Construction engineering survey design contract
Principal: ____________________________________
Address: ____________ Postal Code: ____________ Telephone: ____________
Legal representative: ____________ Position: ____________
Contractor:____________________________________
Address: ____________ Postal Code: ____________ Telephone: ____________
Legal representative: ____________ Position: ____________
In accordance with the relevant provisions of the "Contract Law of the People's Republic of China", this contract was signed by both parties through consensus.
Article 1 The name, content, scale and scope of the engineering survey and design project entrusted by Party A to Party B are detailed in the list of commissioned survey and design projects.
Article 2 Party B shall proceed in stages according to the preliminary design and construction drawing design according to the entrusted survey and design project and the regulations of the competent department. When there are design conditions at each stage, the two parties sign a phase agreement, specifying the name and date of the survey design basic data that Party A should submit, and the name and date of the survey design file to be delivered by Party B as the subsidiary file of this contract. .
Article 3 Party A’s Responsibility
1. According to the provisions of the agreement of each design stage, provide Party B with relevant construction approval files and survey and design basic data, and be responsible for the time, schedule and reliability of the information provided.
Before commissioning surveying and mapping work, before the survey work is carried out, the technical requirements for surveying and mapping and the topographic map marked with the exact location of the proposed project shall be proposed, the plan of the measurement scope shall be delineated, the copy of the land use certificate shall be arranged, and the on-site working conditions shall be arranged.
The following information should be submitted for the preliminary design: 1 approved design task book; 2 site selection report; 3 planning requirements; 4 agreement files for raw materials, fuel, water, electricity, transportation, etc.; 5 approved process design materials, civil use The requirements for the use of the project; 6 survey data that can meet the preliminary design requirements, technical data obtained through scientific research, civil air defense, fire protection, labor protection, industrial hygiene, environmental protection prediction data, etc.
When commissioning the construction drawing design, the approved preliminary design files and the survey data, construction conditions, and technical information of the relevant equipment that meet the requirements of the construction drawing design shall be provided.
2. After receiving the design file delivered by Party B, it shall promptly report to the relevant department for review, and the review opinion shall be forwarded to Party B in writing. Organize the construction unit and the design unit to jointly agree on the relevant technical conditions, organize the design and technical disclosure, and notify Party B to participate in the test evaluation and completion acceptance.
3. When the survey and design personnel enter the on-site operation or cooperate with the construction, they shall be responsible for providing the necessary working and living conditions.
4. Entrusted to cooperate with the design tasks of the introduced projects, from the inquiry, foreign negotiations, domestic and foreign technical inspections to the completion of the production and production stages, should participate in the units responsible for the design tasks.
5. Maintenance of Party B's survey and design files shall not be modified without authorization and may not be transferred to third parties for reuse without the consent of Party B. Party B shall not be responsible for any technical responsibility for items that are reused after the transfer.
6. Pay the survey and design fees on time according to the relevant regulations of the State and this Municipality.
Article 4 Party B’s Responsibility
1. According to the construction project approval file and design basic data provided by Party A, prepare the design file, and deliver the design files of each stage on time according to the provisions of the agreement of each stage, and ensure the quality. Additional fees will be charged for the number of copies of the design file. Additional charges will apply if the supply standard drawing is to be copied.
2. Party B shall submit the survey technical requirements and design according to the approved design task book or the approval file of the previous stage design, as well as the relevant design technology agreement files, design standards, technical specifications, procedures, quotas, etc. Progress and quality propose design files.
3. After the preliminary design has been reviewed by the higher authorities, Party B shall be responsible for the necessary modifications within the scope of the original mission statement. When there is a major change in the original mission letter and the design needs to be re-designed, it must have a submission from the design approval authority or the design task approval authority.
4. Party B shall cooperate with the construction project under the design, and carry out the design and technical disclosure before the start of construction, solve the relevant design problems in the construction process, be responsible for the design change and revision budget, participate in the test evaluation and the completion acceptance of the project. For large and medium-sized industrial projects and complex civil projects, field design representatives should be sent and participate in concealed project acceptance.
5. For complex projects, when Party B needs to assist in collecting basic design materials, it should be handled in accordance with the relevant provisions of technical services.
6. The surveying unit shall conduct surveys of engineering surveying, engineering geology, hydrogeology, etc. in accordance with current standards, norms, regulations and technical regulations, and submit survey results according to the schedule and quality as stipulated in the contract.
Article 5 Survey and Design Costs
Party B shall collect the survey and design fees in accordance with the survey and design fee standards and methods approved by the State. After the design contract takes effect, Party A shall pay Party B a design fee of 30%; when Party B delivers the preliminary design file, Party A shall pay Party B the design fee; when the construction drawing design file is delivered, Party A shall be responsible for clearing all design fees. Small design projects and reuse design projects pay design fees twice. That is, when signing the design contract, 20% of the deposit is selected as the deposit, and the entire design fee is paid when the construction drawing is completed.
After the investigation contract takes effect, Party A shall pay Party B 30% of the survey fee. When Party B delivers the survey file, Party A shall be responsible for the settlement of all survey fees.
Article 6 Liability for breach of contract
1. Party A does not perform the contract and has no right to request a refund of the deposit. If Party B fails to perform the contract, Party B shall return the deposit twice.
2. Party A shall not provide the construction project approval file and design basic data on time, or influence Party B's design progress or design modification due to data reasons. Party B shall delay the delivery of the design file date, Party A shall, according to the actual loss date of Party B. Calculated by the daily output value of ________ yuan, supplemented by the design fee.
3. Party A requests to change the design for any reason. After Party B's consent, Party A shall, in addition to the delivery time of the design file, be reconciled, and Party A shall pay the design fee according to the actual rework date of Party B.
4. If Party A requests to stop the design for any reason, Party B shall promptly notify Party B in writing, Party B shall immediately stop the design, and the deposit paid by Party A shall not be repaid, and the deposit shall be insufficient for the design progress, and the fee shall be paid according to the actual progress of the completed design. .
5. If Party A requests the preliminary design file to be approved for more than half a year, the contract will be invalid by itself, and the deposit and design fee received by Party B will not be returned.
6. Due to the wrong survey and design of Party B, when Party A causes a large economic loss to Party A, Party B shall, in addition to being responsible for actively taking remedial measures, exempt the part of the survey and design fee from the loss, and pay Party A and the direct loss part of the survey and design fee. Equal compensation.
7. When the delivery time of the survey and design files is delayed according to the time specified in the agreement, Party A and Party B agree that Party A may pay less than 1% of the survey and design fee for this period, and Party A shall pay Party B the design fee for this stage in advance. of________%.
8. If Party A delays the delivery of survey and design fees, it shall pay the overdue liquidated damages, calculated on the basis of the accumulated number of days, and pays 1% of the penalty for the survey design fee every day, but the maximum amount of reimbursement per day shall not exceed 100 yuan.
9. If Party B fails to go to the site to deal with the design problem in time, if the design is not revised in time according to the opinions of the examination and approval authority, the design fee shall be reduced by 1% for each impact.
Article 7 In the process of execution of the contract, if there is a dispute, the two parties shall resolve the matter on the basis of seeking truth from facts, and the solution shall not be resolved on a case-by-case basis.
1. Apply to the ________ Arbitration Commission for arbitration.
2. Prosecute to the people's court.
Article 8 If the contract is not completed, the supplementary clause may be added to the contract by mutual agreement, and the supplementary clause is also an effective part of the contract.
Article 9 The commission survey and design project list and the survey design agreement of the sub-files of this contract are all part of this contract and have the same legal effect.
Article 10 This contract is in the form of ____ copies. The original two points, a copy of ____ copies. The competent departments of the business of Party A and Party B shall each hold one copy and the municipal infrastructure construction department shall have one copy.
Party A: ____________________________
representative of A:________________________
____year month day
Party B: ____________________________
Party B representative: ________________________
____year month day
Address: ____________ Postal Code: ____________ Telephone: ____________
Legal representative: ____________ Position: ____________
Contractor:____________________________________
Address: ____________ Postal Code: ____________ Telephone: ____________
Legal representative: ____________ Position: ____________
In accordance with the relevant provisions of the "Contract Law of the People's Republic of China", this contract was signed by both parties through consensus.
Article 1 The name, content, scale and scope of the engineering survey and design project entrusted by Party A to Party B are detailed in the list of commissioned survey and design projects.
Article 2 Party B shall proceed in stages according to the preliminary design and construction drawing design according to the entrusted survey and design project and the regulations of the competent department. When there are design conditions at each stage, the two parties sign a phase agreement, specifying the name and date of the survey design basic data that Party A should submit, and the name and date of the survey design file to be delivered by Party B as the subsidiary file of this contract. .
Article 3 Party A’s Responsibility
1. According to the provisions of the agreement of each design stage, provide Party B with relevant construction approval files and survey and design basic data, and be responsible for the time, schedule and reliability of the information provided.
Before commissioning surveying and mapping work, before the survey work is carried out, the technical requirements for surveying and mapping and the topographic map marked with the exact location of the proposed project shall be proposed, the plan of the measurement scope shall be delineated, the copy of the land use certificate shall be arranged, and the on-site working conditions shall be arranged.
The following information should be submitted for the preliminary design: 1 approved design task book; 2 site selection report; 3 planning requirements; 4 agreement files for raw materials, fuel, water, electricity, transportation, etc.; 5 approved process design materials, civil use The requirements for the use of the project; 6 survey data that can meet the preliminary design requirements, technical data obtained through scientific research, civil air defense, fire protection, labor protection, industrial hygiene, environmental protection prediction data, etc.
When commissioning the construction drawing design, the approved preliminary design files and the survey data, construction conditions, and technical information of the relevant equipment that meet the requirements of the construction drawing design shall be provided.
2. After receiving the design file delivered by Party B, it shall promptly report to the relevant department for review, and the review opinion shall be forwarded to Party B in writing. Organize the construction unit and the design unit to jointly agree on the relevant technical conditions, organize the design and technical disclosure, and notify Party B to participate in the test evaluation and completion acceptance.
3. When the survey and design personnel enter the on-site operation or cooperate with the construction, they shall be responsible for providing the necessary working and living conditions.
4. Entrusted to cooperate with the design tasks of the introduced projects, from the inquiry, foreign negotiations, domestic and foreign technical inspections to the completion of the production and production stages, should participate in the units responsible for the design tasks.
5. Maintenance of Party B's survey and design files shall not be modified without authorization and may not be transferred to third parties for reuse without the consent of Party B. Party B shall not be responsible for any technical responsibility for items that are reused after the transfer.
6. Pay the survey and design fees on time according to the relevant regulations of the State and this Municipality.
Article 4 Party B’s Responsibility
1. According to the construction project approval file and design basic data provided by Party A, prepare the design file, and deliver the design files of each stage on time according to the provisions of the agreement of each stage, and ensure the quality. Additional fees will be charged for the number of copies of the design file. Additional charges will apply if the supply standard drawing is to be copied.
2. Party B shall submit the survey technical requirements and design according to the approved design task book or the approval file of the previous stage design, as well as the relevant design technology agreement files, design standards, technical specifications, procedures, quotas, etc. Progress and quality propose design files.
3. After the preliminary design has been reviewed by the higher authorities, Party B shall be responsible for the necessary modifications within the scope of the original mission statement. When there is a major change in the original mission letter and the design needs to be re-designed, it must have a submission from the design approval authority or the design task approval authority.
4. Party B shall cooperate with the construction project under the design, and carry out the design and technical disclosure before the start of construction, solve the relevant design problems in the construction process, be responsible for the design change and revision budget, participate in the test evaluation and the completion acceptance of the project. For large and medium-sized industrial projects and complex civil projects, field design representatives should be sent and participate in concealed project acceptance.
5. For complex projects, when Party B needs to assist in collecting basic design materials, it should be handled in accordance with the relevant provisions of technical services.
6. The surveying unit shall conduct surveys of engineering surveying, engineering geology, hydrogeology, etc. in accordance with current standards, norms, regulations and technical regulations, and submit survey results according to the schedule and quality as stipulated in the contract.
Article 5 Survey and Design Costs
Party B shall collect the survey and design fees in accordance with the survey and design fee standards and methods approved by the State. After the design contract takes effect, Party A shall pay Party B a design fee of 30%; when Party B delivers the preliminary design file, Party A shall pay Party B the design fee; when the construction drawing design file is delivered, Party A shall be responsible for clearing all design fees. Small design projects and reuse design projects pay design fees twice. That is, when signing the design contract, 20% of the deposit is selected as the deposit, and the entire design fee is paid when the construction drawing is completed.
After the investigation contract takes effect, Party A shall pay Party B 30% of the survey fee. When Party B delivers the survey file, Party A shall be responsible for the settlement of all survey fees.
Article 6 Liability for breach of contract
1. Party A does not perform the contract and has no right to request a refund of the deposit. If Party B fails to perform the contract, Party B shall return the deposit twice.
2. Party A shall not provide the construction project approval file and design basic data on time, or influence Party B's design progress or design modification due to data reasons. Party B shall delay the delivery of the design file date, Party A shall, according to the actual loss date of Party B. Calculated by the daily output value of ________ yuan, supplemented by the design fee.
3. Party A requests to change the design for any reason. After Party B's consent, Party A shall, in addition to the delivery time of the design file, be reconciled, and Party A shall pay the design fee according to the actual rework date of Party B.
4. If Party A requests to stop the design for any reason, Party B shall promptly notify Party B in writing, Party B shall immediately stop the design, and the deposit paid by Party A shall not be repaid, and the deposit shall be insufficient for the design progress, and the fee shall be paid according to the actual progress of the completed design. .
5. If Party A requests the preliminary design file to be approved for more than half a year, the contract will be invalid by itself, and the deposit and design fee received by Party B will not be returned.
6. Due to the wrong survey and design of Party B, when Party A causes a large economic loss to Party A, Party B shall, in addition to being responsible for actively taking remedial measures, exempt the part of the survey and design fee from the loss, and pay Party A and the direct loss part of the survey and design fee. Equal compensation.
7. When the delivery time of the survey and design files is delayed according to the time specified in the agreement, Party A and Party B agree that Party A may pay less than 1% of the survey and design fee for this period, and Party A shall pay Party B the design fee for this stage in advance. of________%.
8. If Party A delays the delivery of survey and design fees, it shall pay the overdue liquidated damages, calculated on the basis of the accumulated number of days, and pays 1% of the penalty for the survey design fee every day, but the maximum amount of reimbursement per day shall not exceed 100 yuan.
9. If Party B fails to go to the site to deal with the design problem in time, if the design is not revised in time according to the opinions of the examination and approval authority, the design fee shall be reduced by 1% for each impact.
Article 7 In the process of execution of the contract, if there is a dispute, the two parties shall resolve the matter on the basis of seeking truth from facts, and the solution shall not be resolved on a case-by-case basis.
1. Apply to the ________ Arbitration Commission for arbitration.
2. Prosecute to the people's court.
Article 8 If the contract is not completed, the supplementary clause may be added to the contract by mutual agreement, and the supplementary clause is also an effective part of the contract.
Article 9 The commission survey and design project list and the survey design agreement of the sub-files of this contract are all part of this contract and have the same legal effect.
Article 10 This contract is in the form of ____ copies. The original two points, a copy of ____ copies. The competent departments of the business of Party A and Party B shall each hold one copy and the municipal infrastructure construction department shall have one copy.
Party A: ____________________________
representative of A:________________________
____year month day
Party B: ____________________________
Party B representative: ________________________
____year month day
recommended article
- Qingdao Construction Project Construction Contract
- Construction project demolition house contract
- Shanghai Housing Sublease Contract Sample
- Construction Engineering Design Contract (3)
- Urban residential area owner management committee charter
- Room decoration commission
- Demonstration text of construction project contract (2)
- Shanghai housing rental (commercial housing pre-leasing)
- Engineering construction supervision commission
- Shanghai Participatory Housing Agreement
- Construction engineering technical consulting contract
- Demonstration text of commercial housing contract
popular articles
- Classical life motto
- Temporary wall construction agreement
- Describe the fast time sentence 2019
- College entrance examination inspirational quotes
- Korean swear words
- Construction project entrusted supervision contract (Chinese and English)
- Team construction contract (construction team)
- Du Yuexi's famous sayings
- Real estate mortgage loan contract
- Ministry of Construction, State Administration for Industry and Commerce
- Teacher's famous saying
- Strong words
- Sad love sentence 2019
- Qingdao Construction Project Construction Contract
- Construction engineering survey contract
- Contract conditions for construction of water conservancy and hydropower civil engineering
- Thanks to the friend's words 2019
- English famous words
- Taizai’s famous sayings
- Qq space mood phrase
- 2014 is very touching words
- Injured sentence
- Tao Xingzhi's famous sayings
- I want to say something to the teacher.
- Construction project demolition house contract (official model
- The latest high school inspirational maxim
- Deaf people jingle 2019
- Construction project construction contract (general)
- Bing Xin’s famous words
- a good saying that loves labor