Construction project labor service subcontract

Engineering contractor package):
Labor subcontractor:
In accordance with the "Contract Law of the People's Republic of China", "Building Law of the People's Republic of China" and other relevant laws and administrative regulations, follow the principles of equality, voluntariness, fairness and good faith, in view of the signing of the general contracting contract or professional contracting with the project contractor The contractual contract"), the two parties reached an agreement on the labor subcontracting agreement and entered into this contract.
1. Qualification certificate number of labor subcontractor:
Issuing authority:
Qualifications and grades:
Review time and validity period:
2. Labor subcontracting work objects and providing labor service content project name:
construction place:
Subcontracting scope:
Provide subcontracted labor services:
3. Subcontracting work period Start working date: year, month and day, end of work date: year, month and day, total calendar working days: day
4. Quality Standards Engineering Quality: According to the quality agreement of the general contract, the current National Construction and Acceptance Code for Construction and Installation Engineering and the Quality Assessment Standard for Building Installation Engineering, this work must reach the quality assessment level.
5. The contract file and the order of interpretation constitute the file of this contract and the order of priority interpretation is as follows:
This contract;
Attachment file of this contract;
The general contracting contract for the construction of the project;
The construction contract of the project.
6. Standard Specifications In addition to the contractual provisions of this project, the applicable standard specifications of this contract are as follows:


7, the general contract
7.1 The project contractor shall provide a general contract for inspection by the labor subcontractor. When required by the labor subcontractor, the project contractor shall provide the labor subcontractor with a copy or a copy of the general contract or professional subcontract.
7.2 Labor subcontractors should have a comprehensive understanding of the provisions of the general contract.
8, drawings
8.1 The project contractor shall provide the labor subcontractor with a drawing set and a standard drawing set related to the work of this contract before the labor subcontracting work starts.
8.2.
9, project manager
9.1 The project manager appointed by the project contractor to perform this contract at the construction site shall be: Job title: , Title: .
9.2 The project manager appointed by the labor subcontractor to perform the contract at the construction site is: Position: , Title: .
10. Project contractor's obligations
10.1 Set up a project management team that is compatible with the project, fully implement the general contract contract, organize the implementation of various tasks of construction management, and be responsible to the contractor for the duration and quality of the project;
10.2 Unless otherwise agreed in this contract, the project contractor completes the following work in the pre-construction period of the labor subcontractor and bears the corresponding expenses:
The construction site that has the conditions for commencement of labor service under this contract is delivered to the labor subcontractor before the date of the year, and the construction site delivery requirements with the commencement conditions are:
Complete water, electricity, heat, telecommunications and other construction pipelines and construction roads before the date of the year, and meet the time and quality requirements for the energy supply, communication and construction roads required to complete the contract labor service;
Provide corresponding engineering geological and underground pipe network data to labor subcontractors before the date of the year;
Complete the following work procedures before the date of the year:
Provide the corresponding benchmarks and coordinate control points to the labor subcontractors before the date of the year, and the inspection requirements and protection responsibilities are:
Provide the following production and living temporary facilities to labor subcontractors before the date of the year: The requirements for inspection and protection are:
10.3 Responsible for the preparation of construction organization design, unified formulation of various management objectives, organization of annual, quarterly and monthly construction plans, material demand and consumption plan, implementation of project quality, construction period, safe production, civilized construction, measurement and analysis Control, supervision, inspection and acceptance of experimental tests;
10.4 Responsible for engineering survey positioning, settlement observation, technical disclosure, organization of drawing review, unified arrangement of technical archives data collection and delivery acceptance;
10.5 Coordinate and coordinate the settlement of production and living temporary facilities, work water, electricity and construction sites independently used by non-labor subcontractors;
10.6 Provide drawings on time, timely delivery of materials, equipment, construction machinery and equipment, turnover materials and safety facilities to ensure construction needs;
10.7 pay labor remuneration to labor subcontractors in accordance with this contract;
10.8 Responsible for contacting the contractor, supervision, design and related departments to coordinate the on-site working relationship.
11. Labor subcontractor's obligation
11.1 Responsible for the project quality within the scope of subcontracting of this contract, and organize skilled workers with corresponding qualification certificates to work; without the authorization or permission of the project contractor, they shall not establish work contact with the contractor and relevant departments without authorization. Consciously abide by laws and regulations and relevant rules and regulations;
11.2 According to the requirements of the overall progress plan of the construction organization design, the labor subcontractor submits the construction plan for the next month before the end of each month, and submits the construction plan for the submission phase required by the stage construction period. If necessary, submit the construction schedule according to the requirements of the project contractor. The construction plan and the labor arrangement plan corresponding to the completion of the above-mentioned stage and time period construction plan shall be strictly implemented after approval by the project contractor;
11.3 Carefully organize the construction according to the design drawings, construction acceptance specifications, relevant technical requirements and construction organization design to ensure that the project quality meets the agreed standards; scientifically arrange the operation plan, invest sufficient manpower and material resources to ensure the construction period; strengthen safety education Seriously implement safety technical specifications, strictly abide by safety systems, implement safety measures, ensure construction safety; strengthen on-site management; strictly implement the construction authorities and environmental protection, fire protection, sanitation and other relevant departments on the construction site management regulations, to achieve civilized construction; Responsible for quality modification, rework, delays in construction, safety accidents, damage caused by dirty scenes and various fines caused by their own responsibilities;
11.4 Conscientiously accept the management, supervision and inspection of the project contractor and relevant departments; accept the project contractor to check the equipment, materials storage and use at any time, and the valid documents and certificates of the operators; and other units on site Coordinate coordination and take care of the overall situation;
11.5 According to the project contractor's unified planning of stacking materials and machinery, set the signs according to the standard chemical requirements of the project contractor, do a good job in the management of the living area, and do a good job in the security of the area under its own responsibility;
11.6 Submit the report on time, complete original technical and economic data, and cooperate with the project contractor to handle the acceptance;
11.7 Do a good job in the protection of finished products around the construction site, structures, underground pipelines and completed works. The labor subcontractor shall bear all the economic losses and various fines caused by the labor subcontractor’s liability. ;
11.8 properly keep and reasonably use the tools, turnover materials and other facilities provided or leased by the project contractor to the labor subcontractors;
11.9 The labor subcontractor shall obey the instructions of the contractor and the engineer forwarded by the project contractor.
11.10 Unless otherwise agreed in this contract, the labor subcontractor shall be responsible for the implementation and completion of the contents of the operation, and the labor subcontractor shall bear and perform all the obligations and work procedures stipulated in the general contract contract and related to the labor operation.
12. Safety construction and inspection
12.1 Labor subcontractors shall abide by the relevant regulations on safe construction of engineering construction, strictly follow the safety standards, and accept the supervision and inspection carried out by industry safety inspectors according to law, and take necessary safety protection measures to eliminate hidden dangers. Due to the inability of the labor subcontractor's safety measures to cause accidents and the costs incurred, the labor subcontractors shall bear the costs.
12.2 The project contractor shall provide safety education to the staff at the construction site and be responsible for their safety. The project contractor shall not require the labor subcontractor to conduct construction in violation of the safety management regulations. The safety contractor caused by the project contractor shall bear the corresponding responsibility and expenses incurred by the project contractor.
13, security protection
13.1 When labor subcontractors are constructing power equipment, transmission lines, underground pipelines, sealed earthquake-proof workshops, inflammable and explosive areas, and traffic-oriented roads near the street, safety precautions should be submitted to the project contractor before construction begins. After the contractor has approved it, the cost of the protective measures shall be borne by the project contractor.
13.2 When performing blasting operations, when working in radioactive or toxic environments and using toxic and corrosive materials, the labor subcontractor shall notify the project contractor in writing 10 days before the construction and propose corresponding safety protection. The measures shall be implemented after being approved by the project contractor, and the project contractor shall bear the costs of safety protection measures.
13.3 The safety protection articles used by the labor subcontractors in the construction site shall be provided by the labor subcontractor. After approval by the project contractor, the project contractor shall be responsible for the supply.
14. Accident handling
14.1 In the event of major casualties and other safety incidents, the labor subcontractor shall immediately report to the relevant department and report to the project contractor in accordance with relevant regulations, and at the same time handle the accident according to relevant national laws and administrative regulations.
14.2 If the labor subcontractor and the project contractor have disputes over the liability of the accident, they shall be dealt with according to relevant regulations.
15, insurance
15.1 Before the commencement of the construction of the labor subcontractor, the project contractor shall obtain the insurance for the owner and the life and property of the third person in the construction site, and the labor subcontractor shall not be required to pay the insurance premium.
15.2 The materials and equipment to be installed that are transported to the construction site for labor service shall be handled or obtained by the project contractor, and the labor subcontractor shall not be required to pay the insurance fee.
15.3 The project contractor must insure the construction machinery and equipment used for the lease or supply to the labor subcontractor and pay the insurance fee. The scope of the project contractor’s own insurance is:
15.4 Labor subcontractors must handle accidental injury insurance for employees engaged in dangerous operations, and provide insurance for the life and property of their own personnel and construction machinery and equipment in the construction site, and pay insurance premiums. The scope of labor subcontractors' own insurance is:
15.5 When an insurance accident occurs, the labor subcontractor and the project contractor are responsible for taking the necessary measures to prevent or reduce losses.
16. Supply of materials and equipment
16.1 The labor subcontractor shall submit the materials, equipment and components supply plan to the project contractor within the day after receiving the drawings; after confirmation, the project contractor shall, according to the quality, variety and specifications of the supply plan, The type, quantity and supply time of the organization shall be delivered and delivered in a timely manner; if the labor subcontractor is required to transport or unload the vehicle, the labor subcontractor must proceed in time and the cost is separately agreed. If the quality, variety, specifications and model do not meet the requirements, the labor subcontractor shall submit it at the time of acceptance, and the project contractor shall be responsible for handling it.
16.2 Labor subcontractors shall properly keep and reasonably use the materials and equipment supplied by the project contractor. If the loss or damage occurs due to poor storage, the labor subcontractor shall compensate and bear all economic losses caused by the delay of the construction period.
16.3 The project contractor entrusts the labor subcontractor to purchase the following low-value consumable materials:
The cost of purchasing materials is:
The cost of purchasing materials is:
The cost of purchasing materials is:
The cost of purchasing materials is:
16.4 If the project contractor entrusts the labor subcontractor to purchase low-value and consumable materials, the labor subcontractor shall reimburse the project contractor with the purchase certificate and the management fee plus %.
17, labor compensation
17.1 The labor remuneration for this project is calculated in any of the following ways:
Fixed labor remuneration;
The unit price of the contract for different types of labor services is calculated according to the confirmed working hours;
The unit price of the piece of work that agrees on different work results is calculated according to the confirmed amount of work.
17.2 The labor remuneration for this project, except for the circumstances specified in 17.6 of this contract, is a one-time death and will not be adjusted.
17.3 In the first way, the total amount of labor compensation is RMB.
17.4 In the first way, the unit price of the different types of services is:
The unit price is yuan;
The unit price is yuan;
The unit price is yuan;
The unit price is yuan;
The unit price is yuan.
17.5 In the first way, the unit price of the different work results is:
The unit price is yuan;
The unit price is yuan;
The unit price is yuan;
The unit price is yuan;
The unit price is yuan.
17.6 Fixed remuneration or unit price can be adjusted under the following circumstances:
Based on the price agreed in this contract, the market artificial price changes by more than %, and is adjusted according to the difference between the price before and after the change;
If the subsequent laws and policies change, resulting in changes in labor prices, the difference between the price before and after the change shall be adjusted;
Other situations agreed by both parties:
18. Confirmation of working hours and engineering quantity
18.1 If the fixed labor compensation method is adopted, the working hours and engineering quantities are not calculated during the construction process.
18.2 If the labor remuneration is calculated according to the determined working hours, the number of labor services provided by the labor subcontractor shall be reported to the project contractor on a daily basis and confirmed by the project contractor.
18.3 If the labor remuneration is calculated according to the confirmed quantity of work, the project contractor who is completed by the labor subcontractor on a monthly basis shall be reported to the project contractor for confirmation by the project contractor. If the labor subcontractor is not recognized by the project contractor and exceeds the scope of the design drawings and the amount of rework caused by the labor subcontractor, the project contractor shall not measure it.
19. Intermediate payment for labor compensation
19.1 If the payment of labor services is paid by means of fixed labor remuneration, the labor subcontractor and the project contractor agree to pay according to the following methods:
The contract is effective, that is, the advance payment is paid;
Intermediate payment:
The first payment time is the year, month, and day, and the payment is made;
The second payment time is the year, month, and day, and the payment is made;
......
19.2 If the labor remuneration is paid by the unit price or the unit price of the piece, the labor subcontractor and the project contractor agree on the payment method.
19.3 The contract determines the adjusted labor remuneration, the labor remuneration for engineering change adjustment and the additional labor remuneration agreed in other clauses, and shall be adjusted and paid in the same period as the above-mentioned labor remuneration.
20, construction machinery, turnover materials supply
20.1 The equipment and equipment provided by the project contractor to the labor subcontractor's labor service shall meet the requirements of the construction, be transported into the site in time, be installed and commissioned, and be delivered to the labor subcontractor after good operation. Turnover materials and low-value consumable materials shall be delivered to the on-site labor subcontractors on time to ensure construction needs. If labor, subcontractor transportation, unloading, installation and commissioning are required, the cost will be separately agreed.
20.2 The list of equipment and equipment that the project contractor should provide for construction shall be found in Attached File 2.
20.3 The list of turnover materials and low-value consumables that the project contractor should provide is shown in Attachment III.
21. Construction change
21.1 If the original work content changes during construction, the project contractor project manager shall send a notice of change to the labor subcontractor in writing 7 days in advance, and provide the corresponding drawings and instructions for the change. The labor subcontractor shall make the following required changes in accordance with the notice of change and related requirements issued by the project contractor:
Change the elevation, baseline, position and size of the relevant part of the project;
Increase or decrease the amount of work agreed upon in the contract;
Change the relevant construction time and sequence;
Additional work required for engineering changes.
21.2 The increase in labor compensation due to the change and the loss of the labor subcontractor caused by the project shall be borne by the project contractor, and the delay of the construction period shall be postponed accordingly; due to the reduction of the amount of work, the labor remuneration shall be correspondingly reduced and the construction period shall be adjusted accordingly.
21.3 Labor subcontractors may not change the original engineering design during construction. Due to the cost of the labor subcontractor's unauthorized alteration of the design and the direct loss of the project contractor, the labor subcontractor shall bear the delay, and the delay of the construction period shall not be postponed.
21.4 Due to engineering changes caused by the labor subcontractor's own reasons, the labor subcontractor has no right to request additional labor compensation.
22. Construction acceptance
22.1 The labor subcontractor shall ensure that the quality of the completed construction is in accordance with the quality standards agreed in this contract. Upon completion of the construction of the labor subcontractor, the completion report shall be submitted to the project contractor to notify the project contractor to accept the project; the project contractor shall, within 7 days after receiving the above report of the labor subcontractor, accept the construction results of the labor subcontractor. If the acceptance is qualified or the project contractor fails to organize the inspection within the above-mentioned period, it shall be deemed that the labor subcontractor has completed the work stipulated in this contract. However, if the concealed project acceptance result or the project completion acceptance result between the project contractor and the contractor indicates that the construction subcontractor's construction quality is unqualified, the labor subcontractor shall be responsible for repairing without compensation, not extending the construction period, and undertaking the resulting project contractor. Related losses.
22.2 Upon completion of all project completion, the labor subcontractor will no longer be responsible for the construction quality of the subcontracted labor service. The quality warranty responsibility during the quality warranty period shall be borne by the project contractor.
23, construction cooperation
23.1 The labor subcontractor shall cooperate with the project contractor to carry out preliminary acceptance of his work, and the work contractor's work content, construction site inspection and concealed works carried out by the contractor according to the requirements of the contractor or the construction administrative department. Acceptance and completion acceptance of the project; when the contractor of the project or the work of a third party in the construction site must cooperate with the labor subcontractor, the labor subcontractor shall cooperate according to the instructions of the project contractor. In addition to the above preliminary acceptance, concealed project acceptance and project completion acceptance, the project contractor shall bear the construction period loss and expenses incurred by the labor subcontractor for providing the above cooperation.
23.2 When the labor subcontractor completes the labor service work as agreed, the project contractor shall cooperate with the labor subcontractor or ensure that the labor subcontractor obtains the third party when the project contractor or the third party in the construction site must cooperate. Coordination, and the project contractor shall bear the costs incurred as a result.
24, the final payment of labor compensation
24.1 After all work is completed, within 14 days after the project contractor approves, the labor subcontractor submits the complete settlement information to the project contractor, and the two parties shall make the final payment of the labor remuneration according to the pricing method stipulated in this contract.
24.2 The project contractor shall verify within 14 days after receiving the settlement information submitted by the labor subcontractor, and give confirmation or propose amendments. After the project contractor confirms the settlement information, it will pay the labor remuneration to the labor subcontractor within 14 days.
24.3 When a labor subcontractor and a project contractor dispute a settlement fee for labor services, they shall be dealt with in accordance with the contractual disputes in this contract.
25. Liability for breach of contract
25.1 The project contractor shall be liable for breach of contract when one of the following occurs:
The project contractor violates the provisions of Articles 19 and 24 of this contract and fails to pay labor remuneration to the labor subcontractor on time;
Other circumstances in which the project contractor fails to perform or fails to perform the contractual obligations as agreed.
25.2 If the project contractor fails to verify the amount of work done by the labor subcontractor or fails to pay the labor remuneration or labor repayment as agreed, the labor subcontractor shall pay the labor subcontractor arrears according to the bank loan interest rate. The interest paid, and the labor subcontractor pays the daily liquidated damages according to the amount of the arrears.
25.3 When the project contractor fails to perform or fails to perform other obligations of the contract as agreed, the labor contractor shall pay the liquidated damages, and the project contractor shall compensate the economic loss caused by the breach of contract to the labor subcontractor, delaying the delay. Labor subcontractor working hours.
25.4 The labor subcontractor shall be liable for breach of contract when one of the following occurs:
If the labor subcontractor delays the delivery of work due to its own reasons, the project contractor shall pay the liquidated liquidated damages for each day of delay;
The construction quality of the labor subcontractor does not meet the quality standards stipulated in this contract, but when it can meet the minimum standards set by the state, the labor subcontractor shall pay the liquidated damages to the project contractor;
When the labor subcontractor fails to perform or fails to perform other obligations of the contract as agreed, the contractor shall pay the liquidated damages, and the labor subcontractor shall compensate the economic loss caused by the breach of contract to the project contractor and the delayed labor subcontracting. People's working hours will not be postponed.
25.5 After the breach of contract by one party and the other party requires the defaulting party to continue to perform the contract, the defaulting party shall continue to perform the contract after undertaking the above-mentioned breach of contract liability.
26. Claim
26.1 When the project contractor submits the notice of intention or other information to the contractor according to the general contract, the labor subcontractor shall actively cooperate to maintain and present the corresponding information so that the project contractor can abide by the general contract.
26.2 In the course of the implementation of labor service, if the labor subcontractor encounters unfavorable external conditions and may claim according to the general contract, the project contractor shall take all reasonable steps to claim additional payment or extend the construction period to the contractor. . When the claim is successful, the project contractor shall forward the corresponding portion of the claim to the labor subcontractor.
26.3 When one party to this contract makes a claim against the other party, there should be a legitimate reason for the claim and evidence of the validity of the claim at the time of the event.
26.4 The project contractor fails to perform its own obligations or errors as agreed, and other circumstances that should be borne by the project contractor, resulting in delays in working hours and labor subcontractors failing to receive contractual remuneration and labor subcontractors in a timely manner. For other economic losses, the labor subcontractor may claim in writing from the project contractor in the following manner:
Within 21 days after the claim event, the project contractor’s project manager is notified of the intention to make a claim;
Within 21 days after the notice of intention to issue the claim, the project manager of the project contractor shall submit a claim report and relevant information for extending the working hours and compensating for economic losses;
After receiving the claim report and relevant information submitted by the labor subcontractor, the project contractor shall give a reply within 21 days, or request the labor subcontractor to further supplement the claim reason and evidence;
The project contractor's project manager did not reply or did not make further requests to the labor subcontractor within 21 days after receiving the claim report and relevant information submitted by the labor subcontractor, and the claim was deemed to have been approved;
When the claim event continues, the labor subcontractor shall issue the claim intention to the project contractor in stages, and submit the relevant information and final claim report to the project contractor project manager within 21 days after the end of the claim event. . The claim reply procedure is the same as the regulations.
26.5 The labor subcontractor fails to perform its own obligations or errors as agreed, causing economic losses to the project contractor. The project contractor may make a claim in writing to the labor subcontractor in accordance with the above procedures and time limits.
27. Disputes
27.1 If the project contractor and the labor subcontractor have disputes in the performance of the contract, they may reconcile themselves or request the relevant competent department to mediate. If either party is unwilling to settle, mediate or settle or mediate, the two parties agree to adopt the following first method to solve the problem. dispute:
The parties reached an arbitration agreement and applied to the Arbitration Commission for arbitration;
Prosecuted to a people's court with jurisdiction.
27.2 After a dispute has occurred, both parties shall continue to perform the contract unless the following conditions are met, and the work shall be continued to protect the completed work results:
The unilateral breach of contract causes the contract to be unfulfilled, and the parties agree to terminate the contract;
Mediation requires the suspension of the contract work and acceptance by both parties;
The arbitration institution requested to stop the contract work;
The court requested that the contract work be stopped.
28. Prohibit subcontracting or subcontracting
28.1 Labor subcontractors may not subcontract or subcontract labor services under this contract to others. Otherwise, the labor subcontractor will bear the responsibility according to law.
28.2.
29, force majeure
29.1 The definition of force majeure in this contract is the same as defined in the general contract.
29.2 After the event of force majeure, the labor subcontractor shall immediately notify the project contractor's project manager and take prompt measures to reduce the losses as far as possible, and the project contractor shall assist the labor subcontractor to take measures. The project contractor's project manager believes that the labor subcontractor should suspend work and the labor subcontractor should suspend work. Within 48 hours after the event of force majeure, the labor subcontractor informs the project contractor of the project manager of the damage and loss, and the estimated cost of cleaning and repair. The force majeure event continues to occur, and the labor subcontractor should notify the project contractor project manager of the victimization every 7 days. Within 14 days after the end of force majeure, the labor subcontractor shall submit a formal report and related information on the cleaning and repair costs to the project contractor project manager.
29.3 The costs and delays due to force majeure events shall be borne by both parties as follows:
The damage caused by the project itself, the third-person casualties and property losses caused by the engineering damage, and the damage to the materials and equipment to be installed that are transported to the construction site for labor service shall be borne by the project contractor;
The casualties of the project contractor and the labor subcontractor shall be the responsibility of the unit in which they are located and bear the corresponding expenses;
The labor subcontractor’s own mechanical equipment damage and loss of work stopage shall be borne by the labor subcontractor;
The damage caused by the contractor of the project to the labor contractor shall be borne by the project contractor, but the loss of the work shall be borne by the labor subcontractor;
During the period of suspension of work, the labor subcontractor shall be responsible for the necessary management personnel and security personnel required to remain at the construction site by the project contractor's project manager;
The cost of cleaning and repairing the project shall be borne by the project contractor;
Delayed working hours are postponed accordingly.
29.4 Due to the force majeure after the contractual party has delayed performance of the contract, the corresponding responsibility of the delaying performer cannot be waived.
30. Cultural relics and underground obstacles
30.1 When collecting cultural relics such as tombs, ancient architectural sites, fossils or other items of archaeological or geological research value in labor operations, the labor subcontractor shall immediately protect the site and notify the project contractor in writing within 4 hours. The project manager and the project contractor shall report the local cultural relics management department within 24 hours after receiving the written notice. The project contractor and the labor subcontractor shall take appropriate protection measures according to the requirements of the cultural relics management department. The project contractor bears the costs incurred and delays the contract work time. If the labor subcontractor discovers that it will not conceal or rob the cultural relics, causing the cultural relics to be damaged, the responsible person shall bear corresponding responsibilities according to law.
30.2 When the underground obstacles affecting work are found in the labor operation, the labor subcontractor shall notify the project contractor project manager in writing within 8 hours, and at the same time propose a disposal plan. After the project contractor receives the disposal plan, the project contractor shall receive the disposal plan. Within the hour, the project contractor will approve or propose an amendment plan, and the project contractor will bear the expenses incurred and delay the contract work time. When the underground obstacles found have vested units, the project contractor shall report to the relevant departments for joint disposal.
31, the contract is lifted
31.1 If the project contractor fails to pay the labor remuneration in accordance with the contract, the labor subcontractor may stop working. After stopping work for more than 28 days, the project contractor still does not pay the labor service, and the labor subcontractor can issue a notice to cancel the contract.
31.2 If the general contractor or professional subcontract is terminated before the labor subcontractor fails to fully perform this contractual obligation, the project contractor shall notify the labor subcontractor to terminate this contract. After receiving the notice, the labor subcontractor evacuates the site as soon as possible, and the project contractor shall pay the labor remuneration of the labor subcontractor for the completed project and compensate for the losses suffered as a result.
31.3 If the contract cannot be performed due to force majeure, or if the contract is unsuccessful due to breach of contract or due to the contractor, the project contractor and the labor subcontractor may cancel the contract.
31.4 After the contract is terminated, the labor subcontractor shall properly perform the work of protecting and transferring the completed project and the remaining materials and equipment, and withdraw from the construction site as required by the project contractor. The project contractor shall provide the necessary conditions for the labor subcontractor to withdraw, pay the above expenses incurred, and pay the remuneration for the completed work labor according to the contract. The party that is at fault shall compensate for the loss caused to the other party by the contract. After the contract is terminated, it does not affect the validity of the settlement and clean-up clauses agreed upon by the parties in the contract.
32, contract termination
32.1 The parties fulfill all the obligations of the contract, and the payment of the labor remuneration is completed. The labor subcontractor delivers the results of the labor service to the project contractor, and the contract is terminated after the project contractor has passed the inspection.
32.2.
33, the number of contracts
33.1 The original of this contract is two copies, with the same effect, each of the project contractor and the labor subcontractor; each copy of the contract, the project contractor, the labor subcontractor.

34, supplementary terms

35. Contract entry into force The contract is concluded at the date of the year:
This contract comes into effect after the agreement between the parties.
Attached file 1: Project contractor supply materials, equipment, and accessories plan attached file 2: Project contractor provides construction equipment, equipment list attached file 3: Project contractor provides turnover, low value consumables material list Contractor: Labor Subcontractor:
Residence: Residence:
Legal representative: Legal representative:
Attorney: Attorney:
Bank of deposit: Bank of deposit:
Account number: Account number:
Postal code: Postal code: