Subcontract for construction and installation engineering
General contractor: ____________________________
Address: ____________ Postal Code ____________ Telephone ____________
Legal representative: ____________ Position ____________
Subcontractor: ____________________________
Address: ____________ Postal Code ____________ Telephone ____________
Legal representative: ____________ Position ____________
In accordance with the "Contract Law of the People's Republic of China", the "Measures for the Implementation of the General Subcontracting of Construction and Installation Projects" of the Ministry of Construction and the relevant provisions of the XX XX Archives of the XX Municipal People's Government, this contract was signed by both parties and was strictly implemented.
Article 1 Project
First, the project name: ________________
Second, the project location: ________________
Third, the project number: _________ construction permit number: _______ business license number: _______
4. Subcontracted project scope and engineering quantity
V. The term of the subcontracted project starts on ________________________________________________________________________________________________________________________________________________________
6. The labor cost of the subcontracted project is ________ yuan.
7. Party B shall enter the type of work and the number of people ________.
Article 2 Project settlement
According to the subcontracted project, the first month's advance living expenses will be calculated according to the contracted person's ____ per person, and will be deducted at the next month's settlement. In the course of the construction, the acceptance of the qualified project quantity completed in the current month will be completed. Both parties shall pass the acceptance test and shall be settled.
Article 3 Project Quality
Party A shall carry out technical disclosure and organization acceptance according to the national quality acceptance specifications and assessment standards. Party B shall carefully organize the construction according to the requirements of construction drawings and specifications to ensure the quality of the project. If the quality is not up to standard, it must be reworked and repaired, and the loss of materials and materials shall be borne by Party B. If the quality of the project is inferior and cannot be saved, Party B shall be responsible for compensating for the loss of all materials.
Article 4 Safety Production
1. Party A shall make a safe disclosure of the project undertaken by Party B, put forward clear safety requirements, and conduct supervision and inspection. Party B must conscientiously implement the rules and regulations concerning safety construction, strictly abide by the safe operation procedures, and provide safe production facilities to Party A. Party B can only use it after passing the inspection. If there is any casualty accident during the construction due to violation of the above regulations, Party B shall be responsible for the loss.
2. Labor protection articles and live operating devices used by individuals, such as insulating gloves and rubber boots, shall be resolved by Party B themselves. If Party B does have difficulties, it may propose a plan to be used and Party A shall assist in the settlement.
3. In the course of construction, Party B shall be responsible for the fire accident caused by Party B's violation of fire regulations and regulations.
Article 5 Life Management
1. After Party B's workers enter the scene, the accommodation and accommodation problems provided by Party A and the main cooking utensils shall be kept by Party B. If there is damage, the compensation will be compensated. The small scattered appliances are provided by Party B, and the domestic coal is provided by Party A in a quantitative amount.
2. The food and oil used for daily life shall be taken care of by Party B. Party A shall provide convenience in medical and health care. If Party B's workers have illness, they may seek medical treatment from Party A with the approval of their responsible person. The medical expenses shall be paid by Party B. Responsible for paying monthly.
Article 6 Unit price of subcontracted labor costs
1. Subcontracting of unit projects, ________ yuan per budget day. The implementation of unilateral square meters labor costs, ____ yuan per square meter.
Second, the internal plastering and subcontracting, to achieve a high quality budget day of ________ yuan. ________ yuan per eligible budget day. A separate labor cost is applied for ________ yuan per square meter.
3. Each budgeted work day for individual subcontracted stone and earthwork is ________ yuan.
4. Every day of the work is ________ yuan.
5. All-day suspension, waiting for materials, water stoppage, power outage, and clearing work days are ________ yuan.
6. Water, electricity, heating, and sanitation projects, ________ yuan per budget day.
7. The working day of reducing the work efficiency by 10% during the winter construction period. The unit price of the workday is ________ yuan.
Eight, subcontracted project cost schedule
Article 7 Material Supply Management
Party B shall set up a special person to handle the limit collection procedures for cement, steel, commodity components, hardware, linoleum, asphalt and special materials for water, electricity, heating and sanitation. Party B shall strictly follow the quality requirements and materials provided by Party A for construction. Party B shall bear the waste of materials used in the construction of Party B and the unreasonable excess of the quota. Party B shall use the materials according to the 施工 during the construction, so that the daily use will be cleared, the materials will be cleaned, and the site will be kept clean.
Article 8 Construction Machinery
First, the large-scale tools are the responsibility of Party A to ensure the use of the need.
Second, the manual operation tool is responsible for Party B.
3. Party B shall take care of the equipment that Party A is responsible for, and Party B shall be responsible for compensation if there is any loss.
4. The medium and small-sized machinery required for construction shall be equipped by Party A according to the construction plan. One machine shall be equipped with a driver to ensure the normal construction of Party B. Party B is not allowed to operate the equipment without authorization.
Article 9 Site Management
1. Personnel of Party A and Party B shall strictly abide by the various management systems on the site and organize the construction under the unified leadership of the person in charge of Party A. The parties involved in the planning, progress, and material supply shall cooperate closely to ensure smooth construction.
2. Party B shall educate construction personnel on compliance with laws and regulations, safety production and property protection, and designate special personnel to be responsible for on-site security work. It is strictly forbidden to steal on-site materials. If there is any illegal behavior in violation of the on-site management system, Party A has the right to take necessary Party B shall bear legal responsibility and be responsible for compensation for economic losses.
Third, the subcontractors should be relatively stable, wear work signs when entering and leaving the construction site, and not allow people outside the contract to enter and leave the site and accommodation.
Article 10 Liability for breach of contract
1. Projects subcontracted by Party B shall not be subcontracted. In the course of construction, the inspection fails to meet the national acceptance specification, and the quality of the project cannot be guaranteed. Party A has the right to terminate the contract and cause losses of rework, and Party B shall compensate.
2. After the contract is signed, neither party may arbitrarily change or cancel it without the consent of both parties. If Party B fails to cancel the contract unilaterally without Party A's consent, Party B shall compensate Party A for the economic losses caused by Party A's impact on the construction plan; if Party A cancels the contract midway, it shall compensate Party B for the economic losses caused thereby.
3. Party B must complete the construction period and quality requirements as stipulated in the contract. Otherwise, each time after the overdue period, Party A shall reimburse Party A for overdue liquidated damages according to the labor cost of the subcontracted project.
4. Party A and Party B shall not owe all kinds of payables for any reason, such as defaulting on non-payment, and repaying the default payment of overdue payment according to the bank's short-term loan interest rate.
Article 11 Supplementary Provisions
1. In the event of a dispute arising from this contract, both parties shall consult in a timely manner and the negotiation will not be completed. If it cannot be solved, it can be solved as follows: Apply to the Economic Contract Arbitration Committee of the building where the building is located for arbitration and bring a suit in the people's court.
2. This contract is a __ share, and both parties are responsible for one copy. The remaining copies are submitted to ____ for filing.
3. For those who require forensic examination, they may go to the district or county administration for industry and commerce at the location where the building is located for notarization or notarization.
4. Other terms agreed by the parties:
1.
2.
Article 12 Contract Attachment File and Validity Period
1. Contract Attachment File:
1. Project budget book;
2.
2. This contract shall become effective from the date of the seal of both parties, and shall expire after the completion of the project and settlement.
Total package unit: ________________________
Legal representative: ______________________
____year month day
Subcontracting unit: ________________________
Legal representative: ______________________
____year month day
Address: ____________ Postal Code ____________ Telephone ____________
Legal representative: ____________ Position ____________
Subcontractor: ____________________________
Address: ____________ Postal Code ____________ Telephone ____________
Legal representative: ____________ Position ____________
In accordance with the "Contract Law of the People's Republic of China", the "Measures for the Implementation of the General Subcontracting of Construction and Installation Projects" of the Ministry of Construction and the relevant provisions of the XX XX Archives of the XX Municipal People's Government, this contract was signed by both parties and was strictly implemented.
Article 1 Project
First, the project name: ________________
Second, the project location: ________________
Third, the project number: _________ construction permit number: _______ business license number: _______
4. Subcontracted project scope and engineering quantity
V. The term of the subcontracted project starts on ________________________________________________________________________________________________________________________________________________________
6. The labor cost of the subcontracted project is ________ yuan.
7. Party B shall enter the type of work and the number of people ________.
Article 2 Project settlement
According to the subcontracted project, the first month's advance living expenses will be calculated according to the contracted person's ____ per person, and will be deducted at the next month's settlement. In the course of the construction, the acceptance of the qualified project quantity completed in the current month will be completed. Both parties shall pass the acceptance test and shall be settled.
Article 3 Project Quality
Party A shall carry out technical disclosure and organization acceptance according to the national quality acceptance specifications and assessment standards. Party B shall carefully organize the construction according to the requirements of construction drawings and specifications to ensure the quality of the project. If the quality is not up to standard, it must be reworked and repaired, and the loss of materials and materials shall be borne by Party B. If the quality of the project is inferior and cannot be saved, Party B shall be responsible for compensating for the loss of all materials.
Article 4 Safety Production
1. Party A shall make a safe disclosure of the project undertaken by Party B, put forward clear safety requirements, and conduct supervision and inspection. Party B must conscientiously implement the rules and regulations concerning safety construction, strictly abide by the safe operation procedures, and provide safe production facilities to Party A. Party B can only use it after passing the inspection. If there is any casualty accident during the construction due to violation of the above regulations, Party B shall be responsible for the loss.
2. Labor protection articles and live operating devices used by individuals, such as insulating gloves and rubber boots, shall be resolved by Party B themselves. If Party B does have difficulties, it may propose a plan to be used and Party A shall assist in the settlement.
3. In the course of construction, Party B shall be responsible for the fire accident caused by Party B's violation of fire regulations and regulations.
Article 5 Life Management
1. After Party B's workers enter the scene, the accommodation and accommodation problems provided by Party A and the main cooking utensils shall be kept by Party B. If there is damage, the compensation will be compensated. The small scattered appliances are provided by Party B, and the domestic coal is provided by Party A in a quantitative amount.
2. The food and oil used for daily life shall be taken care of by Party B. Party A shall provide convenience in medical and health care. If Party B's workers have illness, they may seek medical treatment from Party A with the approval of their responsible person. The medical expenses shall be paid by Party B. Responsible for paying monthly.
Article 6 Unit price of subcontracted labor costs
1. Subcontracting of unit projects, ________ yuan per budget day. The implementation of unilateral square meters labor costs, ____ yuan per square meter.
Second, the internal plastering and subcontracting, to achieve a high quality budget day of ________ yuan. ________ yuan per eligible budget day. A separate labor cost is applied for ________ yuan per square meter.
3. Each budgeted work day for individual subcontracted stone and earthwork is ________ yuan.
4. Every day of the work is ________ yuan.
5. All-day suspension, waiting for materials, water stoppage, power outage, and clearing work days are ________ yuan.
6. Water, electricity, heating, and sanitation projects, ________ yuan per budget day.
7. The working day of reducing the work efficiency by 10% during the winter construction period. The unit price of the workday is ________ yuan.
Eight, subcontracted project cost schedule
Article 7 Material Supply Management
Party B shall set up a special person to handle the limit collection procedures for cement, steel, commodity components, hardware, linoleum, asphalt and special materials for water, electricity, heating and sanitation. Party B shall strictly follow the quality requirements and materials provided by Party A for construction. Party B shall bear the waste of materials used in the construction of Party B and the unreasonable excess of the quota. Party B shall use the materials according to the 施工 during the construction, so that the daily use will be cleared, the materials will be cleaned, and the site will be kept clean.
Article 8 Construction Machinery
First, the large-scale tools are the responsibility of Party A to ensure the use of the need.
Second, the manual operation tool is responsible for Party B.
3. Party B shall take care of the equipment that Party A is responsible for, and Party B shall be responsible for compensation if there is any loss.
4. The medium and small-sized machinery required for construction shall be equipped by Party A according to the construction plan. One machine shall be equipped with a driver to ensure the normal construction of Party B. Party B is not allowed to operate the equipment without authorization.
Article 9 Site Management
1. Personnel of Party A and Party B shall strictly abide by the various management systems on the site and organize the construction under the unified leadership of the person in charge of Party A. The parties involved in the planning, progress, and material supply shall cooperate closely to ensure smooth construction.
2. Party B shall educate construction personnel on compliance with laws and regulations, safety production and property protection, and designate special personnel to be responsible for on-site security work. It is strictly forbidden to steal on-site materials. If there is any illegal behavior in violation of the on-site management system, Party A has the right to take necessary Party B shall bear legal responsibility and be responsible for compensation for economic losses.
Third, the subcontractors should be relatively stable, wear work signs when entering and leaving the construction site, and not allow people outside the contract to enter and leave the site and accommodation.
Article 10 Liability for breach of contract
1. Projects subcontracted by Party B shall not be subcontracted. In the course of construction, the inspection fails to meet the national acceptance specification, and the quality of the project cannot be guaranteed. Party A has the right to terminate the contract and cause losses of rework, and Party B shall compensate.
2. After the contract is signed, neither party may arbitrarily change or cancel it without the consent of both parties. If Party B fails to cancel the contract unilaterally without Party A's consent, Party B shall compensate Party A for the economic losses caused by Party A's impact on the construction plan; if Party A cancels the contract midway, it shall compensate Party B for the economic losses caused thereby.
3. Party B must complete the construction period and quality requirements as stipulated in the contract. Otherwise, each time after the overdue period, Party A shall reimburse Party A for overdue liquidated damages according to the labor cost of the subcontracted project.
4. Party A and Party B shall not owe all kinds of payables for any reason, such as defaulting on non-payment, and repaying the default payment of overdue payment according to the bank's short-term loan interest rate.
Article 11 Supplementary Provisions
1. In the event of a dispute arising from this contract, both parties shall consult in a timely manner and the negotiation will not be completed. If it cannot be solved, it can be solved as follows: Apply to the Economic Contract Arbitration Committee of the building where the building is located for arbitration and bring a suit in the people's court.
2. This contract is a __ share, and both parties are responsible for one copy. The remaining copies are submitted to ____ for filing.
3. For those who require forensic examination, they may go to the district or county administration for industry and commerce at the location where the building is located for notarization or notarization.
4. Other terms agreed by the parties:
1.
2.
Article 12 Contract Attachment File and Validity Period
1. Contract Attachment File:
1. Project budget book;
2.
2. This contract shall become effective from the date of the seal of both parties, and shall expire after the completion of the project and settlement.
Total package unit: ________________________
Legal representative: ______________________
____year month day
Subcontracting unit: ________________________
Legal representative: ______________________
____year month day
recommended article
- Shanghai housing rental (commercial housing pre-leasing)
- Construction engineering technical consulting contract
- Room decoration commission
- Demonstration text of commercial housing contract
- Engineering construction supervision commission
- Construction project demolition house contract
- Qingdao Construction Project Construction Contract
- Shanghai Housing Sublease Contract Sample
- Construction Engineering Design Contract (3)
- Shanghai Participatory Housing Agreement
- Demonstration text of construction project contract (2)
- Urban residential area owner management committee charter
popular articles
- Ministry of Construction, State Administration for Industry and Commerce
- College entrance examination inspirational quotes
- a good saying that loves labor
- Deaf people jingle 2019
- Strong words
- 2014 is very touching words
- Injured sentence
- Du Yuexi's famous sayings
- Korean swear words
- The latest high school inspirational maxim
- Describe the fast time sentence 2019
- Sad love sentence 2019
- Teacher's famous saying
- Bing Xin’s famous words
- Real estate mortgage loan contract
- Qq space mood phrase
- Tao Xingzhi's famous sayings
- Construction engineering survey contract
- I want to say something to the teacher.
- Classical life motto
- Contract conditions for construction of water conservancy and hydropower civil engineering
- Thanks to the friend's words 2019
- English famous words
- Construction project demolition house contract (official model
- Team construction contract (construction team)
- Taizai’s famous sayings
- Construction project entrusted supervision contract (Chinese and English)
- Temporary wall construction agreement
- Construction project construction contract (general)
- Qingdao Construction Project Construction Contract