Construction Engineering Design Contract (3)

Construction engineering design contract

Enter into the contract:
Construction unit: _____, hereinafter referred to as Party A;
Design unit: _____, hereinafter referred to as Party B;
After full negotiation between Party A and Party B, this contract is signed in order to comply with it.

The first project name, scale, investment amount, construction site

Party A entrusts Party B to undertake the design project of ____ project, the construction and installation area is _____ square meters, the approved total investment is ___10,000 yuan, and the construction site is ____.

Article 2 Party A’s obligations

1. Party A shall submit to Party B the design task book approved by the superior, the site selection report, and the agreement files of raw materials, fuel, water, electricity, transportation, etc., which meet the preliminary design requirements, before ________. Survey data, technical materials that need to be obtained through scientific research. Party A shall provide approved preliminary design files and survey data that meet the design requirements of the construction drawings, construction conditions, and technical information about the equipment before the construction drawing of the ______________.

Party A is responsible for the accuracy of the above information.

2. Promptly handle the design file approval work at each design stage.

3. Before the commencement of the project, Party A shall organize the relevant construction unit, and Party B shall carry out the design and technical disclosure; after the completion of the project, Party A shall notify Party B to participate in the completion acceptance.

4. When the designer enters the construction site to carry out the work, Party A shall provide the necessary working conditions and be convenient in life. During the design and construction process, the trial production test shall be carried out due to technical special needs. Party A is responsible for the travel expenses of the party to the field.

5. Party A must maintain Party B's design files and may not modify them without authorization. Party A shall not copy, reuse or arbitrarily expand the scope of construction without the consent of Party B.

6. Party A shall have a confidentiality obligation to Party B's design results and may not transfer it to a third party for reuse without permission.

Article 3 Obligation of Party B

1. Party B must deliver the preliminary design file to Party A before the _________ date; deliver the technical design file to Party A before _________, and deliver the construction to Party A before ______ Graphic design file. Among them, the preliminary design file is a ___ share, the technical design file is a ___ share, the construction drawing design file is a ___ share, and the other party needs to add the number of files to the model fee, and the fee is charged separately. Before ___year__month__ day, Party B must submit all design files to Party A.

.

2. Party B must submit the survey technical requirements and design according to the approved design task book or the approval file of the previous stage design, as well as the design technical and economic agreement files, design standards, technical specifications, procedures, quotas, etc., and submit the quality-compliant design files.

3. After the preliminary design has been reviewed by the higher authorities, Party B shall be responsible for the necessary modifications within the scope of the original mission statement.

4. The design unit shall cooperate with the construction project to undertake the design task, carry out the technical pre-construction technical disclosure, solve the relevant design problems in the construction, be responsible for design change and revision budget, participate in concealed project acceptance and project completion acceptance.

Article 4 Modification and suspension of design

1. Party A shall request the modification of the design of the project for any reason. With the consent of Party B, Party A shall, in addition to the delivery time of the design file, be revised according to the actual rework date of Party B, and increase the design fee by ___ yuan per working day, or according to the design stage. The percentage of work in rework is calculated.

2. If the original task book is reworked or modified if there is a major change, it must have a submission from the design approval authority or the design task approval authority. The payment of the design cost that has already been carried out is calculated according to the preceding article.

3. If Party A requests to stop design in the middle of the reason, Party B shall promptly notify Party B in writing that the design fee has not been refunded, and the design fee shall be increased and paid according to the actual labor day at that stage, and the contractual relationship shall be terminated.

Article 5 Number of Design Fees and Delivery Method

Within ___ days after the design contract is effective, Party A shall deliver a deposit equivalent to ____% of the design fee to Party B. After the design contract is fulfilled, the deposit will be used as the design fee; Party B shall submit the preliminary design plan to Party A within ___ days. Party shall pay Party B a design fee of ____%; Party B shall settle all design fees to Party B within ___ days after Party A submits the construction drawing file.

Article 6 Reward and Breach of Contract

1. Within the reasonable project investment control number, since Party B uses advanced technology or reasonable advice to save engineering investment, it can withdraw ___% from Party B to save the investment amount.

2. Since Party A cannot provide relevant design information on time and accurately, causing Party B to fail to design or cause design rework, Party B shall, in addition to extending the date of delivery of the design file, Party A shall, according to the actual loss of working days of Party B, daily ___yuan Calculate the incremental design fee.

3. Party A shall not pay the deposit and design fee to Party B in accordance with the time stipulated in the contract, and shall pay Party B the liquidated damages according to the bank's provisions on deferred payment.

4. Due to Party B's reasons, delay in the delivery of the design file, Party B shall pay Party A a penalty of ____% of the design fee for each delay of ___ days.

5. Due to the poor quality of the design of Party B, it is necessary for Party B to continue to improve the design tasks, and to reduce the amount of waste caused by the loss or the design fee. For those who have caused major quality accidents due to design errors of Party B, Party B shall not only pay the design fee for the lost part, but also pay corresponding liability.

Article 7 Other

__________.

Article 8

This contract is effective after the signature of both parties on ___year__month__day, and all design tasks are invalid after completion. If there are any unfinished matters in this contract, it is necessary to make additional provisions through mutual consultation. The Supplementary Agreement is equally valid as this Agreement. However, it must not contradict the contents of this contract.

In the event of a dispute arising from the execution of the contract, both parties shall resolve it in a timely manner. If the two parties belong to the same department when the negotiation fails, the mediation by the superior competent department; if the mediation fails or does not belong to the same department, it may apply to the ___ arbitration committee for arbitration.

The original of this contract is in duplicate, one for each of Party A and Party B; one copy of the contract is ____ copies, and one for each unit of the Commission, Construction Committee, China Construction Bank, etc.

Construction unit: Design unit:
Legal representative: _______ Legal representative: ____
Contact: _________ Contact: _________
Communications Office: _________ Communications Office: _________
Phone or telegram: _______ Phone or telegram: _______
Bank of deposit: ________ Bank of deposit: ________
Account number: __________ Account number: __________
___Year __月__日订
Attached:
______ design project fee schedule;
______ Engineering Design Supplementary Agreement.

Schedule 1
Design project fee schedule
┌───┬───┬───┬───┬───┬───┬───┬───┬──┐
│Project │Project Name │Unit │Design │Unit │Engineering │Investment Evaluation │Design Fee │Design │
│号│称│方米│容│价││元)│
│ │ │ │ │ m) │ │ │ ││
├───┼───┼───┼───┼───┼───┼───┼───┼──┤
│ │ │ │ │ │ │ │ │ ││
├───┼───┼───┼───┼───┼───┼───┼───┼──┤
│ │ │ │ │ │ │ │ │ ││
├───┼───┼───┼───┼───┼───┼───┼───┼──┤
│ │ │ │ │ │ │ │ │ ││
├───┼───┼───┼───┼───┼───┼───┼───┼──┤
│ │ │ │ │ │ │ │ │ ││
├───┴───┴───┴───┴───┴───┴───┴───┴──┤
│This project entrusts the design of a total of square meters of investment estimate total yuan, estimated design fee │
│ Total yuan. When signing the contract, Party A shall pay Party B a design fee of 50% and temporarily pay the amount according to the yuan. │
└──────────────────────────────────┘

Note: The investment estimate is obtained by Party A. The designed investment amount is subject to the approved preliminary design estimate or revised design estimate.

Construction unit: Design unit:
Infrastructure Leader: _____ Infrastructure Leader: ______
Signing a fee agreement: ____ years __ month __ day

Schedule 2
____ Engineering Design Supplementary Agreement
This Agreement is signed under the architectural design contract No. ____ and is an attached file of the original contract. The ___ needs to be compiled _____ design, the two sides agreed. Party A shall submit the following basic materials for construction file design on time:
┌──────┬─────────────┬──────────────┐
│ No. │ File and data name │ Delivery date │
├──────┼─────────────┼──────────────┤
│ │ ││
├──────┼─────────────┼──────────────┤
│ │ ││
├──────┼─────────────┼──────────────┤
│ │ ││
└──────┴─────────────┴──────────────┘

Party B shall deliver the following design files on time on the premise that Party A submits the above files and materials on time:

┌──────┬─────────────┬──────────────┐
│ No. │ Design file name and content │ Delivery date │
├──────┼─────────────┼──────────────┤
│ │ ││
├──────┼─────────────┼──────────────┤
│ │ ││
├──────┼─────────────┼──────────────┤
│ │ ││
└──────┴─────────────┴──────────────┘
Construction unit: _____ Design unit: _____
Infrastructure Leader: _____ Design Office Director: ______
Date of signing the agreement: ____ years __ month __ day