Construction and installation engineering design contract
project name:
Requester:
Design unit:
Design number:
Contract number:
____Year _____________
Construction and installation engineering design contract
Enter into the contract:
Construction unit: __________________, hereinafter referred to as Party A;
Design unit: __________________, hereinafter referred to as Party B.
In order to clarify responsibilities, work together and work together to complete the design tasks of national construction projects, according to the provisions of the Regulations on Construction Engineering Survey and Design Contracts and the plan of work tasks approved by ________, this contract is signed by Party A and Party B, obey together.
First, the project name, scale, investment amount, construction site
Party A entrusts Party B to undertake the design project of _____ project, the construction and installation area is ______ square meters, the approved total investment is ____10,000 yuan, and the construction site is _________
Second, Party A’s obligations
1. Party A shall submit to Party B the design task book approved by the superior, the site selection report, and the raw materials, fuel, water, electricity, transportation, etc. before ________________ The archives of the agreement and the survey data that meet the preliminary design requirements require technical data obtained through scientific research. Party A shall provide approved preliminary design files and survey data that meet the design requirements of the construction drawings, construction conditions, and equipment related technologies prior to the construction of the construction drawings in ________________________ data. Party A must guarantee the quality of the above information and must not change it at will.
2, timely handling the design file approval work at each design stage.
3. Before the commencement of the project, Party A shall organize the relevant construction unit to carry out the design and technical disclosure with Party B; after the project is completed, Party A shall notify Party B to participate in the completion acceptance.
4. When the designer enters the construction site for work, Party A shall provide the necessary working conditions and facilitate it in life. In the design and construction process, due to the technical special needs of the trial production test, all costs and the travel expenses for the cooperation of Party A to the outside world shall be the responsibility of Party A.
5. Party A must maintain Party B's design files and may not modify them without permission; Party A shall not copy, reuse or arbitrarily expand the scope of construction without the consent of Party B. Party A is obliged to protect Party B's design copyright and may not transfer it to a third party for reuse.
Third, Party B’s obligations
1. Party B must deliver the preliminary design file to Party A before the ____________ date of ________; deliver to Party A before ________________ Technical design file; before the ________________ date, the construction drawing design file will be delivered to Party A. Among them, the preliminary design file is ______ copies, the technical design file is ____ copies, and the construction drawing design file is ____ copies. Party A needs to add additional file scores and model fees, and will be charged separately. Before the ________________ date, Party B must submit all design files to Party A.
For large-scale construction and installation projects, both parties can design in stages according to specific conditions. When design conditions are met, the two parties sign a phase design contract, specifying the name and date of the design information submitted by Party A, and the date on which Party B delivers the design file. The attached files of this contract are detailed in the attached file. )
2. Party B must submit the survey technical requirements and design according to the approved design task book or the approval file of the previous stage design, as well as the design technical standards, design standards, technical specifications, procedures, quotas, etc., and submit the quality-compliant design. file.
3. After the preliminary design has been reviewed by the higher authorities, Party B shall be responsible for the necessary modifications within the scope of the original mission statement.
4. The design unit shall cooperate with the construction unit to carry out the pre-construction technical disclosure of the construction project undertaken by the construction unit, solve the relevant design problems during the construction, be responsible for the design change and revision budget, and participate in the concealed project acceptance and project completion acceptance.
Fourth, the design modification and stop
1. Party A requires the modification of the design of the project for any reason. With the consent of Party B, Party A shall, in addition to the delivery time of the design file, be revised according to the actual rework date of Party B, and increase the design fee by ____ yuan per working day. Or based on the percentage of work rework in the design phase.
2. If the original task book is reworked or modified if there is a major change, it must have a submission from the design approval authority or the design task approval authority. The payment of the design cost that has already been carried out is calculated according to the preceding article.
3. If Party A requests to stop design in the middle of the reason, Party B shall promptly notify Party B in writing that the designed design fee has not been refunded, and the design fee is increased and paid according to the actual labor day at that stage, and the contractual relationship is terminated.
V. Number of design fees and delivery methods
Within ____ days after the design contract is effective, Party A shall deliver a deposit equivalent to 20% of the design fee to Party B. After the design contract is fulfilled, the deposit shall be used as the design fee; Party B shall submit the preliminary design plan to Party A. Within a day, Party A shall pay Party B a design fee of ____%; Party B shall, within ____ days after Party A submits the construction drawing file, Party A shall settle all design fees to Party B.
Sixth, reward and breach of contract liability
1. Within the reasonable project investment control number, since Party B uses advanced technology or reasonable suggestions to save engineering investment, it can withdraw __% from Party B to save the investment amount.
2. Since Party A cannot provide relevant design information on time and accurately, Party B cannot design or cause design rework. In addition to the date of delivery of the design file, Party B shall also be subject to Party B’s actual loss of working days. ____ yuan calculates the incremental design fee.
3. Party A shall not pay the deposit and design fee to Party B in accordance with the time stipulated in the contract, and shall pay Party B the liquidated damages according to the bank's provisions on deferred payment.
4. Due to Party B's reasons, delay in the delivery of the design file, Party B shall pay Party A a penalty of ____% of the design fee for every ____ days of delay.
5. Due to the poor quality of the design of Party B, it is necessary for Party B to continue to improve the design tasks, and to reduce the amount of waste caused by the loss or the design fee. For those who have caused major quality accidents due to design errors of Party B, Party B shall not only pay the design fee for the loss part, but also pay compensation equal to the design fee directly affected by the loss.
Seven, other
_____________________________________________________________________________________________________________.
This contract shall become effective after the signature of both parties on the date of ____________________________________________________________________________________________________________________ If there are any outstanding matters in this contract, it is necessary to make a supplementary agreement through mutual consultation. The Supplementary Agreement shall have the same effect as this Agreement, but shall not be inconsistent with the contents of this Agreement.
In the event of a dispute arising from the execution of the contract, both parties shall resolve it in a timely manner. If the two parties belong to the same department and the mediation is not completed by the competent authorities at the higher level, or if they do not belong to the same department, they may apply to the contract management agency prescribed by the state for arbitration, or they may directly file a lawsuit with the people's court.
The original of this contract is in duplicate, one for each of Party A and Party B; one copy of the contract is ___, and is sent to the Commission, Construction Committee, CCB, etc.
Construction unit: Design unit:
Representative: Representative:
Contact: Contact:
Communications Office: Communications Office:
Telephone or telegraph: Telephone or telegraph:
Bank of deposit: Bank of deposit:
Account number: Account number:
____________________
Requester:
Design unit:
Design number:
Contract number:
____Year _____________
Construction and installation engineering design contract
Enter into the contract:
Construction unit: __________________, hereinafter referred to as Party A;
Design unit: __________________, hereinafter referred to as Party B.
In order to clarify responsibilities, work together and work together to complete the design tasks of national construction projects, according to the provisions of the Regulations on Construction Engineering Survey and Design Contracts and the plan of work tasks approved by ________, this contract is signed by Party A and Party B, obey together.
First, the project name, scale, investment amount, construction site
Party A entrusts Party B to undertake the design project of _____ project, the construction and installation area is ______ square meters, the approved total investment is ____10,000 yuan, and the construction site is _________
Second, Party A’s obligations
1. Party A shall submit to Party B the design task book approved by the superior, the site selection report, and the raw materials, fuel, water, electricity, transportation, etc. before ________________ The archives of the agreement and the survey data that meet the preliminary design requirements require technical data obtained through scientific research. Party A shall provide approved preliminary design files and survey data that meet the design requirements of the construction drawings, construction conditions, and equipment related technologies prior to the construction of the construction drawings in ________________________ data. Party A must guarantee the quality of the above information and must not change it at will.
2, timely handling the design file approval work at each design stage.
3. Before the commencement of the project, Party A shall organize the relevant construction unit to carry out the design and technical disclosure with Party B; after the project is completed, Party A shall notify Party B to participate in the completion acceptance.
4. When the designer enters the construction site for work, Party A shall provide the necessary working conditions and facilitate it in life. In the design and construction process, due to the technical special needs of the trial production test, all costs and the travel expenses for the cooperation of Party A to the outside world shall be the responsibility of Party A.
5. Party A must maintain Party B's design files and may not modify them without permission; Party A shall not copy, reuse or arbitrarily expand the scope of construction without the consent of Party B. Party A is obliged to protect Party B's design copyright and may not transfer it to a third party for reuse.
Third, Party B’s obligations
1. Party B must deliver the preliminary design file to Party A before the ____________ date of ________; deliver to Party A before ________________ Technical design file; before the ________________ date, the construction drawing design file will be delivered to Party A. Among them, the preliminary design file is ______ copies, the technical design file is ____ copies, and the construction drawing design file is ____ copies. Party A needs to add additional file scores and model fees, and will be charged separately. Before the ________________ date, Party B must submit all design files to Party A.
For large-scale construction and installation projects, both parties can design in stages according to specific conditions. When design conditions are met, the two parties sign a phase design contract, specifying the name and date of the design information submitted by Party A, and the date on which Party B delivers the design file. The attached files of this contract are detailed in the attached file. )
2. Party B must submit the survey technical requirements and design according to the approved design task book or the approval file of the previous stage design, as well as the design technical standards, design standards, technical specifications, procedures, quotas, etc., and submit the quality-compliant design. file.
3. After the preliminary design has been reviewed by the higher authorities, Party B shall be responsible for the necessary modifications within the scope of the original mission statement.
4. The design unit shall cooperate with the construction unit to carry out the pre-construction technical disclosure of the construction project undertaken by the construction unit, solve the relevant design problems during the construction, be responsible for the design change and revision budget, and participate in the concealed project acceptance and project completion acceptance.
Fourth, the design modification and stop
1. Party A requires the modification of the design of the project for any reason. With the consent of Party B, Party A shall, in addition to the delivery time of the design file, be revised according to the actual rework date of Party B, and increase the design fee by ____ yuan per working day. Or based on the percentage of work rework in the design phase.
2. If the original task book is reworked or modified if there is a major change, it must have a submission from the design approval authority or the design task approval authority. The payment of the design cost that has already been carried out is calculated according to the preceding article.
3. If Party A requests to stop design in the middle of the reason, Party B shall promptly notify Party B in writing that the designed design fee has not been refunded, and the design fee is increased and paid according to the actual labor day at that stage, and the contractual relationship is terminated.
V. Number of design fees and delivery methods
Within ____ days after the design contract is effective, Party A shall deliver a deposit equivalent to 20% of the design fee to Party B. After the design contract is fulfilled, the deposit shall be used as the design fee; Party B shall submit the preliminary design plan to Party A. Within a day, Party A shall pay Party B a design fee of ____%; Party B shall, within ____ days after Party A submits the construction drawing file, Party A shall settle all design fees to Party B.
Sixth, reward and breach of contract liability
1. Within the reasonable project investment control number, since Party B uses advanced technology or reasonable suggestions to save engineering investment, it can withdraw __% from Party B to save the investment amount.
2. Since Party A cannot provide relevant design information on time and accurately, Party B cannot design or cause design rework. In addition to the date of delivery of the design file, Party B shall also be subject to Party B’s actual loss of working days. ____ yuan calculates the incremental design fee.
3. Party A shall not pay the deposit and design fee to Party B in accordance with the time stipulated in the contract, and shall pay Party B the liquidated damages according to the bank's provisions on deferred payment.
4. Due to Party B's reasons, delay in the delivery of the design file, Party B shall pay Party A a penalty of ____% of the design fee for every ____ days of delay.
5. Due to the poor quality of the design of Party B, it is necessary for Party B to continue to improve the design tasks, and to reduce the amount of waste caused by the loss or the design fee. For those who have caused major quality accidents due to design errors of Party B, Party B shall not only pay the design fee for the loss part, but also pay compensation equal to the design fee directly affected by the loss.
Seven, other
_____________________________________________________________________________________________________________.
This contract shall become effective after the signature of both parties on the date of ____________________________________________________________________________________________________________________ If there are any outstanding matters in this contract, it is necessary to make a supplementary agreement through mutual consultation. The Supplementary Agreement shall have the same effect as this Agreement, but shall not be inconsistent with the contents of this Agreement.
In the event of a dispute arising from the execution of the contract, both parties shall resolve it in a timely manner. If the two parties belong to the same department and the mediation is not completed by the competent authorities at the higher level, or if they do not belong to the same department, they may apply to the contract management agency prescribed by the state for arbitration, or they may directly file a lawsuit with the people's court.
The original of this contract is in duplicate, one for each of Party A and Party B; one copy of the contract is ___, and is sent to the Commission, Construction Committee, CCB, etc.
Construction unit: Design unit:
Representative: Representative:
Contact: Contact:
Communications Office: Communications Office:
Telephone or telegraph: Telephone or telegraph:
Bank of deposit: Bank of deposit:
Account number: Account number:
____________________
recommended article
- Construction Engineering Design Contract (3)
- Qingdao Construction Project Construction Contract
- Construction engineering technical consulting contract
- Room decoration commission
- Shanghai Housing Sublease Contract Sample
- Demonstration text of commercial housing contract
- Shanghai housing rental (commercial housing pre-leasing)
- Urban residential area owner management committee charter
- Demonstration text of construction project contract (2)
- Shanghai Participatory Housing Agreement
- Engineering construction supervision commission
- Construction project demolition house contract
popular articles
- Contract conditions for construction of water conservancy and hydropower civil engineering
- Strong words
- Classical life motto
- Deaf people jingle 2019
- Teacher's famous saying
- Sad love sentence 2019
- 2014 is very touching words
- Du Yuexi's famous sayings
- The latest high school inspirational maxim
- I want to say something to the teacher.
- Describe the fast time sentence 2019
- Real estate mortgage loan contract
- Construction project construction contract (general)
- Qingdao Construction Project Construction Contract
- Tao Xingzhi's famous sayings
- Bing Xin’s famous words
- Construction project demolition house contract (official model
- Korean swear words
- a good saying that loves labor
- Taizai’s famous sayings
- Injured sentence
- Thanks to the friend's words 2019
- College entrance examination inspirational quotes
- Qq space mood phrase
- Construction engineering survey contract
- Construction project entrusted supervision contract (Chinese and English)
- Ministry of Construction, State Administration for Industry and Commerce
- Team construction contract (construction team)
- English famous words
- Temporary wall construction agreement