Repair repair contract
Founder: _______________
Contractor: _______________
The first repair and repair project
Project content compensation
Total RMB amount
Article 2 Material Material Name Trademark Manufacturer Specification Model Unit Quantity Quality Provider Provide Date Consumption Fixed Material Fee Unit Price Amount
Total RMB amount
Article 3 Inspection standards, methods, time, place and duration of protests: ___________ The fourth repair time is from _________ years ______ months ______ days to __________ years ______ months _ ___day.
Article 5 Technical standards and quality requirements for repair and repair projects: ____________ Article 6 The time, method and confidentiality requirements for the provision of technical materials and drawings by the ordering party: _______________ Article 7 The contractor finds the drawings and techniques provided by the ordering party If the request is unreasonable, a written protest shall be filed with the ordering party on _______ days. The ordering party shall reply within ________ days after receiving the written protest.
Article 8 The ordering party shall allow the third party to complete the main work of the repairing project; the work that can be completed by the third party is: ________. Article 9: The order of the ordering person to assist the contractor: _____________ Article 10 Time, method and place of repair and repair project delivery: __________________ Article 11 Acceptance standards, methods and time for repair and repair projects: __________________ Article 12 The ordering person shall be __________ years ______ days before ______ To the contractor _______________ yuan.
Article 13 Settlement method and time limit ____________ Article 14 Warranty period: __________ Article 15 Conditions for the dissolution of this contract: The ordering party may cancel the contract at any time, but it shall notify the contractor in person The damage caused to the contractor.
Article 16 Liability for breach of contract: ___________________How to calculate liquidated damages or damages: _________ Article 17: Settlement of contract disputes: The disputes arising under this contract shall be settled through negotiation between the two parties. If the negotiation fails, it shall be submitted to Suzhou City. Arbitration committee arbitration.
Article 18 Other agreed matters: ______________________
Settlement residence: Postal code: Contractor's residence: Postal code:
Legal representative: Legal representative:
Attorney: Attorney:
Phone: Fax: Phone: Fax:
Contractor: _______________
The first repair and repair project
Project content compensation
Total RMB amount
Article 2 Material Material Name Trademark Manufacturer Specification Model Unit Quantity Quality Provider Provide Date Consumption Fixed Material Fee Unit Price Amount
Total RMB amount
Article 3 Inspection standards, methods, time, place and duration of protests: ___________ The fourth repair time is from _________ years ______ months ______ days to __________ years ______ months _ ___day.
Article 5 Technical standards and quality requirements for repair and repair projects: ____________ Article 6 The time, method and confidentiality requirements for the provision of technical materials and drawings by the ordering party: _______________ Article 7 The contractor finds the drawings and techniques provided by the ordering party If the request is unreasonable, a written protest shall be filed with the ordering party on _______ days. The ordering party shall reply within ________ days after receiving the written protest.
Article 8 The ordering party shall allow the third party to complete the main work of the repairing project; the work that can be completed by the third party is: ________. Article 9: The order of the ordering person to assist the contractor: _____________ Article 10 Time, method and place of repair and repair project delivery: __________________ Article 11 Acceptance standards, methods and time for repair and repair projects: __________________ Article 12 The ordering person shall be __________ years ______ days before ______ To the contractor _______________ yuan.
Article 13 Settlement method and time limit ____________ Article 14 Warranty period: __________ Article 15 Conditions for the dissolution of this contract: The ordering party may cancel the contract at any time, but it shall notify the contractor in person The damage caused to the contractor.
Article 16 Liability for breach of contract: ___________________How to calculate liquidated damages or damages: _________ Article 17: Settlement of contract disputes: The disputes arising under this contract shall be settled through negotiation between the two parties. If the negotiation fails, it shall be submitted to Suzhou City. Arbitration committee arbitration.
Article 18 Other agreed matters: ______________________
Settlement residence: Postal code: Contractor's residence: Postal code:
Legal representative: Legal representative:
Attorney: Attorney:
Phone: Fax: Phone: Fax:
recommended article
- Maintenance contract
- Computer maintenance agreement
- Contract (including transportation)
- Parking contract
- Jingmen City residential decoration and construction project construction contract
- International tanker charter contract
- Lighter processing installation contract
- Car maintenance contract
- Mud painting contract
- House demolition entrustment contract
- Contract
- LOGO Design Registration Agreement
popular articles
- Life motto
- Weibo's famous sayings
- Grateful mother's words
- Space mood phrase
- Motivate employees
- Contract
- Blessing phrase
- Legal maxim
- 2014 motivational phrase
- Distressed sentence 2019
- Commissioned production contract model
- Processing contract model
- Encourage words 2019
- Philosophical words 2019
- About building a ship contract
- Construction and installation engineering construction contract
- Pump repair contract
- Respect the teacher's famous words
- Parental love
- Good sentence excerpt 2019
- Non-mainstream sentence 2019
- Repair repair contract
- Decoration contract demonstration text
- Relieved words
- Sample of the processing agreement (light industry)
- Spring Festival blessing
- Hyun dance family impression sentence
- What I said to my father 2019
- Not afraid of failure
- Print production contract