Maintenance contract

Contract number: _________

Party A: _________

Legal address: _________

Legal representative: _________

Position: _________

Attorney: _________

identification number:_________

mailing address:_________

Postal code: _________

Contact: _________

phone:_________

fax:_________

account number:_________

email:_________

Party B: _________

Legal address: _________

Legal representative: _________

Position: _________

Attorney: _________

identification number:_________

mailing address:_________

Postal code: _________

Contact: _________

phone:_________

fax:_________

account number:_________

E-mail: _________ The two parties signed the following _________ amendment agreement through friendly negotiation based on the principle of mutual benefit:

The first repair repair project, quantity, compensation

┌──────────┬────┬──────┬─────┐

│Repair repair items and contents│Unit of measurement│Quantity or workload│ Remuneration│

│ │ │ ├──┬──┤

│ │ │ │Unit price │ Amount │

├──────────┼────┼──────┼──┼──┤

│ │ │ │ │ │ │

├──────────┼────┼──────┼──┼──┤

│ │ │ │ │ │ │

├──────────┼────┼──────┼──┼──┤

│ │ │ │ │ │ │

├──────────┴────┴──────┴──┴──┤

│ Total RMB amount: │

└────────────────────────────┘

Article 2 The ordering party guarantees that it has the right to repair the above _________.

Article 3 The contractor shall guarantee the repair certificate and the right to engage in repairs.

Article 4 material

┌──┬──┬──┬──┬──┬──┬──┬──┬──┬──┬──┬──┐

│Material│Trademark│Production│Specification│Measurement│Quantity│Quality│Provide│Delivery│Consumption│Unit Price│Price │

│Name│ │Manufacturer│Model│Unit│ │ │人│ Date│Standard │ │ │

├──┼──┼──┼──┼──┼──┼──┼──┼──┼──┼──┼──┤

│ │ │ │ │ │ │ │ │ │ │ │ │ │

├──┼──┼──┼──┼──┼──┼──┼──┼──┼──┼──┼──┤

│ │ │ │ │ │ │ │ │ │ │ │ │ │

├──┼──┼──┼──┼──┼──┼──┼──┼──┼──┼──┼──┤

│ │ │ │ │ │ │ │ │ │ │ │ │ │

├──┼──┼──┼──┼──┼──┼──┼──┼──┼──┼──┼──┤

│ │ │ │ │ │ │ │ │ │ │ │ │ │

└──┴──┴──┴──┴──┴──┴──┴──┴──┴──┴──┴──┘

Article 5 inspection

1. The standard for the person to be inspected by the contractor: _________, method: _________, time: _________, location: _________

2. The contractor shall verify the standards for the materials provided by the ordering party: _________, method: _________, time: _________, location: _________

Article 6 Repair and repair time

From ______ years _________ months _________ days to _________ years _________ months _________ days.

Article 7 Quality Requirements

Repair and repair items shall comply with the requirements and requirements of _________. The specific technical standards and quality requirements shall include: _________

Article 8 Information Provided

1. The ordering person shall provide the following technical materials and drawings to the contractor in the form of _________ at _________: _________.

2. If the contractor finds that the drawings and technical requirements provided by the ordering party are unreasonable, he shall submit a written objection to the ordering party on _________ days. The ordering party shall reply within ______ days after receiving the written objection.

Article 9 Subcontracting

1. The ordering party agrees to submit the main work of the fixed crop to a third party; the work that can be completed by a third party includes: _________.

2. If the contractor submits the main work contracted by him to a third party, he shall be responsible to the ordering party for the work done by the third party.

3. Both parties must employ a third party to perform the relevant obligations of the contractor in this Agreement after obtaining the written approval of the other party. Otherwise, the uninformed party has the right to unilaterally stop the execution of this agreement.

4. The contractor may submit the auxiliary work contracted by him to a third party. If the contractor submits the auxiliary work contracted by him to a third party, he shall be responsible to the ordering party for the work done by the third party.

Article 10 Confidentiality

The contractor shall keep secrets on the following aspects and may not retain copies or technical materials without the permission of the ordering party. Specifically include:

1. The parties agree that the content and data or information related to the parties during the execution of this contract are recognized as confidential.

2. Both parties are responsible for ensuring that their employees and employed third parties are strictly obligated to maintain confidentiality.

3. The author is responsible for his or her own confidential information.

Article 11: Consequences of midway changes

If the ordering party changes the requirements of the contracting work in the middle and causes the loss of the contractor, the loss shall be compensated.

Article 12 Assistance

1. The contractor shall provide the following assistance to the contractor: _________ and meet the following requirements: _________.

2. If the ordering party fails to perform the assistance obligation and the contracting work cannot be completed, the contractor may urge the ordering person to perform the assistance obligation within _________ days and may extend the performance period.

3. If the ordering party fails to perform the obligation of assistance within the time limit, the contractor may cancel the contract.

Article 13 Supervision

During the work, the contractor shall accept the necessary supervision and inspection by the ordering party, but the ordering person shall not obstruct the contractor’s normal work due to the supervision and inspection.

Article 14: Obligation to keep

The contractor shall properly keep the materials provided by the ordering party and the results of the work completed. If the damage is caused or damaged due to improper storage, the contractor shall be liable for damages.

Article 15 Replacement Parts:

1. Parts replacement may affect the function and performance of _________. The contractor shall proceed after consultation with the ordering party.

2. The replacement parts provided by the ordering person for the contractor must be guaranteed to be the original parts of the same brand as the equipment. If there are special circumstances, the contractor must replace the parts with the same function and technical indicators as the original parts after negotiating with the ordering party. .

3. The cost of replacing parts shall be borne by the ordering party. The contractor is obliged to provide the quotation of the parts, which shall be confirmed by the ordering party. The price of the parts in the quotation shall not be higher than that provided by the manufacturer of the equipment in the _________ authorized service center. The price of the parts. The ordering party may purchase the parts at a third place where the contractor has confirmed in writing.

4. The contractor shall not replace or hire a third party to replace or disassemble the parts without the written consent of the ordering party without the consent of the ordering party.

Article 16 Delivery

After the repair and repair project is completed, the delivery time is _________, delivery method: _________, delivery location: _________.

Article 17 Acceptance

1. The two parties agree to carry out the inspection and acceptance work of this repair by _________, and pay the prescribed reward _________ yuan. This part of the cost is borne by the ordering person.

2. The inspection standard for the repair and repair project is based on _________, and the experience collection time is: _________

Article 18 Repair costs

The cost of this repair is _________ yuan, and the ordering party shall prepay the contractor _________ yuan before the _________ year _________ month _________ day, after the completion of this repair and experience acceptance ________ _ The final payment of _________ yuan will be paid in the day.

Article 19 Settlement method

The payment and material fees are settled by: _________

Article 20 Warranty

After the equipment is repaired, the contractor provides a ____________month warranty for the same failure of the equipment.

However, the following conditions are not covered by the warranty:

1. Damage caused by unauthorized disassembly or handling;

2. Failure and damage caused by the use of counterfeit or shoddy materials;

3. Damage caused by force majeure such as natural disasters and human disasters;

4. Damage caused by the consent of the contractor or the employment of a third party.

Article 21 Change of Contract

During the performance of this contract, if any party needs to change this contract in the event of special circumstances, the party requesting the change shall promptly notify the other party in writing. After obtaining the consent of the other party, the parties shall sign a written change agreement within the prescribed time limit, and the agreement will become a contract. The part that is split. Without the written documents signed by both parties, neither party has the right to change this contract. Otherwise, the economic losses of the other party will be borne by the responsible party.

Article 22 Termination of the contract

The parties have the right to terminate this Agreement immediately and unilaterally if:

1. In the absence of special reasons, one of the parties has failed to perform its obligations under this contract.

2. Replace the parts privately without the consent of the ordering party.

3. When replacing parts, without the consent of the ordering party, the non-original brand/or counterfeit parts are replaced by the contractor. The contractor refunds the cost of the parts paid by the ordering party and replaces the original brand parts free of charge. If the equipment is damaged, the contractor People must pay compensation at market prices.

4. The contractor’s payment is owed without the consent of the contractor.

Article 23 Transfer of the contract

Except as otherwise provided in the contract or agreed by both parties, no rights or obligations of the parties under this contract shall be transferred to a third party without the prior written consent of the other party. Any transfer without any express written consent of the other party is void.

Article 24 Declaration and Guarantee

Make a person:

1. The ordering party guarantees that it has the right to sign and is capable of performing this contract.

2. At the time of signing this contract, no court, arbitral institution, administrative organ or regulatory body has made any judgment, ruling, ruling or specific administrative act sufficient to have a material adverse effect on the performance of this contract by the ordering party.

Contractor:

1. The contractor guarantees that he has the right to sign and is capable of performing this contract.

2. At the time of signing this contract, no court, arbitral institution, administrative organ or regulatory body has made any judgment, ruling, ruling or specific administrative act that is sufficient to cause the contractor to have a material adverse effect on the performance of this contract.

Article 25 Notice

1. According to this contract, all notices sent by one party to the other party, as well as the file exchanges between the two parties and the notices and requirements related to this contract, must be in writing and can be transmitted by _________. If the above methods cannot be delivered, the method of delivery of the announcement may be adopted.

2. The mailing address of each party is as follows: _________.

3. A party's change notice or mailing address shall be notified to the other party in writing within _________ days from the date of change; otherwise, the unreported party shall bear the relevant liabilities arising therefrom.

Article 26 Treatment of Disputes

1. This contract is governed by and construed in accordance with the laws of the People's Republic of China.

2. The disputes arising during the performance of this contract shall be settled by the parties concerned through negotiation, or may be settled by the relevant departments; if the negotiation or mediation fails, the following _________ methods shall be adopted:

Submit to the _________ Arbitration Commission for arbitration;

Prosecuted to the people's court according to law.

Article 27 Force Majeure

1. If any party to this contract fails to perform all or part of its obligations under this contract due to the event of force majeure, the performance of the obligation shall be suspended during the event of force majeure.

2. The party claiming to be affected by the force majeure event shall, as far as practicable, notify the other party of the occurrence of the force majeure event in writing within the shortest possible time, and provide the other party with such force majeure events within _________ days after the occurrence of the force majeure event. Appropriate evidence of its duration and written information that the contract cannot be performed or needs to be extended. Claiming a force majeure event causes its performance of this contract to be objectively impossible or impractical, and it is the responsibility of all reasonable efforts to eliminate or mitigate the effects of such force majeure events.

3. When a force majeure event occurs, both parties shall immediately decide how to implement this contract through friendly negotiation. Upon termination or elimination of the event of force majeure or its effects, both parties shall immediately resume the performance of their respective obligations under this contract. If force majeure and its effects cannot be terminated or eliminated, causing either party to the contract to lose the ability to continue to perform the contract, the parties may negotiate to terminate the contract or temporarily delay the performance of the contract, and the party facing the force majeure shall not be liable for this. If the party is force majeure after the delay in performance, the liability cannot be waived.

4. The term "force majeure" as used in this contract means that the affected party cannot reasonably control it. It cannot be expected or even if it is expected to be inevitable and cannot be overcome, and appears after the signing date of this contract, so that the party may Partial performance is objectively impossible or impractical. Such events include, but are not limited to, natural disasters such as floods, fires, droughts, typhoons, earthquakes, and social events such as war, turmoil, strikes, government actions, or legal requirements.

Article 28 Interpretation of the contract

The matters not covered in this contract or the content of the terms are not clear. The parties to the contract may reasonably interpret this contract according to the principles of this contract, the purpose of the contract, the trading habits and the content of the related terms. This interpretation is binding unless the interpretation is inconsistent with the law or this contract.

Article 29 Supplementary and Attached Files

If the matters not covered in this contract are implemented in accordance with relevant laws and regulations, and the laws and regulations do not stipulate, the two parties may reach a written supplementary contract. The subsidiary files and supplementary contracts of this contract are inseparable components of this contract and have the same legal effect as this contract.

Article 30: The validity of the contract

This contract shall take effect from the date on which the legal representatives of the parties or both parties or their authorized representatives sign and affix the official seal of the unit or the special seal of the contract.

Valid for _________ years, from _________ years ______ months _________ days to _________ years _________ months _________ days.

The original form of this contract is _________ copies, and each party holds _________ copies, which has the same legal effect.

Make a person: _________ Contractor: ______

Legal representative: _________ Legal representative: ______

Attorney: _________ Attorney: ______

Place of signing: _________ Signing location: _________

_________Year ____________________________________________