Water conservancy project construction supervision contract

Contractor: ____________ Contract No.: ______________
Supervisor: ____________ Signing location: ______________
Signing time: ____ years __ month __ day According to the "Contract Law of the People's Republic of China", ____________ and ___________, this contract is concluded by consensus between the two parties on matters related to the construction of this project.
1. The contractor entrusts the supervisor to supervise the construction of the project in accordance with the requirements of the construction supervision contract.
Project Overview:
1. project name:___________________________
2. construction place:___________________________
3. Project size and characteristics: ________________________
4. Total project investment: static: _______________________
dynamic:_______________________
5. Total project duration: __________________________
Scope of supervision: The supervision business shall be undertaken in accordance with the scope stipulated in the terms of the special contract.
Supervision content: undertake the supervision business according to the content stipulated in the terms of the special contract.
The construction project supervision period is from ____________________ to ____________________.
The construction supervision remuneration is ____ yuan, and the contractor shall settle the payment to the supervisor in the manner and time specified in the terms of this special contract.
Second, the construction file of the construction supervision contract and the order of interpretation.
Supervisory letter of entrustment or letter of acceptance.
Supervision contract.
Supplementary files signed by both parties during the implementation of the supervision.
Special contract terms.
General contract terms.
Supervisory tender.
Supervisory tender.
The above-mentioned contract files are a whole, replacing all the agreements signed by the parties before the signing of this contract, the records of the talks and all the files related to mutual commitment.
3. This contract shall become effective after it has been signed by the legal representatives of the two parties or their entrusted agents and affixed with the official seal of the unit.
4. The original of this contract is two copies, with the same legal effect, and each party shall hold one copy; a copy of ____ copies, each holding ____ copies.
Employer: ______ Supervisor: ______
Legal representative: ____ Legal representative: ____
Attorney: ____ Attorney: ____
Zip code: _________ Zip code: _________
Phone: _________ Phone: _________
Fax: _________ Fax: _________
Bank of deposit: _______ Bank of deposit: __________
Account number: _________ Account number: _________

General contract clause

Word meaning and applicable language

Article 1 The following nouns and terms have the meanings given in this Article unless otherwise specified by the contextual number:
1. "Engineering Project" means the project construction project in which the Employer entrusts the Supervisor to implement the construction supervision.
2. "Employer" means a legal person who entrusts the supervision business and assumes the direct investment responsibility and its legal successor.
3. “Supervisor” means the legal person and its legal heirs who undertake the supervision business and supervision responsibility.
4. The “supervisory organization” is the organization that the supervisor is directly responsible for the implementation of the supervision business at the project site, and is composed of the chief management engineer, the supervision engineer and the supervisor, and other personnel.
5. “Construction Project Supervision” is the supervision engineer's performance of his duties in accordance with this contract, including normal supervision work and additional supervision work.
6. The “Director Management Engineer” is the person in charge who is nominated by the supervisor and approved by the contractor to be appointed to the supervision organization to perform the contract.
7. “Contractor” means the constructor who signs the construction contract with the contractor.
8. "Day" means any period from midnight to the next midnight.
Nine, "Month" is the period from the day of the Gregorian calendar from any day in a month to the day before the corresponding date of the next month.
X. “This contract” means the contract of supervision signed and validated by both parties.
XI. “Engineering Construction Contract” means the contract for the construction of the Project signed and effective by the Employer and the Contractor.
12. “Residing” means that the supervision organization and the supervision personnel enter the construction site and begin to implement or prepare to implement the supervision business.
XIII. “Site” refers to the place where the construction project is implemented.
XIV. “Local laws and regulations” refers to the laws and regulations formulated by the provincial people's congresses or the standing committees and the people's governments.
Article 2 The language of the contract applies to Chinese characters.

Applicable laws, regulations, rules and supervision basis

Article 3 The laws, regulations and rules applicable to this contract are the laws and administrative regulations of the People's Republic of China and the local laws and regulations of the relevant departments of the State Council and the localities.
Article 4 The basis for supervision work is the national laws, regulations, rules and technical standards, construction project construction files approved by the relevant departments, and engineering construction contract files and this contract file.

Notification and contact

Article 5 The Employer shall authorize a Permanent Representative who is familiar with the situation of the Project and who can make prompt decisions on some major issues in the construction of the Project, and is responsible for contacting the Supervisory Organization. When replacing the resident representative, the supervisor should be notified in advance.
Article 6 In the process of implementing the contract, the contact between the two parties shall be subject to the written letter, and may be verbally or telephonely notified without causing personal, equipment or engineering accidents without urgent treatment, and shall be within 48 hours afterwards. Make a written notice.
Article 7 The opinions and decisions of the contractor on the implementation of the project shall be implemented through the supervision organization; the contractor shall obtain various engineering implementation orders such as notices, instructions and changes from the supervision organization.

Supervisor's duties and responsibilities

Article 8 The supervisor shall submit to the Employer a list and resume of the supervision plan, the supervision organization, and the appointed chief engineer and main supervisors within the time specified in the terms of the special contract.
Article 9 The supervisor shall, in accordance with the scope and contents of the supervision as stipulated in the terms of the special contract, dispatch the professional supporting personnel who meet the qualifications according to the supervision plan to the construction site, set up the supervision organization, prepare the supervision rules, and normal. Carry out supervision work in an orderly manner, complete the supervision tasks as stipulated in this contract, and assume corresponding supervisory responsibilities.
Article 10 During the supervision period, the supervisor may make reasonable adjustments to the supervision organization and personnel according to the progress of the project and the size of the supervision business. The replacement of the chief management engineer shall be subject to the consent of the contractor, and the other principal supervisors shall be kept relatively stable. If there is any adjustment, the contractor shall be reported for filing.
Article 11 The supervisor shall establish a responsibility system for supervision posts and a lifelong responsibility system for project quality in accordance with the relevant provisions of the State.
Article 12 During the supervision period, the supervisors must abide by the professional ethics and behavioral norms of supervision work, and use reasonable skills to provide quality services; they should adhere to the principles of “law-abiding, honest, fair, and scientific” and work diligently, efficiently, and independently. Supervision services to protect the interests of the contractor and the legitimate rights and interests of the contractor. Supervisors shall not be employed by or accept the interests of the contractor.
Article 13 The on-site supervision personnel shall timely supervise the construction of the project in accordance with the construction operation procedures, and the key parts and key processes of the project shall be supervised by the side station.
Article 14 Supervisors must take effective measures to collect, organize and archive all kinds of information during the implementation phase of the project, and ensure the completeness and accuracy of on-site records, tests, inspections and quality inspections.
Article 15 The supervision organization shall conscientiously make the "supervisor diary" to maintain its timeliness, completeness and continuity; it shall submit the monthly report of supervision work and the special report within the scope of supervision business to the contractor.
Article 16 The equipment and facilities provided by the contractor used by the supervision institution shall belong to the contractor except for special provisions. After the termination of this contract, it shall be handed over to the contractor in accordance with the provisions of the special contract.
Article 17 Within the term of this contract or after the termination of the contract, without the consent of the contractor, the supervisory institution and all supervisors shall not disclose the technical and commercial materials related to the business of this contract; and shall properly prepare the information provided by the contractor. The preservation, recycling and confidentiality of the construction construction archives.
Article 18 If the delay or delay of the construction progress exceeds the time limit stipulated in this supervision contract, the supervisor shall negotiate with the contractor and sign a supplementary agreement for the extension of the supervision period.
Article 19 Within the time limit stipulated in this contract, if the quality of the project or the direct economic loss of the contractor is caused by the default of the supervisor or the supervisor or the fault of the supervisor, the supervisor shall bear the corresponding economy in accordance with the provisions of this special contract. responsibility.
Article 20 If the supervisor fails to perform or fails to perform the contract due to force majeure, the supervisor shall not be liable.
Article 21 The supervisor shall not be liable for the extension of the quality accident and the time limit for completion caused by the contractor's violation of the relevant construction contract.

Contractor’s obligations and responsibilities

Article 22 The contractor shall be responsible for coordinating the external environment of the project construction and providing the necessary working environment and external conditions for the supervision work.
Article 23 The contractor shall provide the supervision organization with the archives and materials related to the construction of the project required for the supervision business in accordance with the time, quantity and method agreed upon in the terms of the special contract.
Article 24 The contractor shall make a written decision on the matters submitted by the supervisory institution in writing and requesting a decision within the time specified in the terms of the special contract, and shall promptly serve on the supervision institution. Exceeding the agreed time, the supervisory agency has not received the written decision of the contractor, and the supervisory agency may consider that the contractor has no disagreement on the matters raised by the contractor and no further confirmation is required.
Article 25 The contractor shall notify the contractor of the project construction in writing of the list of the chief engineer and the main management personnel and the permission granted to the supervision institution before the commencement of the project.
Article 26 The contractor shall provide the supervision organization with the work and living conditions necessary for carrying out the supervision business, and the provision of the above conditions shall be clarified in the terms of the special contract. The contractor shall not be able to provide compensation for living and working conditions. The cost of compensation shall be specified in the terms of the special contract.
Article 27 If the parties agree that the contractor provides the staff to the supervision institution free of charge, it shall be clearly stated in the terms of the special contract. All such personnel shall be deemed to be members of the supervisory body and subject to the uniform arrangement and use of the supervisory authority.
Article 28 The contractor shall maintain the independence of the work of the supervision organization and shall not interfere with the supervision business of the supervision organization.
Article 29 If the progress of the construction is postponed or delayed due to non-supervising reasons and exceeds the service period stipulated in the supervision contract, the contractor shall accept the supervisor's corresponding increase in supervision remuneration requirements, and supervise the extension of the service period and increase the supervision period. Remuneration will sign a supplementary agreement as soon as possible.
Article 30 The contractor shall perform the duties and obligations stipulated in the contract of supervision. If there is a breach of contract, the company shall compensate the economic losses caused by the breach of contract to the supervisor.

Supervisor's rights

Article 31 The supervisor has the following rights:
1. Select the right to propose the construction, equipment and materials supply.
2. The right of confirmation and denial of the subcontracted items and subcontracting units selected by the contractor.
Third, assist the contractor to sign the construction contract.
4. The right to review and confirm the design files of the project construction. Only the engineer's drawings and design files that have been reviewed and confirmed by the supervision organization and stamped with the official seal can become an effective construction basis.
5. The approval authority for engineering construction organization design, construction measures, construction plans and construction technical plans.
6. The right to dispose of the design change site within the scope of the amount specified in the terms of the special contract.
7. In accordance with the principles of safety and optimization, make recommendations to the design unit on major technical issues in the implementation of the project and submit a written report to the contractor.
8. Organizing and coordinating the presiding power of the parties involved in the construction of the project.
9. The commencement order, the stoppage order, the rework order and the reinstatement order shall be issued in accordance with the provisions of the project construction contract. The release order and the reinstatement order shall be approved in advance by the contractor.
X. The right to inspect and inspect all parts of the project and any of its processes, materials, components and engineering equipment. However, all the above inspections and inspections do not exempt the contractor from the responsibility of the relevant contract.
11. The construction quality of all projects and the right to inspect and confirm the materials and equipment used in the project; the supervision of safe production and civilized construction.
12. The inspection and supervision of the construction progress of the project and the right to sign the construction contract.
XIII. The right to review and supervise the temporary works designed and constructed by the contractor.
14. The right to review and sign the payment of the project payment, and the confirmation and denial of the settlement of the project settlement. The contractor does not pay any construction money without the signature of the supervisory authority.
15. The right to request the contractor to remove incompetent on-site construction and management personnel.
16. The right to request the contractor to increase and replace the construction equipment, and the increased costs and delays of the construction period shall be borne by the contractor.

Employer’s rights

Article 32 The right to inspect the supervision work of the supervision organization and the supervision personnel in accordance with this contract.
Article 33 The right to select engineering design units and contractors.
Article 34 There is the right of examination and approval of engineering design changes. The final decision on major issues in quality, progress and investment in the construction of the project.
Article 35 The final decision on payment and settlement of construction funds shall be made.
Article 36 The supervisor shall replace the chief management engineer with the prior consent of the contractor and have the right to request the supervisor to replace the incompetent supervisor until the contract is terminated.
Article 37 The right to request the supervisor to submit the special report within the scope of the supervision monthly report and the supervision project.

Contract effective, changed and terminated

Article 38 This contract shall terminate upon the expiration of the supervision period and the settlement of the supervision remuneration.
Article 39 For the reasons of non-supervisor, the increase of the supervision workload and the extension of working hours shall be regarded as additional work of the supervision institution. The supervisor has the right to request additional compensation and extend the time limit accordingly. :
1. Due to non-supervised reasons such as the contractor, the contractor and force majeure, the supervision work is hindered or delayed, resulting in an increase in the supervision workload or duration.
2. During the performance of this contract, the Employer requires the Supervisory Authority to complete work outside the scope of the contract of supervision.
3. When the supervision business is suspended or terminated due to non-supervising reasons, it will work after the recovery or resume the supervision business.
Article 40 When the relevant laws, regulations, rules and standards of the country to which this contract applies are changed, the signing parties shall make corresponding adjustments and changes to the relevant provisions of the contract including the compensation of the supervision after full negotiation.
Article 41 In the course of supervision, if the circumstances change, the contract must be changed, and both parties must agree to sign the change contract or supplementary agreement. Solutions to problems such as costs incurred by changes should be clarified in the change contract or supplemental agreement.
Article 42 When the contractor or supervisor requests to terminate the contract, it shall notify the other party in writing 56 days in advance. If the reply of the other party is not received within 28 days after the notice is delivered, the notice of termination of the supervision contract may be issued 14 days thereafter. This contract is terminated. If the loss is caused by the termination of the contract, the responsible person shall be responsible for compensating for the loss, except that the liability may be exempted according to law.
Article 43 During the term of this contract, due to major adjustments or force majeure of the construction project design, the project shall be suspended in whole or in part until the contract has to be terminated, and the contract shall be notified in writing by the contractor to terminate the contract. termination. Both parties should negotiate to resolve the remaining issues arising from the termination of the contract.
Article 44 When the contract is terminated due to the responsibility of the supervisor, the supervisor has no right to obtain the fees for failing to perform the supervision.
Article 45 The termination of this contract does not affect the rights and responsibilities of the parties.

Default action

Article 46 The contractor’s liability for breach of contract and breach of contract.
In the performance of this contract, the following behavior of the contractor is a breach of contract:
1. Failure to perform the obligations stipulated in Articles 22 and 23 of the General Contract Terms.
2. The supervisory remuneration is not paid within the time limit specified in Article 48 of the special contract clause.
For the above-mentioned breach of contract, the contractor shall be liable for breach of contract, paying the liquidated damages or compensation to the supervisor according to the terms of the special contract, thus causing economic losses to the supervisor.
Article 47: The supervisor shall be liable for breach of contract and breach of contract.
During the performance of this contract, the following actions of the supervisor or the supervisory agency are breach of contract:
1. Failure to perform the obligations and responsibilities of Articles 8, 9, and 11 of the General Contract Terms.
2. The Supervisor no longer has the ability to undertake the supervision business of the Project and terminate the contract, or cause significant economic losses to the Employer due to the supervision accident.
For the above-mentioned breach of contract, the supervisor shall bear the liability for breach of contract and, according to the terms of the special contract, direct the contractor to pay liquidated damages or compensate for economic losses.

Supervision compensation

Article 48 The remuneration of normal supervision business shall be calculated according to the method stipulated in the terms of the special contract, and the consignor shall pay according to the time limit and method stipulated in the terms of the special contract.
Article 49: The supervisor shall, according to the requirements of the contractor, complete the additional remuneration for the completion of the additional supervision work, or the remuneration due to the extension of the construction period, shall be calculated according to the method agreed in the supplementary supplementary agreement or the special contract clause, and the payment method and time limit. It should be carried out in accordance with the provisions of normal supervision and remuneration.
Article 50 The contractor shall not pay the supervision remuneration within the agreed payment period, and shall pay the late payment fee or interest from the date of the agreed payment to the date of the actual payment.
Article 51 If the contractor disagrees with the remuneration item in the notice of payment of supervision remuneration submitted by the supervisor, it shall, within 7 days after receiving the notice of payment from the supervisor, issue a notice of dissent to the supervisor, which shall be settled through negotiation between the two parties. No objection, payable in accordance with the provisions of Article 49 of the General Contract Terms.

other

Article 52 If the supervisory personnel must go abroad for inspection within the scope of the supervision business, the expenses shall be reported to the contractor for reimbursement by the contractor.
Article 53 In the scope of supervision business, if the supervision organization needs to hire another expert for consultation or assistance, the expenses shall be borne by the supervisor; the consultation and assistance outside the scope of supervision shall be borne by the contractor with the consent of the contractor. .
Article 54: Due to the rationalization proposals put forward by the supervision organization in the process of supervision, the contractor shall obtain direct economic benefits, and the contractor shall give the supervision institution reasonable incentives.
Article 55 Within 56 days after the entry into force of the supervision contract, the supervisor shall handle the insurance in accordance with the types stipulated in the terms of the special contract and submit a copy of the insurance contract to the contractor. The conditions of the insurance contract shall be in accordance with the contract.

Settlement of Disputes

Article 56 A dispute arising from this contract shall be settled by both parties through negotiation; it may also be settled by the competent project department or the industry contract dispute mediation agency; if the negotiation or mediation fails, both parties agree to be arbitrated by the arbitration commission; the parties are not in this contract. If the arbitration institution is contracted and fails to reach a written arbitration agreement afterwards, it may file a suit in a people's court.
Article 57 In the process of negotiation, mediation, arbitration or prosecution of disputes, the two parties shall continue to assume their respective responsibilities and obligations as stipulated in the supervision contract to ensure the normal operation of the project.

Dedicated contract clause

Applicable laws, regulations, rules and supervision basis

Article 3 The national laws, administrative regulations and departmental rules applicable to this contract, as well as local laws and regulations, are: ________________.
Article 4 The basis for supervision of this contract is: ________________.

Supervisor's duties and responsibilities

Article 8 The supervisor shall submit to the Employer a list and resume of the supervision plan, the supervision organization, and the appointed chief engineer and main supervisor within ____ days after the contract is effective.
Article 9 The supervision scope of the supervisor is: ________________.
Supervisor's supervision work and main measures: _________________________________________
The supervisor shall dispatch the supervisory personnel to the construction site within ____ days after the supervision contract takes effect.
Article 13 The key parts of the project that need to be supervised by the station are: ________. The key process that requires side station supervision is: ________.
Article 16 The supervision institution shall use the equipment, facilities and articles of work and living conditions provided by the contractor to transfer the contractor within ________ days after the completion of the supervision business or the termination of the contract.
Article 19 The calculation formula for the compensation of the contractor shall be compensated for the direct economic loss of the contractor due to the negligence of the supervisor:
Compensation = direct economic loss × compensation ratio

Contractor’s obligations and responsibilities

Article 23 The contractor shall provide the supervision organization with the engineering construction materials related to the project as follows:

┏━━┯━━━━━━┯━━┯━━━━┯━━━━┯━━━━━━━━━━━┓
┃ No. │ Data Name │ Number of Copies │ Provide Time │ Retraction Time │ Save and Privacy Requirements ┃
┠──┼──────┼──┼────┼────┼───────────┨
┃│││││ ┃
┠──┼──────┼──┼────┼────┼───────────┨
┃│││││ ┃
┠──┼──────┼──┼────┼────┼───────────┨
┃│││││ ┃
┗━━┷━━━━━━┷━━┷━━━━┷━━━━┷━━━━━━━━━━━┛

Article 24 The time limit for the issuer to make a written decision on the matter submitted by the supervisor or the supervisory authority and requesting a decision, and to serve on the supervisor or the supervision institution:
General file ____ days;
Urgent matters, change files ____ days.
Article 26 The necessary working and living conditions provided by the contractor to the supervision institution for free are: ________.
The time provided by the above conditions: ________.
If the supervisor provides, the facilities and equipment that the contractor gives financial compensation are: _____________________________________________.
The way to provide financial compensation for the above facilities and equipment is: ______________.
Article 27 The list of staff and requirements provided by the contractor: ______________________________________________.

Supervisor's rights

The amount of the right to dispose of the design change independently in Article 31, paragraph 6 is: ________.

Default action

Article 46 If the contractor breaches the contract, it shall pay the supervisor the liquidated damages or compensate the economic losses. The calculation method is as follows:
1. Liquidated damages: ________________.
Second, the economic loss: ________________.
Article 47 If the supervisor breaches the contract, he shall pay the contractor’s liquidated damages and compensate the economic losses.
1. Liquidated damages: ________________.
Second, the economic loss: ________________.

Supervision compensation

Article 48 The parties agree to calculate and pay the supervision fee as follows:
1. The composition, calculation method and calculation formula of supervision remuneration are: ________________________________________________.
Second, the adjustment and adjustment methods and calculation formulas of supervision compensation are: ________________________________________________.

Third, the payment method of supervision compensation is: ____________________.
4. The payment time for supervision compensation is: ____________________.
Article 49 The parties agree to take the supervision remuneration for additional supervision work as follows: ________________________________________.
Article 50 The interest rate for the issuer to postpone the payment of supervision remuneration to pay the interest to the supervisor is: _______________________________________.

other

Article 54: Awards for Rationalization Suggestions:
First, the calculation method of economic benefits: _____________________.
Second, the calculation method of the bonus amount: _____________________.
Third, the reward payment method: _______________________.
Article 55: Types of insurance that supervisors need to participate in: __________________.

Settlement of Disputes

Article 56: Mediation and Arbitration of Contract Disputes:
1. The mediation body agreed by both parties is: ____________________.
2. The arbitration institution agreed by both parties is: ____________________.
Additional agreement terms: ______________________________________________________________.

Contract attached file

First, the supervision content design aspect 1. Assist the contractor to sign the survey design, scientific research test and construction drawing agreement with the survey design and scientific research unit.
2. Manage the relevant contracts and agreements signed between the contractor and the designer, and urge the designer to supply qualified design files in time according to the requirements of the contract and the agreement.
3. Familiar with the design file content, review whether the design file meets the approved design task book and the original approval opinion, and whether it meets the survey design contract.
4. On behalf of the contractor to verify the design file and various design changes, suggestions and optimization recommendations.
5. Timely issue design files to the construction person, find problems in time to contact the designer, and report major issues to the contractor.
6. The organization designer will carry out the on-site design.
7. Assist the contractor to discuss the major technical issues and optimization design with the designer.
8. Review the constructor's comments and suggestions on the design folder, conduct research with the designer, and urge the designer to give a reply as soon as possible.
9. On behalf of the contractor, the design file submitted by the constructor shall be reviewed in accordance with the project construction contract file.
10. Keep all design files and process materials.
11. Other related businesses.
Procurement aspect 1. Assist the contractor in the procurement bidding work.
2. Manage procurement contracts and monitor and control the progress of procurement plans.
3. The equipment supervises and prompts the main permanent engineering equipment.
4. Assist or on behalf of the Employer to carry out quality inspection and arrival inspection of the permanent engineering equipment entering the site.
5. Other related businesses.
Construction aspect Assist the contractor in project bidding and sign the construction contract.
2. Comprehensively manage the project construction contract and review and approve the qualifications of the subcontractors selected by the constructor.
3. Supervise the contractor to implement the construction conditions that must be provided in accordance with the provisions of the project construction contract, inspect the construction preparation work of the construction unit, and issue a project start-up order after passing the inspection and examination.
4. Approving the construction organization design, construction progress plan, construction technical measures, operation procedures, process test results, temporary construction design and raw materials used by the contractor.
5. Issue supplementary design files, technical specifications, etc., and answer suggestions and opinions from the construction unit.
6. Project schedule control: According to the overall progress of the project construction contract, prepare the control progress target and the annual construction plan, and review and approve the construction implementation progress plan proposed by the constructor and check its implementation. Supervise the construction workers to take definite measures to achieve the target requirements of the contract. When there is a large deviation in the implementation progress, the proponent is advised to adjust the control progress plan in time, and the adjustment of the progress plan is completed after approval by the contractor.
7. Construction quality control: review the quality assurance system and measures of the construction unit, verify the quality file; inspect the whole process of the construction according to the project construction contract file, design file and technical standards, and track and supervise the important project parts and main processes. Based on the unit project, according to the requirements of the Ministry of Water Resources “Water Quality and Hydropower Infrastructure Engineering Unit Quality Assessment Standards” and “Water Conservancy and Hydropower Engineering Construction Quality Assessment Regulations”, the engineering quality grades assessed by the construction unit will be reviewed.
8. Project Investment Control: Assist the contractor to prepare investment control targets and annual investment plans; review the capital flow plan submitted by the construction unit; review the construction quantity and unit price of the construction unit, and issue measurement and payment vouchers to accept the claim; Conduct claims investigation and negotiation, and put forward handling opinions; handle engineering changes and issue engineering change orders.
9. Construction safety supervision: check construction safety measures, labor protection and environmental protection measures, and make recommendations; check flood control measures and make recommendations; participate in major safety accident investigations.
10. Presided over the coordination of the construction of the project within the scope of the authorization of the supervision contract, and prepared the minutes of the construction coordination meeting.
11. Assist the contractor to carry out the acceptance and completion acceptance of the project at the various stages according to the state regulations, and review the completed drawings and materials prepared by the design unit and the construction unit.
12. Information management: Do a good job in construction site record and information feedback; prepare supervision month and annual report according to the requirements of the supervision contract subsidiary file; reorganize project data and project files on time, do daily management of texts, records, forms and orders, and when the time limit expires Hand over to the contractor.
13. Other related work.
Second, the supervision organization shall provide the information and archives provided to the contractor. The main contents of the monthly supervision report monthly report supervision report:
1. Project Overview: Includes project location, main features of the project and a brief description of the contract.
2. Memorabilia.
3. Project progress and image.
4. Funds are in place and used.
5. Quality control: including quality assessment, quality analysis, quality incident handling, etc.
6. Contract implementation: including contract changes, claims and defaults.
7. On-site meetings and correspondence: including minutes of meetings, correspondence.
8. Supervision work: including the supervision organization's block diagram, resource input, important supervision activities, drawing review, issuance, technical program review, engineering needs to solve problems and other matters.
9. Construction personnel: including the dynamics of labor, equipment invested, organization management and existing problems.
10. Safety and environmental protection.
11. Progress payment.
12. Project progress picture.
13. Other: including natural conditions such as hydrology and meteorology.
Unscheduled supervision work report 1. Suggestions on engineering optimization design and engineering changes.
2. Investment analysis and forecasting, and rational allocation of funds and resources and recommendations for investment.
3. Project progress forecast analysis report.
Daily supervision file Supervisory diary and construction memorabilia.
2. The construction plan approves the file.
3. Construction measures approved the file.
4. Construction schedule adjustment and approval of files.
5. Progress payment payment confirmation file.
6. Claims are accepted, investigated and processed.
7. Supervisory coordination meeting minutes file.
8. Other supervisory business transactions.
Number of copies submitted by the file: ________.