Construction engineering survey contract
Construction unit:____________________________
Address: ____________ Postal Code ____________ Telephone ____________
Legal representative: ____________ Position ____________
Survey unit: ____________________________
Address: ____________ Postal Code ____________ Telephone ____________
Legal representative: ____________ Position ____________
In order to clarify the economic responsibilities of the construction unit and the survey unit, work division and cooperation, mutual promotion, and more quickly and provincially complete the survey task of the construction project, according to the construction project project that has been formally approved, the contract is concluded after full consultation between the two parties. So that both parties can abide by.
Article 1 Project name, scale, investment amount, construction site ________________________.
Article 2 The scope, progress and quality of the survey ________________________.
Article 3 Obligations of Party A
1. When signing the contract, Party A must submit a copy of the plan assignment document approved by the infrastructure program to Party B, and submit the land approval file and red line copy for the engineering geological survey.
2. When signing the contract, Party A must submit to Party B the topographic map and the floor plan of the survey area proposed by the design unit and agreed by the construction unit on the ____________________ The survey technical requirements and drawings entrusted by the construction unit and the design unit are responsible for the time, schedule and quality of the submission.
3. Party A must do the work of water, electricity supply, leveling roads, cleaning the site, and preparing materials for on-site survey work before ____________________
4. Party A must complete the compensation procedures for land acquisition, demolition, tree cutting, and mining of young crops before Party B enters the scene on ____________________________
5. Party A must be responsible for resolving the conditions of food, accommodation, office and other conditions of Party B's prospectors. Party B shall pay for the food and shelter expenses of Party B's on-site survey personnel. If Party A arranges to live in a guest house or restaurant, the expenses shall be borne by Party A. The collective welfare facilities of Party A’s personnel shall provide convenience for Party B’s personnel. The necessary settings for the construction of migrant workers, fuel materials, and winter heating, coal and timber are supplied by Party A; the maintenance of the production site and the maintenance of the equipment are handled by Party A and bear the expenses.
6. The transportation and labor costs of Party B's survey personnel and surveying equipment entering the project site shall be borne by Party A.
7. Party A's survey results file of Party B shall not be modified without authorization and may not be transferred to a third party for repeated use.
Article 4 Obligations of Party B
1. Party B shall conduct engineering survey, engineering geological and hydrogeological survey work in accordance with current standards, specifications and technical regulations, and submit survey results according to the schedule and quality stipulated in the contract.
2. Party B shall enter the site survey on ____________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________ The book is a ____ copy. If Party B affects the on-site construction for more than 3 days due to climate or Party A, the construction period can be postponed.
Article 5 Deposit and Survey Fees and Methods of Disbursement
1. The survey fee is charged according to the engineering survey fee standard issued by the competent national authority. The total price is estimated to be ________ yuan. Within ________ days after the commencement of this survey contract, Party A shall pay Party B a deposit equivalent to 30% of the survey fee; after the survey contract is performed, the deposit shall be used as the survey fee. If Party A fails to perform the contract, it has no right to demand repayment of the deposit. If Party B fails to perform the contract, it shall return the deposit twice. After the commencement of the survey work, Party A shall pay Party B 30% of the survey fee; after the completion of the survey project, Party B shall submit the survey report and drawings to Party A according to the contract, and carry out the project settlement. After Party A extracts the information, ____ During the day, the survey fee shall be paid according to the actual survey workload. The payment of survey expenses shall be handled by the Construction Bank for collection and commitment.
2. For the special project charging method, in principle, 20% to 40% of the survey fee will be charged according to the total price of the survey project.
Article 6 Party A’s liability for breach of contract
1. If Party A changes its plan, or the information provided is inaccurate, or fails to provide the necessary information or working conditions for survey and design, and causes rework, suspension, work or modification of the survey and design, Party A shall The actual amount of work consumed by Party B shall be increased, and the construction period shall be postponed. Due to the responsibility of Party A, significant rework or redesign of the design shall be caused. The additional construction fee shall be increased and the construction period shall be postponed.
2. If Party A delivers the survey fee or deposit beyond the time specified in the contract, Party B shall pay Party B a penalty of ________ yuan in accordance with the bank's delay in payment.
Article 7 Party B’s liability for breach of contract
1. If Party B reworks or causes engineering losses due to poor quality of survey, it shall continue to improve the survey and bear economic and technical responsibilities according to the losses caused. Party A may reduce the amount of damage caused by the damage, and reduce or not pay the survey and design fees.
2. If Party B causes major quality accidents in the project due to investigation errors, in addition to exempting the survey and design fees from the lost part, it shall also pay compensation equal to the part of the survey and design fee directly affected by the loss.
3. Since Party B's liability delays the provision of survey files for a period of more than ____ days, each time a delay is made, Party A shall pay Party A a penalty of ____% of the total price of the engineering survey fee.
Article 8 Dispute Resolution
In the event of a dispute arising from the execution of this contract, both parties shall promptly resolve the dispute. If the two parties belong to the same department and the mediation is not completed by the competent authorities at the higher level, or if they do not belong to the same department, they shall be resolved according to the following method: apply for arbitration by the ________ Arbitration Commission;
Article 9 Other Agreements
________________________________________________________________
This contract is valid after signing by both parties on ________________________________________________________________________________________________________________________________ If there are any outstanding matters in this contract, it is necessary to make a supplementary agreement through mutual consultation. The Supplementary Agreement is equally valid as this Agreement.
The original of this contract is in duplicate, one for each of Party A and Party B; one copy of the contract is ____ copies, and is sent to the Commission, Construction Committee, and CCB.
Construction unit:____________
Representative: ______________________
____year month day
Survey unit: ____________
Representative: ______________________
____year month day
Address: ____________ Postal Code ____________ Telephone ____________
Legal representative: ____________ Position ____________
Survey unit: ____________________________
Address: ____________ Postal Code ____________ Telephone ____________
Legal representative: ____________ Position ____________
In order to clarify the economic responsibilities of the construction unit and the survey unit, work division and cooperation, mutual promotion, and more quickly and provincially complete the survey task of the construction project, according to the construction project project that has been formally approved, the contract is concluded after full consultation between the two parties. So that both parties can abide by.
Article 1 Project name, scale, investment amount, construction site ________________________.
Article 2 The scope, progress and quality of the survey ________________________.
Article 3 Obligations of Party A
1. When signing the contract, Party A must submit a copy of the plan assignment document approved by the infrastructure program to Party B, and submit the land approval file and red line copy for the engineering geological survey.
2. When signing the contract, Party A must submit to Party B the topographic map and the floor plan of the survey area proposed by the design unit and agreed by the construction unit on the ____________________ The survey technical requirements and drawings entrusted by the construction unit and the design unit are responsible for the time, schedule and quality of the submission.
3. Party A must do the work of water, electricity supply, leveling roads, cleaning the site, and preparing materials for on-site survey work before ____________________
4. Party A must complete the compensation procedures for land acquisition, demolition, tree cutting, and mining of young crops before Party B enters the scene on ____________________________
5. Party A must be responsible for resolving the conditions of food, accommodation, office and other conditions of Party B's prospectors. Party B shall pay for the food and shelter expenses of Party B's on-site survey personnel. If Party A arranges to live in a guest house or restaurant, the expenses shall be borne by Party A. The collective welfare facilities of Party A’s personnel shall provide convenience for Party B’s personnel. The necessary settings for the construction of migrant workers, fuel materials, and winter heating, coal and timber are supplied by Party A; the maintenance of the production site and the maintenance of the equipment are handled by Party A and bear the expenses.
6. The transportation and labor costs of Party B's survey personnel and surveying equipment entering the project site shall be borne by Party A.
7. Party A's survey results file of Party B shall not be modified without authorization and may not be transferred to a third party for repeated use.
Article 4 Obligations of Party B
1. Party B shall conduct engineering survey, engineering geological and hydrogeological survey work in accordance with current standards, specifications and technical regulations, and submit survey results according to the schedule and quality stipulated in the contract.
2. Party B shall enter the site survey on ____________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________________ The book is a ____ copy. If Party B affects the on-site construction for more than 3 days due to climate or Party A, the construction period can be postponed.
Article 5 Deposit and Survey Fees and Methods of Disbursement
1. The survey fee is charged according to the engineering survey fee standard issued by the competent national authority. The total price is estimated to be ________ yuan. Within ________ days after the commencement of this survey contract, Party A shall pay Party B a deposit equivalent to 30% of the survey fee; after the survey contract is performed, the deposit shall be used as the survey fee. If Party A fails to perform the contract, it has no right to demand repayment of the deposit. If Party B fails to perform the contract, it shall return the deposit twice. After the commencement of the survey work, Party A shall pay Party B 30% of the survey fee; after the completion of the survey project, Party B shall submit the survey report and drawings to Party A according to the contract, and carry out the project settlement. After Party A extracts the information, ____ During the day, the survey fee shall be paid according to the actual survey workload. The payment of survey expenses shall be handled by the Construction Bank for collection and commitment.
2. For the special project charging method, in principle, 20% to 40% of the survey fee will be charged according to the total price of the survey project.
Article 6 Party A’s liability for breach of contract
1. If Party A changes its plan, or the information provided is inaccurate, or fails to provide the necessary information or working conditions for survey and design, and causes rework, suspension, work or modification of the survey and design, Party A shall The actual amount of work consumed by Party B shall be increased, and the construction period shall be postponed. Due to the responsibility of Party A, significant rework or redesign of the design shall be caused. The additional construction fee shall be increased and the construction period shall be postponed.
2. If Party A delivers the survey fee or deposit beyond the time specified in the contract, Party B shall pay Party B a penalty of ________ yuan in accordance with the bank's delay in payment.
Article 7 Party B’s liability for breach of contract
1. If Party B reworks or causes engineering losses due to poor quality of survey, it shall continue to improve the survey and bear economic and technical responsibilities according to the losses caused. Party A may reduce the amount of damage caused by the damage, and reduce or not pay the survey and design fees.
2. If Party B causes major quality accidents in the project due to investigation errors, in addition to exempting the survey and design fees from the lost part, it shall also pay compensation equal to the part of the survey and design fee directly affected by the loss.
3. Since Party B's liability delays the provision of survey files for a period of more than ____ days, each time a delay is made, Party A shall pay Party A a penalty of ____% of the total price of the engineering survey fee.
Article 8 Dispute Resolution
In the event of a dispute arising from the execution of this contract, both parties shall promptly resolve the dispute. If the two parties belong to the same department and the mediation is not completed by the competent authorities at the higher level, or if they do not belong to the same department, they shall be resolved according to the following method: apply for arbitration by the ________ Arbitration Commission;
Article 9 Other Agreements
________________________________________________________________
This contract is valid after signing by both parties on ________________________________________________________________________________________________________________________________ If there are any outstanding matters in this contract, it is necessary to make a supplementary agreement through mutual consultation. The Supplementary Agreement is equally valid as this Agreement.
The original of this contract is in duplicate, one for each of Party A and Party B; one copy of the contract is ____ copies, and is sent to the Commission, Construction Committee, and CCB.
Construction unit:____________
Representative: ______________________
____year month day
Survey unit: ____________
Representative: ______________________
____year month day
recommended article
- Urban residential area owner management committee charter
- Room decoration commission
- Demonstration text of commercial housing contract
- Construction project demolition house contract
- Construction Engineering Design Contract (3)
- Engineering construction supervision commission
- Shanghai housing rental (commercial housing pre-leasing)
- Shanghai Housing Sublease Contract Sample
- Demonstration text of construction project contract (2)
- Qingdao Construction Project Construction Contract
- Construction engineering technical consulting contract
- Shanghai Participatory Housing Agreement
popular articles
- 2014 is very touching words
- Construction project entrusted supervision contract (Chinese and English)
- Tao Xingzhi's famous sayings
- Describe the fast time sentence 2019
- Temporary wall construction agreement
- a good saying that loves labor
- Bing Xin’s famous words
- Construction engineering survey contract
- English famous words
- Real estate mortgage loan contract
- Teacher's famous saying
- Qingdao Construction Project Construction Contract
- Taizai’s famous sayings
- Deaf people jingle 2019
- Ministry of Construction, State Administration for Industry and Commerce
- College entrance examination inspirational quotes
- Thanks to the friend's words 2019
- Team construction contract (construction team)
- Du Yuexi's famous sayings
- I want to say something to the teacher.
- Strong words
- Contract conditions for construction of water conservancy and hydropower civil engineering
- Korean swear words
- Construction project construction contract (general)
- Classical life motto
- Sad love sentence 2019
- Qq space mood phrase
- Construction project demolition house contract (official model
- Injured sentence
- The latest high school inspirational maxim