Architectural design contract

Project Name: Industrial Plant Engineering

Project Location: City

Contract No.: XX-Bead-011

Design certificate level:

Contractor:

designer:

Date of signing: Year, month and day

Ministry of Construction

Producer

State Administration for Industry and Commerce

Contractor:

designer:

The contractor entrusts the designer to undertake _ industrial plant engineering design, and the contract is signed by both parties.

Article 1 This contract is signed in accordance with the following files:

1.1 "Contract Law of the People's Republic of China", "Building Law of the People's Republic of China", "Regulations on the Management of Construction Engineering Survey and Design Market"

1.2 National and local regulations and regulations on construction engineering survey and design management.

1.3 Construction project approval file.

Article 2 The contents of this contract design project: name, scale, stage, investment and design fee are shown in the table below.

Serial number

Sub-project name

Construction scale

Design stage and content

Estimated total investment

fee

rate

%

design fee

Number of layers

construction area

Program

initial design

Construction drawing

1

Factory building

2

8500

√

√

0000.00 dry

2

General plan engineering

Note: The specific design scope is subject to the “General Contractual Contract” signed by the contractor and the owner.

Article 3 The relevant information and files submitted by the contractor to the designer:

Serial number information and file name

Number of copies

Date of submission

Related matters

1

Project approval document

1

2

Construction land planning permit

1

3

Construction land red line map

1

4

Design points provided by the planning department

1

5

Design power of attorney and design requirements

1

6

Engineering geological survey report

1

Article 4 Design materials and files that the designer shall deliver to the contractor:

Serial number information and file name

Number of copies

Date of submission

Related matters

1

Architectural design and master plan

3

7 days after the owner confirms

2

Architectural design complete construction drawing

8

20 days after the approval of the plan

3

General drawing construction drawing

8

15 days after approval of construction drawings

Article 5 The design fee for this contract is RMB 10,000. The progress of the design fee payment is detailed in the table below.

The payment order accounts for the total design fee

%

Paid amount

Paid time

First payment

20% deposit

Within three days after the signing of this contract

Second payment

75%

Five days after the completion of the complete set of construction drawings

Third payment

5%

The total construction drawing is within five days after the drawing

Description:

1. Pay the design fee for each stage while submitting the design files for each stage.

2. Set all the design fees at the same time as submitting the last part of the construction drawing, leaving no last payment.

3. The actual design fee is approved according to the preliminary design budget estimate. When there is a difference between the actual design fee and the estimated design fee, the two parties will sign a supplementary agreement.

4. After the performance of this contract, the deposit will be used as a design fee.

Article 6: Liability of both parties

6.1 Responsibility of the contractor:

6.1.1 The Employer shall submit the materials and files to the designer within the prescribed time and in accordance with the provisions of Article 3 of this contract, and shall be responsible for the completeness, correctness and time limit of the contract. The contractor shall not require the consignor to violate the relevant state. Standard design.

If the contractor submits the above-mentioned materials and files within 15 days of the specified time limit, the designer shall delay the delivery of the design files in accordance with the provisions of Article 4 of the contract; when the specified period is more than 15 days, the designer has the right to re-determine the time for submitting the design files.

6.1.2 If the contractor changes the entrusted design project, the scale, the conditions, or the information submitted is incorrect, or the submitted materials are greatly modified, resulting in the design of the designer to rework, the two parties need to negotiate additional supplementary agreements and re-clarify the relevant In addition to the terms, the contractor shall pay the design fee to the designer according to the workload of the designer.

Before the contract is signed, the contractor has agreed that the design work done by the designer for the contractor should be paid according to the charging standard.

6.1.3 If the designer asks the designer to deliver the design materials and files earlier than the contract time, if the designer can do so, the contractor should pay the designer the labor cost according to the workload that the designer has invested in advance.

6.1.4 The contractor shall provide the necessary staff to work on the design issues and provide necessary working and living conditions and transportation.

6.1.5 The contractor shall protect the designer's tender, design plan, file, data drawing, data, computing software and patented technology. Without the consent of the designer, the design information and files delivered by the Employer to the designer shall not be modified, copied or transferred to a third party or used for projects outside this contract. If any of the above occurs, the Employer shall be legally responsible and design. The person has the right to file a claim with the contractor.

6.2 Designer responsibility:

6.2.1 The designer shall carry out the engineering design according to the national technical specifications, standards, regulations and the design requirements put forward by the contractor, and submit the quality qualified design materials according to the progress requirements stipulated in the contract and be responsible for them.

6.2.2 The main technical standards adopted by the designer are: the current national design codes and standards related to the project.

6.2.3 The reasonable use period of the design is 50 years.

6.2.4 The designer shall deliver the materials and files to the Employer in accordance with the content, progress and number of copies specified in Articles 2 and 4 of this contract.

6.2.5 After the designer delivers the design materials and files, he shall participate in the relevant design review as required, and shall be responsible for making necessary adjustments and additions to the contents not exceeding the original scope according to the review conclusions. The designer delivers the design materials and files according to the time limit specified in the contract. The project begins construction during the year and is responsible for the design of the contractor and the construction unit, handling the design issues and participating in the completion acceptance. If the project has not started construction within one year, the designer is still responsible for the above work, but the consulting service fee should be appropriately charged to the contractor according to the required workload. The amount of the fee is determined by both parties.

6.2.6 The designer shall protect the intellectual property rights of the contractor and shall not disclose or transfer the technical and economic data such as the product drawings submitted by the contractor to the third party. If the above situation occurs and economic losses are caused to the contractor, the contractor has the right to claim against the designer.

Article 7: Liability for breach of contract:

7.1 During the performance of the contract, the contractor requests to terminate or cancel the contract. If the designer has not started the design work, the deposit paid by the contractor shall not be refunded; if the design work has begun, the contractor shall, according to the actual workload that the designer has carried out, In less than half, half of the design fee for this phase will be paid; if more than half of the total, the design fee for the phase will be paid.

7.2 The Employer shall pay the design fee to the designer in accordance with the amount and time specified in Article 5 of this contract. For each day overdue, it shall bear the overdue liquidated damages of two-thousandths of the amount. When the deadline is more than 30 days, the designer has the right to suspend the next stage of work and notify the contractor in writing. The superior or design approval department of the contractor does not approve the design file or the project is suspended. The contractor pays the design fee in accordance with 7.1. 7.3 The designer is responsible for modifying or supplementing the omissions or errors in the design materials and files. Due to the designer's mistakes causing loss of engineering quality accidents, the designer shall be exempt from the design fee directly affected by the loss, in addition to taking remedial measures. If the loss is serious, the contractor shall be paid compensation according to the degree of the loss and the size of the designer's responsibility. The compensation shall be agreed by both parties as 1.5% of the actual loss. 7.4 Due to the designer's own reasons, the delivery time of the design materials and design files in accordance with Article 4 of this contract is delayed. For each day of delay, the design fee of the project shall be reduced by two-thousandths. 7.5 After the contract is in force, the designer requests to terminate or cancel the contract, and the designer shall double the deposit. Article 8 When other 8.1 contractors require the designer to send a special person to stay at the construction site to cooperate and solve the relevant problems, the two parties shall sign a supplementary agreement or a technical consulting service contract. 8.2 The national or local standard map adopted by the designer for this contract project shall be purchased by the contractor at the expense of the relevant publishing department. Article 4 of this contract stipulates that the number of design materials and files delivered by the designer exceeds the number specified in the Engineering Design Fees Standard, and the designer shall charge the cost of the work. 8.3 Building design materials and archives, building materials, building components and equipment. The technical specifications such as specifications, models and performance shall be indicated, and the designer shall not designate the manufacturer or supplier. When the contractor needs the designer's designer to cooperate with the processing order, the required cost is borne by the contractor. 8.4 The contractor entrusts the design and cooperation with the design tasks of the introduced project. From the inquiry, the external negotiation, the domestic and international technical inspection to the completion of the production and production, the designers who undertake the relevant design tasks should be absorbed. Except for the cost of going abroad, in addition to the installation fee, other expenses are paid by the contractor. 8.5 The contractor entrusts the designer to undertake the work services other than the contents of this contract, and pay the fee separately. 8.6 When the contract cannot be fulfilled due to force majeure factors, both parties shall resolve the matter in time. 8.7 In the event of a dispute between the contract, the parties shall resolve it in a timely manner. It may also be mediated by the local construction administrative department. If the mediation fails, the parties agree to be arbitrated by the Zhuhai Municipal Arbitration Commission. If the parties have not agreed on the arbitration institution in the contract and have not reached a written agreement on the arbitration afterwards, they may file a suit in a people's court. 8.8 This contract is in five copies, the contractor is responsible for the copy, the designer is responsible for the copy, and the construction administrative department is responsible for the record. 8.9 This contract is signed by both parties and takes effect after the issuer pays the deposit to the designer. 8.10 After the contract is in force, it shall be submitted to the review department as stipulated by the construction administrative department at the provincial level according to the regulations. When both parties deem it necessary, they shall apply for attestation at the administrative department for industry and commerce where the project is located. After the parties have fulfilled their obligations under the contract, the contract will be terminated. 8.11 In the event that the contract is not completed, the parties may sign a supplementary agreement. The relevant agreements and the telegrams, faxes and minutes of meetings approved by both parties are part of this contract and have the same legal effect as this contract. 8.12 Other agreed matters:

Issuer Name: Designer Name:

Legal representative: Legal representative:

Attorney: Attorney:

Residence: Residence:

Postal Code: Postal Code:

Phone: Phone:

Fax: Fax:

Bank of deposit: Bank of deposit:

Bank account number: Bank account number:

Construction administrative department filing: Attestation opinion:

Record number: Manager:

Date of filing: Year, month and day date: Year, month and day