The Ministry of Construction and the State Administration for Industry and Commerce issued and issued the "Construction Project Cost Consultation Contract (
Notice of the Ministry of Construction and the State Administration for Industry and Commerce on Printing and Distributing the Construction Project Cost Consultation Contract
Construction departments of all provinces and autonomous regions, municipal construction commissions, industrial and commercial administrations, and relevant departments of the State Council:
In order to strengthen the construction project cost consulting market management and regulate market behavior, according to the "Contract Law of the People's Republic of China", we have formulated the "Construction Engineering Cost Consultation Contract", which is now issued to you and related to the implementation of the "Model Text". The problem notification is as follows:
1. When carrying out the construction project cost consulting business in China and signing the construction project cost consulting contract, the contract should be concluded with reference to this Model Text, and all regions and departments should be promoted and used.
2. The principal who signs the construction project cost consulting contract shall be a legal person or a natural person. The consultant must have legal personality and shall hold the engineering cost consulting qualification certificate issued by the construction administrative department and the business license of the enterprise legal person issued by the industrial and commercial administrative department. .
3. The contractual conditions of the "Model Text" are divided into two parts: "Contract Standard Conditions" and "Contract-Specific Conditions".
1. "Contract standard conditions" shall be quoted in full and shall not be deleted.
2. "Contract-specific conditions" shall be revised and supplemented according to the actual conditions of the consulting project according to the terms and contents of the articles, but shall not violate the principles of fairness and fairness.
4. The interpretation of the Model Text belongs to the Ministry of Construction and the State Administration for Industry and Commerce. If there are any problems and suggestions in implementation, please report to the Standards and Ratings Department of the Ministry of Construction and the Market Standardization Management Department of the State Administration for Industry and Commerce.
5. The "Model Text" will come into force on October 1, 2002.
Construction project cost consulting contract GF-2002-0212
Part I Construction Project Cost Consultation Contract
__________
versus__________
After the two sides reached a consensus, this contract was signed.
1. The client entrusts the consultant to provide construction project cost consulting services for the following projects:
1. Project Name:
2. Service category:
2. The wording and terminology of this contract shall be synonymous with the conditions of the construction project cost consulting contract and the relevant subsidiary files.
3. The following files are part of this contract:
1. Construction project cost consulting contract standard conditions;
2. Special conditions for construction project cost consulting contract;
3. Supplementary and revised files jointly signed in the execution of the construction project cost consulting contract.
4. The Consultant agrees to undertake the construction project cost consulting business within the scope agreed upon in the special conditions of this contract in accordance with the provisions of this contract.
5. The Principal agrees to pay the Consultant a fee in accordance with the time limit, method, currency and amount specified in this contract.
6. Construction cost consulting business of this contract
Implemented on the day of the month, until the year
The end of the month.
7. This contract is in quadruplicate and has the same legal effect. Both parties hold two copies.
Appointee: Consultant:
Legal representative: Legal representative:
Attorney: Attorney:
Residence: Residence:
Bank of deposit: Bank of deposit:
Account number: Account number:
Postal Code: Postal Code:
Telephone: Telephone:
Fax: Fax:
E-mail: E-mail:
Year month day year month day
Part II Construction project cost consulting contract standard conditions terms definition, applicable language and laws and regulations
Article 1 The following nouns and terms have the following meanings unless otherwise specified in the context.
1. “Principal” means the party entrusted with the construction project cost consulting business and the hired project cost consulting unit, and its legal heir.
2. “Consultant” means the party that undertakes the construction project cost consulting business and the project cost consulting responsibility, as well as its legal heir.
3. “Third person” means a party related to this consulting business other than the principal or consultant.
4. “Day” means the time period from 0:00 on any day to 0:00 on the next day.
Article 2 The construction project cost consulting contract shall be applicable to the laws and regulations of China, as well as the departmental regulations and the relevant pricing regulations and regulations of the project cost or the local regulations and local regulations of the project.
Article 3 The writing, interpretation and explanation of the construction project cost consulting contract shall be Chinese-led. When different language texts are interpreted differently, the Chinese contract text shall prevail.
Consultant's obligations
Article 4: Provide the client with information related to the project cost consulting business, including the qualification certificate for the project cost consultation, the list of professionals who undertake the business of the contract, the consulting work plan, etc., and conduct consultation according to the scope stipulated in the contract special conditions. business.
Article 5 The services provided by the consultant to the client during the performance of this contract include normal services, additional services and additional services.
1. “Normal service” refers to the engineering cost consulting work agreed by both parties in special conditions;
2. “Additional Services” means additional services other than “normal services” as determined by written agreement between the parties;
3. “Extra services” means those that are not “normal service” and “additional services”, but the additional workload that the consultant should increase in accordance with Articles 13, 20 and 22 of the standard conditions of the contract. .
Article 6 During the period of performance of the contract or within the time limit prescribed by the contract, confidential information related to the business activities stipulated in this contract shall not be disclosed.
Principal's obligations
Article 7 The principal shall be responsible for the coordination of the third party related to the construction project cost consulting business and provide external conditions for the consultant's work.
Article 8 The client shall provide the consultant with information related to the consulting business of the project free of charge within the agreed time.
Article 9 The client shall make a written reply on the matters submitted by the consultant in writing and requesting a reply within the agreed time. When the consultant requests the third party to provide relevant information, the client shall be responsible for the transfer and transfer of the information.
Article 10 The client shall authorize the representative who is qualified for the consulting business to be responsible for contacting the consultant.
Consultant's rights
Article 11 The client shall grant the following rights to the consultant within the scope of the entrusted construction project cost consulting business:
1. During the consultation process, if the information provided by the client is not clear, the consultant may submit a written report to the client.
2. During the consultation process, the consultant has the right to check or question the third party's questions related to the consulting business.
3. During the consultation process, the consultant has the right to survey the project site.
Principal rights
Article 12 The client has the following rights:
1. The client has the right to ask the consultant about the progress of the work and related content.
2. The principal has the right to elaborate opinions and suggestions on specific issues.
3. When the client determines that the consulting professional does not perform his duties according to the consulting contract, or colludes with the third party to cause economic losses to the client, the client has the right to request the replacement of the consulting professional until the contract is terminated and the consultant is required to bear the corresponding Liability.
Consultant's responsibility
Article 13 The term of responsibility of the consultant shall be the validity period of the construction project cost consulting contract. If the schedule is delayed or delayed due to the delay of the non-consultant's responsibility and exceeds the agreed date, the parties shall further agree to extend the validity period of the contract accordingly.
Article 14 During the period of responsibility of the consultant, the obligations stipulated in the construction project cost consulting contract shall be fulfilled, and the economic losses caused by the unilateral negligence of the consultant shall be compensated to the client. The total amount of compensation shall not exceed the total amount of construction project cost consulting remuneration.
Article 15 The consultant shall not promptly check or reply to the questions raised by the client or the third party, so that the contract cannot be performed in whole or in part, and the consultant shall bear the responsibility.
Article 16 When the consultant proposes that the claim for compensation to the client cannot be established, it shall compensate for the expenses incurred by the client due to the compensation or other requirements.
Principal responsibility
Article 17 The client shall perform the obligations stipulated in the construction project cost consulting contract. If there is a violation, it shall bear the liability for breach of contract and compensate the loss caused by the consultant.
Article 18 If the client fails to establish compensation or other requirements to the consultant, it shall compensate the expenses of the consultant for various expenses caused by the compensation or other requirements.
Contract effective, change and termination
Article 19 This contract shall come into force on the date of signature and seal by both parties.
Article 20 If the consultant's work or the third party causes the consultant's work to be hindered or delayed, resulting in an increase in the workload or duration, the consultant shall promptly notify the client of the situation and the possible impact. The increased workload is considered as an additional service, and the time for completing the construction project cost consulting work should be extended accordingly and additional remuneration will be obtained.
Article 21 When one of the parties requests to change or cancel the contract, it shall notify the other party before the 14th; if the party suffers losses due to the change or cancellation of the contract, the responsible party shall be responsible for compensation.
Article 22 If a consultant suspends or terminates the construction project cost consulting business for non-self reasons, the increased work of restoring the construction cost consulting business shall be regarded as additional services and shall be entitled to additional time and remuneration. .
Article 23 A notice or agreement to change or terminate a contract shall be in writing, and the original contract shall remain in force until the new agreement is reached.
Consultation business remuneration
Article 24 The normal construction project cost consulting business, the remuneration for additional work and additional work shall be calculated according to the method stipulated in the special conditions for the construction project cost consulting contract, and shall be paid according to the agreed time and amount.
Article 25 If the client fails to pay the construction project cost consulting remuneration within the prescribed payment period, the consultant shall compensate the consultant for the interest paid on the remuneration from the date of the specified payment. The amount of interest is calculated by multiplying the bank's current demand loan by the time of default on the last day of the payment period.
Article 26 If the principal objects to the remuneration or partial remuneration items in the payment notice submitted by the consultant, it shall, within two days after receiving the payment notice, notify the consultant of the objection, but the principal shall not delay its no objection. Payment of honoraria items.
Article 27 The currency currency and exchange rate adopted for the payment of the construction project construction consulting fee shall be stipulated by the contract-specific conditions.
other
Article 28 Due to the needs of the construction project cost consulting business, the consultant shall go abroad for inspections outside the contract, and the client shall be responsible for the expenses required by the client.
Article 29 If the consultant needs the assistance of an external expert, the cost shall be borne by the consultant within the scope of the entrusted construction project cost consulting business; the principal shall be recognized by the client outside the scope of the entrusted construction project cost consulting business. bear.
Article 30 The parties shall not assign the rights and obligations stipulated in the contract without the written consent of the other party.
Article 31 In addition to the written consent of the client, the consultant and the consulting professional shall not accept any remuneration related to the project cost consulting project other than the construction project cost consulting contract.
The consultant may not participate in any activity that may conflict with the interests of the principal as stipulated in the contract.
Settlement of contract disputes
Article 32 The compensation for losses and damages caused by breach of contract or termination of contract shall be settled through consultation between the client and the consultant; if no agreement is reached, it may be submitted to the relevant competent department for mediation; if the negotiation or mediation fails, The parties agree to submit to the arbitration organ for arbitration or to file a lawsuit with the people's court.
Part III Special conditions for construction project cost consulting contract
Article 2 The laws, regulations and engineering cost pricing methods and regulations applicable to this contract:
Article 4 The scope of construction project cost consulting business:
“Construction project cost consulting business” refers to the consulting business of the following service categories:
Preparation, review and project economic evaluation of investment estimates for construction project feasibility studies;
Preparation and review of construction project budget, budget, settlement, and completion settlement;
Construction project bidding base, bidding quotation preparation, review;
Engineering negotiation, change and identification and claims of contract disputes;
Prepare the project cost basis and monitor the project cost and provide relevant information on project cost.
Article 8 The construction project cost consulting materials and time provided by the client as agreed by the parties shall be:
Article 9 The client shall provide a written reply to the consultant's written request and request for a reply within the day.
Article 14 If the consultant fails to work during the period of his/her responsibility, he agrees to bear the economic losses caused by the unilateral responsibility in accordance with the following measures.
Compensation = direct economic loss × reward ratio
Article 24 The client agrees to pay the consultant's normal service fee according to the following calculation method, payment time and amount:
The Principal agrees to pay the additional service fee according to the following calculation method, payment time and amount:
The Principal agrees to pay the additional service fee according to the following calculation method, payment time and amount:
Article 27 The parties agree to pay the remuneration and pay at the exchange rate.
Article 32 If a construction project cost consulting contract is disputed during the performance process, the principal and the consultant shall resolve it in a timely manner; if no agreement is reached, it may be submitted to the relevant competent department for mediation; if the negotiation or mediation fails, the following Way to solve:
Submit to the Arbitration Commission for arbitration;
Prosecuted to the people's court according to law.
Additional agreement terms:
"Construction Engineering Cost Consultation Contract" Instructions for Use
The "Construction Project Cost Consultation Contract" includes "Standard Conditions for Construction Project Cost Consultation Contract" and "Special Conditions for Construction Project Cost Consultation Contract".
The "Standard Conditions" apply to all types of construction projects cost consulting, and both the client and the consultant should abide by them. The "Special Conditions" are based on the characteristics and conditions of the construction project, and are completed by the client and the consultant after consultation. The parties may also add additional terms and amendments to the agreement if they deem it necessary.
Instructions for completing the "Special Conditions":
The "Special Conditions" shall be filled in accordance with the order of the "Standard Conditions". For example, the second article should be based on the specific conditions of the construction project, such as the project type, construction site, etc., to fill in the applicable departments or local laws and regulations and relevant methods and regulations for project cost.
Article 4 When negotiating and clarifying the scope of “construction project cost consulting business scope”, it should first be clear that the scope of the project, such as engineering projects, individual projects or unit projects, and the consulting business involved, and the scope of the project covered by the project general contract or subcontract Consistent. Secondly, the investment estimates, budget estimates or budgets in different stages of project construction such as feasibility study, design, bidding stage or whole process engineering cost consultation should be clarified.
When filling in the construction project cost consulting remuneration standard, it should be based on the complexity of the construction project entrusted by the client, the amount of work, and the agreement between the two parties. Generally, 30% prepayment should be paid when the contract is signed. When the workload is 70% completed, 70% of the project payment is prepaid, and the remaining part is paid off once when the consultation result is finalized. If the consultant has additional services due to the obstacles or delays of the principal and the third party, the rewards should be paid, and the method of calculating the rewards and the time of payment should be agreed. When the payment time is stated, the amount of time should be written. Pay within days.
If the two parties agree to agree, a bonus clause can be established, but it must be equivalent.
Construction departments of all provinces and autonomous regions, municipal construction commissions, industrial and commercial administrations, and relevant departments of the State Council:
In order to strengthen the construction project cost consulting market management and regulate market behavior, according to the "Contract Law of the People's Republic of China", we have formulated the "Construction Engineering Cost Consultation Contract", which is now issued to you and related to the implementation of the "Model Text". The problem notification is as follows:
1. When carrying out the construction project cost consulting business in China and signing the construction project cost consulting contract, the contract should be concluded with reference to this Model Text, and all regions and departments should be promoted and used.
2. The principal who signs the construction project cost consulting contract shall be a legal person or a natural person. The consultant must have legal personality and shall hold the engineering cost consulting qualification certificate issued by the construction administrative department and the business license of the enterprise legal person issued by the industrial and commercial administrative department. .
3. The contractual conditions of the "Model Text" are divided into two parts: "Contract Standard Conditions" and "Contract-Specific Conditions".
1. "Contract standard conditions" shall be quoted in full and shall not be deleted.
2. "Contract-specific conditions" shall be revised and supplemented according to the actual conditions of the consulting project according to the terms and contents of the articles, but shall not violate the principles of fairness and fairness.
4. The interpretation of the Model Text belongs to the Ministry of Construction and the State Administration for Industry and Commerce. If there are any problems and suggestions in implementation, please report to the Standards and Ratings Department of the Ministry of Construction and the Market Standardization Management Department of the State Administration for Industry and Commerce.
5. The "Model Text" will come into force on October 1, 2002.
Construction project cost consulting contract GF-2002-0212
Part I Construction Project Cost Consultation Contract
__________
versus__________
After the two sides reached a consensus, this contract was signed.
1. The client entrusts the consultant to provide construction project cost consulting services for the following projects:
1. Project Name:
2. Service category:
2. The wording and terminology of this contract shall be synonymous with the conditions of the construction project cost consulting contract and the relevant subsidiary files.
3. The following files are part of this contract:
1. Construction project cost consulting contract standard conditions;
2. Special conditions for construction project cost consulting contract;
3. Supplementary and revised files jointly signed in the execution of the construction project cost consulting contract.
4. The Consultant agrees to undertake the construction project cost consulting business within the scope agreed upon in the special conditions of this contract in accordance with the provisions of this contract.
5. The Principal agrees to pay the Consultant a fee in accordance with the time limit, method, currency and amount specified in this contract.
6. Construction cost consulting business of this contract
Implemented on the day of the month, until the year
The end of the month.
7. This contract is in quadruplicate and has the same legal effect. Both parties hold two copies.
Appointee: Consultant:
Legal representative: Legal representative:
Attorney: Attorney:
Residence: Residence:
Bank of deposit: Bank of deposit:
Account number: Account number:
Postal Code: Postal Code:
Telephone: Telephone:
Fax: Fax:
E-mail: E-mail:
Year month day year month day
Part II Construction project cost consulting contract standard conditions terms definition, applicable language and laws and regulations
Article 1 The following nouns and terms have the following meanings unless otherwise specified in the context.
1. “Principal” means the party entrusted with the construction project cost consulting business and the hired project cost consulting unit, and its legal heir.
2. “Consultant” means the party that undertakes the construction project cost consulting business and the project cost consulting responsibility, as well as its legal heir.
3. “Third person” means a party related to this consulting business other than the principal or consultant.
4. “Day” means the time period from 0:00 on any day to 0:00 on the next day.
Article 2 The construction project cost consulting contract shall be applicable to the laws and regulations of China, as well as the departmental regulations and the relevant pricing regulations and regulations of the project cost or the local regulations and local regulations of the project.
Article 3 The writing, interpretation and explanation of the construction project cost consulting contract shall be Chinese-led. When different language texts are interpreted differently, the Chinese contract text shall prevail.
Consultant's obligations
Article 4: Provide the client with information related to the project cost consulting business, including the qualification certificate for the project cost consultation, the list of professionals who undertake the business of the contract, the consulting work plan, etc., and conduct consultation according to the scope stipulated in the contract special conditions. business.
Article 5 The services provided by the consultant to the client during the performance of this contract include normal services, additional services and additional services.
1. “Normal service” refers to the engineering cost consulting work agreed by both parties in special conditions;
2. “Additional Services” means additional services other than “normal services” as determined by written agreement between the parties;
3. “Extra services” means those that are not “normal service” and “additional services”, but the additional workload that the consultant should increase in accordance with Articles 13, 20 and 22 of the standard conditions of the contract. .
Article 6 During the period of performance of the contract or within the time limit prescribed by the contract, confidential information related to the business activities stipulated in this contract shall not be disclosed.
Principal's obligations
Article 7 The principal shall be responsible for the coordination of the third party related to the construction project cost consulting business and provide external conditions for the consultant's work.
Article 8 The client shall provide the consultant with information related to the consulting business of the project free of charge within the agreed time.
Article 9 The client shall make a written reply on the matters submitted by the consultant in writing and requesting a reply within the agreed time. When the consultant requests the third party to provide relevant information, the client shall be responsible for the transfer and transfer of the information.
Article 10 The client shall authorize the representative who is qualified for the consulting business to be responsible for contacting the consultant.
Consultant's rights
Article 11 The client shall grant the following rights to the consultant within the scope of the entrusted construction project cost consulting business:
1. During the consultation process, if the information provided by the client is not clear, the consultant may submit a written report to the client.
2. During the consultation process, the consultant has the right to check or question the third party's questions related to the consulting business.
3. During the consultation process, the consultant has the right to survey the project site.
Principal rights
Article 12 The client has the following rights:
1. The client has the right to ask the consultant about the progress of the work and related content.
2. The principal has the right to elaborate opinions and suggestions on specific issues.
3. When the client determines that the consulting professional does not perform his duties according to the consulting contract, or colludes with the third party to cause economic losses to the client, the client has the right to request the replacement of the consulting professional until the contract is terminated and the consultant is required to bear the corresponding Liability.
Consultant's responsibility
Article 13 The term of responsibility of the consultant shall be the validity period of the construction project cost consulting contract. If the schedule is delayed or delayed due to the delay of the non-consultant's responsibility and exceeds the agreed date, the parties shall further agree to extend the validity period of the contract accordingly.
Article 14 During the period of responsibility of the consultant, the obligations stipulated in the construction project cost consulting contract shall be fulfilled, and the economic losses caused by the unilateral negligence of the consultant shall be compensated to the client. The total amount of compensation shall not exceed the total amount of construction project cost consulting remuneration.
Article 15 The consultant shall not promptly check or reply to the questions raised by the client or the third party, so that the contract cannot be performed in whole or in part, and the consultant shall bear the responsibility.
Article 16 When the consultant proposes that the claim for compensation to the client cannot be established, it shall compensate for the expenses incurred by the client due to the compensation or other requirements.
Principal responsibility
Article 17 The client shall perform the obligations stipulated in the construction project cost consulting contract. If there is a violation, it shall bear the liability for breach of contract and compensate the loss caused by the consultant.
Article 18 If the client fails to establish compensation or other requirements to the consultant, it shall compensate the expenses of the consultant for various expenses caused by the compensation or other requirements.
Contract effective, change and termination
Article 19 This contract shall come into force on the date of signature and seal by both parties.
Article 20 If the consultant's work or the third party causes the consultant's work to be hindered or delayed, resulting in an increase in the workload or duration, the consultant shall promptly notify the client of the situation and the possible impact. The increased workload is considered as an additional service, and the time for completing the construction project cost consulting work should be extended accordingly and additional remuneration will be obtained.
Article 21 When one of the parties requests to change or cancel the contract, it shall notify the other party before the 14th; if the party suffers losses due to the change or cancellation of the contract, the responsible party shall be responsible for compensation.
Article 22 If a consultant suspends or terminates the construction project cost consulting business for non-self reasons, the increased work of restoring the construction cost consulting business shall be regarded as additional services and shall be entitled to additional time and remuneration. .
Article 23 A notice or agreement to change or terminate a contract shall be in writing, and the original contract shall remain in force until the new agreement is reached.
Consultation business remuneration
Article 24 The normal construction project cost consulting business, the remuneration for additional work and additional work shall be calculated according to the method stipulated in the special conditions for the construction project cost consulting contract, and shall be paid according to the agreed time and amount.
Article 25 If the client fails to pay the construction project cost consulting remuneration within the prescribed payment period, the consultant shall compensate the consultant for the interest paid on the remuneration from the date of the specified payment. The amount of interest is calculated by multiplying the bank's current demand loan by the time of default on the last day of the payment period.
Article 26 If the principal objects to the remuneration or partial remuneration items in the payment notice submitted by the consultant, it shall, within two days after receiving the payment notice, notify the consultant of the objection, but the principal shall not delay its no objection. Payment of honoraria items.
Article 27 The currency currency and exchange rate adopted for the payment of the construction project construction consulting fee shall be stipulated by the contract-specific conditions.
other
Article 28 Due to the needs of the construction project cost consulting business, the consultant shall go abroad for inspections outside the contract, and the client shall be responsible for the expenses required by the client.
Article 29 If the consultant needs the assistance of an external expert, the cost shall be borne by the consultant within the scope of the entrusted construction project cost consulting business; the principal shall be recognized by the client outside the scope of the entrusted construction project cost consulting business. bear.
Article 30 The parties shall not assign the rights and obligations stipulated in the contract without the written consent of the other party.
Article 31 In addition to the written consent of the client, the consultant and the consulting professional shall not accept any remuneration related to the project cost consulting project other than the construction project cost consulting contract.
The consultant may not participate in any activity that may conflict with the interests of the principal as stipulated in the contract.
Settlement of contract disputes
Article 32 The compensation for losses and damages caused by breach of contract or termination of contract shall be settled through consultation between the client and the consultant; if no agreement is reached, it may be submitted to the relevant competent department for mediation; if the negotiation or mediation fails, The parties agree to submit to the arbitration organ for arbitration or to file a lawsuit with the people's court.
Part III Special conditions for construction project cost consulting contract
Article 2 The laws, regulations and engineering cost pricing methods and regulations applicable to this contract:
Article 4 The scope of construction project cost consulting business:
“Construction project cost consulting business” refers to the consulting business of the following service categories:
Preparation, review and project economic evaluation of investment estimates for construction project feasibility studies;
Preparation and review of construction project budget, budget, settlement, and completion settlement;
Construction project bidding base, bidding quotation preparation, review;
Engineering negotiation, change and identification and claims of contract disputes;
Prepare the project cost basis and monitor the project cost and provide relevant information on project cost.
Article 8 The construction project cost consulting materials and time provided by the client as agreed by the parties shall be:
Article 9 The client shall provide a written reply to the consultant's written request and request for a reply within the day.
Article 14 If the consultant fails to work during the period of his/her responsibility, he agrees to bear the economic losses caused by the unilateral responsibility in accordance with the following measures.
Compensation = direct economic loss × reward ratio
Article 24 The client agrees to pay the consultant's normal service fee according to the following calculation method, payment time and amount:
The Principal agrees to pay the additional service fee according to the following calculation method, payment time and amount:
The Principal agrees to pay the additional service fee according to the following calculation method, payment time and amount:
Article 27 The parties agree to pay the remuneration and pay at the exchange rate.
Article 32 If a construction project cost consulting contract is disputed during the performance process, the principal and the consultant shall resolve it in a timely manner; if no agreement is reached, it may be submitted to the relevant competent department for mediation; if the negotiation or mediation fails, the following Way to solve:
Submit to the Arbitration Commission for arbitration;
Prosecuted to the people's court according to law.
Additional agreement terms:
"Construction Engineering Cost Consultation Contract" Instructions for Use
The "Construction Project Cost Consultation Contract" includes "Standard Conditions for Construction Project Cost Consultation Contract" and "Special Conditions for Construction Project Cost Consultation Contract".
The "Standard Conditions" apply to all types of construction projects cost consulting, and both the client and the consultant should abide by them. The "Special Conditions" are based on the characteristics and conditions of the construction project, and are completed by the client and the consultant after consultation. The parties may also add additional terms and amendments to the agreement if they deem it necessary.
Instructions for completing the "Special Conditions":
The "Special Conditions" shall be filled in accordance with the order of the "Standard Conditions". For example, the second article should be based on the specific conditions of the construction project, such as the project type, construction site, etc., to fill in the applicable departments or local laws and regulations and relevant methods and regulations for project cost.
Article 4 When negotiating and clarifying the scope of “construction project cost consulting business scope”, it should first be clear that the scope of the project, such as engineering projects, individual projects or unit projects, and the consulting business involved, and the scope of the project covered by the project general contract or subcontract Consistent. Secondly, the investment estimates, budget estimates or budgets in different stages of project construction such as feasibility study, design, bidding stage or whole process engineering cost consultation should be clarified.
When filling in the construction project cost consulting remuneration standard, it should be based on the complexity of the construction project entrusted by the client, the amount of work, and the agreement between the two parties. Generally, 30% prepayment should be paid when the contract is signed. When the workload is 70% completed, 70% of the project payment is prepaid, and the remaining part is paid off once when the consultation result is finalized. If the consultant has additional services due to the obstacles or delays of the principal and the third party, the rewards should be paid, and the method of calculating the rewards and the time of payment should be agreed. When the payment time is stated, the amount of time should be written. Pay within days.
If the two parties agree to agree, a bonus clause can be established, but it must be equivalent.
recommended article
- Construction project demolition house contract
- Demonstration text of commercial housing contract
- Urban residential area owner management committee charter
- Shanghai Housing Sublease Contract Sample
- Demonstration text of construction project contract (2)
- Construction engineering technical consulting contract
- Room decoration commission
- Shanghai housing rental (commercial housing pre-leasing)
- Shanghai Participatory Housing Agreement
- Qingdao Construction Project Construction Contract
- Construction Engineering Design Contract (3)
- Engineering construction supervision commission
popular articles
- Classical life motto
- Temporary wall construction agreement
- English famous words
- Taizai’s famous sayings
- Construction project construction contract (general)
- Construction project demolition house contract (official model
- 2014 is very touching words
- Ministry of Construction, State Administration for Industry and Commerce
- Strong words
- College entrance examination inspirational quotes
- Injured sentence
- Bing Xin’s famous words
- Thanks to the friend's words 2019
- Team construction contract (construction team)
- Contract conditions for construction of water conservancy and hydropower civil engineering
- Describe the fast time sentence 2019
- Real estate mortgage loan contract
- I want to say something to the teacher.
- Sad love sentence 2019
- Teacher's famous saying
- Construction engineering survey contract
- Construction project entrusted supervision contract (Chinese and English)
- Du Yuexi's famous sayings
- a good saying that loves labor
- Deaf people jingle 2019
- The latest high school inspirational maxim
- Tao Xingzhi's famous sayings
- Qingdao Construction Project Construction Contract
- Korean swear words
- Qq space mood phrase