Home decoration engineering contract (reference text)

Principal: ___________________

Name: _____________________________

identification number:_______________________

Address of the residence: _________________________

Postal code: _________________________

contact number:_________________________

Delegate: _________________

Company Name:_________________________

legal representative:_________________________

Company address: _____________________

Certificate No:_________________________

Postal code: _________________________

contact number:_________________________

According to the relevant regulations of the state and the local government, this contract is signed by both parties for mutual compliance.

The first project overview

1. Project address:_____________________________________________

2. Room Specifications ________ Room ________ Hall

3. Construction area ________ room ________ square meters ________ hall ________ square meters kitchen ________ square meters bathroom ________ square meters.

4. Construction content

5. Entrusted method ____________________________

6. Start date ________ year ________ month ________ day

7. Completion date ________ year ________ month ________ day

8. Construction price ________ yuan

Of which: material ________ yuan

Labor fee ________ yuan

Other expenses ________ yuan

Second quality requirement

1. Material type, specification, name

2. The technical standards agreed to refer to the "Quality Specification for Home Decoration Projects" formulated by the China National Light Industry Council.

3. Construction Quality Inspection Supervision Department ______________________________________

4. If there are special quality requirements during the construction process, both parties should reach an agreement and sign a supplementary contract.

5. The warranty period is ________ years from the acceptance of the project, and the warranty is borne by the incumbent.

Third payment

1. After the signing of the contractor, the contractor shall prepay ________% of the price, and the balance shall be paid within one week after the completion of the acceptance. If the payment is delayed, ________% of the amount owed for each day of delay.

2. The payment method for the package clearer is _______________________________.

3. If there are any increase or decrease of the project during the construction process, both parties shall sign additional terms to increase or decrease the price.

Article 4 Liability for breach of contract

1. If Party B cannot guarantee the quality as expected, it shall be reworked at its own expense.

2. Due to Party B's reasons, it is not possible to complete the work on time. Party B shall pay Party A the loss fee of ________ yuan per day.

3. Due to Party A's reasons, it is not possible to complete the work on time. Party A shall pay Party A the loss of work fee of ________ yuan per day.

4. During the construction process, Party A is not responsible for the quality problems caused by the construction of the construction contents without negotiating with the representatives of Party B.

5. After the contract comes into effect, before the expiration of the performance period, the party who cancels the contract without authorization shall pay the liquidated damages according to the ________% of the contract price; if the contract has been arbitrarily terminated and the losses caused to the other party exceed the liquidated damages, compensation shall also be made to compensate for the breach of contract. The lack of gold.

6. If one party requests to cancel the contract and causes economic losses to the other party, compensation shall be made according to the actual losses.

Article 5 Dispute Resolution

1. The disputes arising in the performance of the contract can be resolved through negotiation. When the negotiation fails, the following methods are adopted:

Apply to the local interior decoration industry authorities for mediation.

Solved by arbitration.

Solve through litigation.

Article 6 Contract Change

1. The two parties have reached an agreement. If one party requests to change the content, it is necessary to obtain the consent of the other party and perform the signing procedure.

2. The contract shall take effect from the date of signing; the relevant warranty clause shall take effect during the warranty period, and the remaining terms shall be terminated; all terms shall be terminated after the expiration of the warranty period.

Article 7 Supplementary Provisions

Article 8 Contract Text

The original of this contract is two copies, one for each Party A and Party B, and a copy to be sent to the relevant department as needed.

Party A: ______________________

Party B: ______________________

________ years _____ month _____ day sign