer agrees to other circumstances in which the construction period is postponed.

7.2 If the contractor fails to complete the work to be responsible according to the agreement and affects the construction period, the construction period shall be postponed; if the quality of the materials provided by the contractor and the quality of the equipment are unqualified and affect the quality of the project, the rework expenses shall be borne by the contractor and the construction period shall be postponed.

7.3 The contractor fails to pay the construction cost on time, and the contract period is postponed accordingly.

7.4 If the contractor's responsibility cannot be started on schedule or if the construction period is affected without interruption, the construction period will not be postponed; if the quality of the project is problematic due to the contractor's reasons, the rework costs will be borne by the contractor and the construction period will not be postponed.

Article 8 Quality Standards

Both parties agree on the construction quality standard of this project: ___________________________________________.

During the construction process, both parties have disputes over the quality of the project. The quality of the project is certified by the _________ department. The quality of the certified project does not meet the standards stipulated in the contract. The expenses related to the certification process are borne by the contractor; the quality of the certified project conforms to the contractual agreement. The standard, the expenses related to the certification process expenses are borne by the contractor.

Article IX Project Acceptance and Warranty

9.1 Both parties agree to check the quality of the project in the following stages during the construction process: the contractor shall notify the contractor to accept the acceptance two days in advance, and the project acceptance form shall be filled after the completion of the stage acceptance. 9.2 After the completion of the project, the contractor shall notify the contractor. Upon acceptance, the contractor shall organize the acceptance within two days after receiving the acceptance notice and fill in the project acceptance form. After the project payment is settled, the handover procedure is completed.

9.3 The warranty period for this project is ____ months from the date of signing by both parties. After the acceptance of the qualified signature, fill in the engineering warranty.

Article 10 Payment method of construction funds

10.1 The parties agree to pay the construction cost in the following ____ way:

10.2 After the project has passed the acceptance test, the contractor shall submit the project settlement to the contractor and send the relevant information to the contractor. If the contractor receives the information within ____ days without any objection, it shall be deemed to agree. Both parties shall fill in the project settlement statement and sign it, and the contractor shall settle the final payment of the project to the contractor at the time of signing.

Article 11: The contract takes effect

11.1 This contract and the subsidiary file of the contract shall be sealed to both parties and shall become effective after being signed.

11.2 The Supplementary Contract has the same legal effect as this Contract.

11.3 This contract is in one copy, and both parties are responsible for each.

person A person B:

Address: Business Address:

Work unit: Legal representative:

Attorney: Attorney:

Contact number: Contact number:

Signing date