[Boutique] Engineering Contracting Agreement

Part 1: Engineering Contracting Agreement

Party A:

Party B:

Contract signing place:

According to the "Contract Law of the People's Republic of China", the "Building Law of the People's Republic of China" and other relevant laws, regulations, rules and regulations, the two sides follow the principle of equality, voluntariness, fairness and good faith, and agree on this item and conclude an agreement. Follow the implementation together.

I. Project Overview

1. Project Name:

2. Project location:

Second, the scope and content of the project:

Quantity of work:

Contract form:

Third, the construction period:

1. Start date:

2. Completion date:

3. The total contract period is the working day. During the special weather that cannot be resisted by continuous heavy rain during the period, after the signature of Party A and the supervisor, the construction period can be postponed accordingly.

Fourth, the quality standards use the following:

1. The project quality has reached the provincial excellent to Luban Award;

2. The engineering quality assessment grade is excellent;

3. In line with national quality acceptance criteria;

4. The standards agreed by both parties are as follows:

V. Contract price

The following methods are used to settle the price of this contract:

1. The fixed price method with a one-time total package price, the total price is, and now involves engineering changes and increased engineering volume, and the increase is partially settled. If the change is increased within 5%, the two parties will not sign a supplementary agreement. If the change exceeds 5%, the two parties shall sign a supplementary agreement. 2. Settle according to the actual amount of work. And follow the following conventions:

Project budget price:

Project unit price:

According to the actual amount of engineering, combined with the relevant engineering quota standards of Jiangsu Province, Party B shall report the final price, which shall be confirmed by the accounting firm or audit after the supervision and Party A's review.

All engineering quantities must be submitted by Party A to Party A before submitting monthly statistical reports or completed engineering quantity reports, subject to supervision and approval by Party A.

In the case of engineering changes and increased engineering volume, the person in charge of the project shall issue an order. The change visa shall be signed by the supervisory party and signed by the engineering department of the party and the relevant project leader, and on the actual date of occurrence. Within 15 days, the person in charge of the Party A Department of Planning and Finance will review the signature, and the signature of the leader in charge of Party A, and finally the approval by the general manager will take effect. Otherwise, Party A has the right not to accept it.

The amount of the changed project is within 5% of the total contract price, and no additional contract is required. If it exceeds 5%, a separate contract must be made.

The standard and description of the fee collection: the earthwork quantity measurement implements the provincial and municipal standards for earth and stone acceptance, and the earthwork volume is settled according to the actual situation.

Description of the confirmation method of engineering quantity accounting: Completion of the qualified workload is reported to Party A for review and approval, and the preparation of the statistical report is reported to the supervisor, and the supervision and the confirmation of Party A can be obtained.

Once the contractual agreement is signed, it is not affected by changes in market prices, and is settled according to the contract and the agreed standards.

Sixth, payment method

1. The budget for this project is:

The way to deduct the project advance payment is:

2. The project payment is paid according to the method, specifically:

There is no advance payment for this project;

According to the monthly completion of the engineering quantity statistics report, after the supervision and Party A's review and confirmation, the % of the completed completed project payment shall be paid;

The % of the total construction cost is used as the quality guarantee. If there is no quality problem and other breach of contract, it will be paid to Party B. On the contrary, if there is any quality problem and other breach of contract, Party A has the right to directly deduct Party B's warranty. If the loss caused to Party A exceeds the amount of the warranty, Party B shall still be compensated for the excess.

Seven, materials, equipment supply:

Eight, quality and acceptance

1. The quality of the project must comply with the standards stipulated in Article 4 of this Agreement and be implemented in accordance with the current national acceptance criteria. The quality guarantee period, if the project involves the main structure, should be guaranteed for life.

2. The project manager must hold the post certificate issued by the Provincial Construction Committee, and the number of projects under construction must not exceed two. The project manager is not less than an hour at the time of the site and is responsible for handling related matters in the project.

3. All the participants of Party B shall not be exchanged without the approval of Party A. If it is necessary to replace, Party A shall apply in writing to Party A 3 days in advance. Otherwise, Party B shall have the right to terminate the contract if Party B arbitrarily exchanges personnel for 30%. Party B withdraws unconditionally.

4. The project quality acceptance must be carried out in accordance with the specifications. All project materials must be synchronized with the project construction, and should be available for inspection by relevant departments and personnel at any time.

5. The acceptance of the sub-process and the acceptance of the concealed project must be signed and accepted by Party A and the supervisor before the next process can be carried out.

6. Party A and the supervisor shall complete the acceptance inspection within the hour after receiving the inspection report from Party B and issue a written acceptance opinion. Party A usually checks the quality regularly or irregularly, and issues a written rectification notice within a time limit. Party B must rectify within a time limit according to Party A's request. If the quality problem is found repeatedly, or if it has not met the requirements after two rectifications, Party A has the right to pay liquidated damages according to the situation, and is severely ordered to leave the company. All losses are the responsibility of Party B.

7. After completion, Party B shall notify Party A and the supervisor for acceptance in writing, and Party B shall provide the as-built drawings and all completed materials in compliance with the normative requirements within one day after completion, and shall be in one copy.

8. Other agreements: According to the drawings, the construction shall meet the requirements of Party A and the supervision, and it is forbidden to spill or dump.

Nine, construction organization and construction period

1. Party B shall submit a written construction organization plan to Party A within three days after receiving the official construction drawings of Party A. Party B shall handle the relevant work procedures and other relevant procedures on its own. Party A shall review and approve the construction plan of Party B and arrange the technical drawings.

2. Party B must organize the construction according to the contract construction period and the approved progress plan, and accept Party A and the supervision to supervise and inspect the progress of the project. When the actual progress of the project does not conform to the plan, Party A and the supervisor have the right to order the improvement within a time limit. Party A and the supervisor shall, at the request of Party A and the supervisor, submit the corrective measures to Party A and the supervisors for examination and approval, and Party B shall pay for the work during the period. Party A has the right to suspend the payment of the project payment when the monthly progress is obviously behind the progress plan. If Party B is obviously unable to complete the work according to the agreed construction period, Party A has the right to change the construction team. Party B shall withdraw unconditionally within 10 days after the notice of withdrawal from Party A, and withdraw all personnel and equipment. The project amount shall be completed according to the actual amount of work completed. If payment is made, Party A will not pay any amount. If the company delays the payment of liquidated damages for 2 days of the total construction cost, and causes other losses, it should be fully compensated.

3. Project Manager: On-site representative:

Supervisor: On-site representative:

4. Agreement on water, electricity, accommodation, tools and other facilities during construction: Party B shall solve it by itself.

X. Safety and civilized construction and management

1. Party B shall strictly implement the relevant safety operation management regulations.

2. No identity card, bad track, physically disabled person or child labor may be enrolled. Otherwise, the consequences are at your own risk.

3. Special projects need to hold the employment certificate issued by the labor department and hold the certificate.

4. In the event of a work-related accident or other internal dispute arising during the construction process, Party B shall handle it and bear all economic responsibilities.

5. All mechanical equipment must meet the construction needs, and special equipment must have security inspection certificate.

6. Party B shall carry out standardization management of construction sites in accordance with the regulations of the relevant departments of the local government. Party B shall bear all penalties and losses caused by the failure of standardization management.

7. Party B shall give priority to the payment of construction workers' wages, shall not default, and handle labor disputes and related problems. It shall not affect the construction and shall not cause any adverse effects to Party A. Otherwise, Party A has the right to cancel the contract and order the exit. Compensation for losses, requests for payment of liquidated damages, etc.

XI. Party A’s responsibility

1. Provide drawings and materials as agreed, and carry out technical drawings.

2. Party B shall pay Party B to pay the project payment according to the contract. If Party A cannot timely cash due to financial difficulties, it shall negotiate with Party B and, according to different circumstances, pay Party B the interest of bank loan on the part of payable.

4. Perform other obligations as stipulated in this Agreement and be responsible

12. Party B’s responsibility

1. Complete the construction tasks according to the agreed quality and quantity, in line with the construction period and quality requirements.

2. Party A must obey Party A's on-site management, abide by laws and administrative regulations, abide by various rules and regulations, and maintain Party A's reputation. If it discovers that it intentionally damages its reputation, seriously violates discipline, and violates the contents of the agreement, Party A has the right to impose economic punishment. Until the contract is terminated.

3, should pay attention to the protection of the ecological environment, pay attention to construction safety, not cutting trees and damage other facilities, pay attention to forest fire prevention.

4. Party B shall not stop work or passively absent from work for any reason, and take unreasonable means such as noisy or threatening. Otherwise, Party A has the right to order it to withdraw, and all consequences shall be borne by Party B.

5. If quality problems occur during the warranty period, Party B shall enter the site for repair within the day of receiving the telephone or written notice from Party A. The maintenance within the day is completed, otherwise the maintenance fee shall be deducted from the warranty.

6. Party B shall take the initiative to conduct quality follow-up visits to the project in accordance with relevant regulations.

7,

XIII. Liability for breach of contract

1. Both parties shall strictly abide by the agreement. If there is any violation, they shall be liable for breach of contract in accordance with the relevant provisions of this Agreement.

2. If the construction period is delayed, for each more than one day, the liquidated damages shall be paid according to the total contract price, or the liquidated damages shall be paid to Party A by 1000 yuan per day.

3. In case of quality problems and violation of other agreements in this Agreement, Party B shall, in addition to compensating for all economic losses caused to Party A, Party A may require Party B to bear liquidated damages at 1%-10% of the total contract price, depending on the specific circumstances. .

XIV. Supplementary provisions

1. This Agreement shall become effective upon signature by both parties.

2. This Agreement is signed on the day of the month.

3. Once this Agreement is signed, both parties shall strictly abide by it. If there is a dispute arising from the implementation of this Agreement, the two parties shall resolve it through consultation. If the negotiation fails, the people's court at the place where the contract is signed shall make a ruling.

4. This Agreement is in duplicate and each party has the same legal effect.

person A person B:

Legal representative: Legal representative:

Authorized representative: Authorized representative:

Year, month, day, month, day

Part 2: Engineering Contracting Agreement

Employer: ________________________________

Address: ____________ Postal Code ____________ Phone____________

Legal representative: ____________ Position ____________

Contractor:________________________________

Address: ____________ Postal Code ____________ Phone____________

Legal representative: ____________ Position ____________

In accordance with the "Contract Law of the People's Republic of China" and the relevant provisions of the ________ city, this contract was signed by both parties and was strictly implemented.

First project

First, the project name: ________________

Second, the project location: ________________

Third, the project number: ________________

4. Project scope and content: The total construction area of ​​the project is ________ square meters.

V. Project cost: The construction cost of all construction drawings is RMB ________ yuan, of which: labor costs ________ yuan.

Second project deadline

I. Date of completion: According to the quota of the period of time promulgated by the State, the contract completion date is as follows:

All projects were started from ________________________________________________________________________________________________________________________________________________________________________

2. The preparatory work before the construction shall be completed by the parties in accordance with the provisions of Article 3 of the Engineering Agreement.

3. During the construction process, the construction period may be extended in the following cases. The extension of the time limit shall be negotiated by both parties in a timely manner, and the agreement shall be signed and reported to the relevant department for the record.

1. Those who are forced to stop working due to irresistible human resources;

2. If Party A changes the plan or changes the construction drawing, it cannot continue the construction;

3. Because Party A cannot supply drawings, supplies, equipment or required materials, equipment is not suitable, and is forced to stop work or can not smoothly construct.

Article 3 Material supply

1. The materials required for all projects shall be handled in accordance with the following first supply methods:

1. Special materials, integrated pipe materials and mechanical and electrical products of the Department of Distribution are all purchased by Party A and supplied to the designated place of Party B. Other materials are purchased and supplied by Party B.

2. For the overall distribution and departmental materials, Party B shall be responsible for handling the application, ordering, adjustment and use, special materials and mechanical and electrical products of the department and department, and Party A shall be responsible for purchasing and supplying to the designated place of Party B. Other materials shall be purchased by Party B. supply.

3. The contractor does not include the project, and all materials and equipment are purchased and supplied by Party A to the site or designated processing location.

4. Other ways:

2. Party A shall be responsible for the variety, specifications, quantity and entry period of materials and equipment, as detailed in Party A's supply materials and equipment list.

3. For complete sets of equipment and non-standard equipment, Party A shall be responsible for handling the application, ordering and processing, and Party A shall be responsible for the inspection before the introduction of complete sets of equipment is delivered to Party B.

4. The materials required for the project, if the specifications, varieties or materials of the supply department cannot meet the engineering requirements and must be replaced or processed by other specifications and varieties, the original design unit and Party A shall obtain the prior consent and be signed by the three parties. . The amount difference, price difference and processing fee incurred due to substitution or processing shall be settled according to the current regulations.

5. Any material that should be accompanied by a certificate of conformity must be verified by the supplier when entering the site; if there is no certificate of conformity, it must be used after the supplier has passed the test, and the test cost shall be borne by the supplier. As the construction unit or design unit requires retesting the materials with the factory certificate of conformity, the test cost shall be borne by Party A.

6. If the materials and equipment that Party A is responsible for supplying, if it is not delivered on time or the specifications and quality do not meet the requirements, it will not be solved by the efforts of both parties. Therefore, Party B’s losses shall be borne by Party A.

Article 4 Settlement of construction funds

1. The settlement method of all project cost. According to the following provisions:

1. Settle the budget of the construction plan after the review plus the increase or decrease of the change budget.

2. According to the construction drawing budget plus the dry-coefficient coefficient, the package cost is settled, and the expenses outside the scope of the package are covered;

3. According to the standard construction drawing, the unilateral cost will be settled, and the expenses outside the scope of the package will be paid according to the relevant regulations.

4. The contractor does not include the project, and the labor fee is set according to the budget quota.

5. The project of bidding shall be settled according to the price of the winning bid.

2. The method of disbursement and settlement of project funds shall be handled in accordance with the current regulations.

Article 5 Construction and Design Changes

1. Party B shall organize the construction according to the construction acceptance specifications and quality inspection standards and design requirements issued by the State, and all shall be qualified.

Second, we must adhere to the construction according to the map, and no party may change the design at will. In the case of the following circumstances, the other party shall be responsible for the loss of work, rework, backlog of materials and components, construction strength and mechanical transfer, and shall be borne by the responsible party:

1. If any design is found to be wrong or seriously unreasonable during construction, Party B shall notify Party A in writing, and Party A shall agree with the original design unit within 7 days to propose to modify or change the design file, and sign the agreement between Party A and Party B. After that, the construction is accurate.

2. During construction, if the design change exceeds the original design standard or scale, it should be re-approved according to the approval procedure before construction. After reviewing the project budget by the review office, the bank will review the investment and the agreement will be signed by both parties. Can be constructed. Otherwise, no one may force the construction.

3. During the construction, if the construction is suspended or slowed down in the middle of the construction, both parties shall make a custom-made project to the safety site.

4. During the construction, if Party A is found to be under-invested, the project progress payment cannot be paid on time, and the construction will be suspended or slowed down, and the losses caused to Party B shall be borne by Party A.

3. Party B shall strictly implement the concealed project acceptance system. After the concealed project is completed, it must be recorded and accepted before proceeding to the next process. The general concealed project shall be inspected and accepted by Party B itself, and records shall be made. For major or complex concealed works, Party B shall notify Party A and the design unit in writing to jointly accept and accept the concealed works acceptance procedures. If Party A does not participate at that time, Party B may check and accept it by itself, and Party A shall acknowledge it.

4. Both Party A and Party B shall encounter construction projects in the course of construction and shall submit the approval according to the quota management method. The change budget attached to the change of the engineering agreement shall be sent to the bank in time for construction as the basis for settlement of the project.

Article 6 Completion Acceptance, Settlement and Warranty

1. Party B shall notify Party A of the acceptance date in writing 5 days before the completion of the individual project. If Party A fails to participate in the acceptance on time, Party B shall notify Party B in advance to obtain the consent of Party B, and the acceptance date shall be separately set, but Party A shall acknowledge the completion. If the date is not accepted, the management fees and losses incurred by Party A shall be borne by Party A. And pay the overdue liquidated damages of Party B to one-tenth of the daily cost of the budget.

2. The completion acceptance of the completed project shall be completed within 3 days from the date of acceptance. If Party A fails to take over as scheduled, causing losses in the project after acceptance, Party A shall bear the responsibility.

3. If the unit project in this project is to be handed over to Party A separately, at the time of handover, both parties shall go through the intermediate acceptance procedures as the basis for the acceptance of the completion project of the unit.

4. In the completion of the completion of the project, if the quality of the project is found to be inconsistent with the regulations, Party B shall be responsible for the repair or rework without compensation, and shall be completed within the agreed measures and deadlines. After the experience is accepted, the transfer will be made. If the project is overdue, Party B shall reimburse Party A for overdue liquidated damages of one-tenth of a million per day of the budget.

5. The project has been basically completed. If a certain material or equipment cannot be resolved, the project cannot be completed on schedule. With the consent of both parties, the project can be completed and reduced, and the completion and acceptance of the completed project will be completed. formalities.

6. Acceptance of completion projects shall be based on the construction acceptance specifications issued by the State, the technician inspection standards and the construction drawings. In the case of completion acceptance, Party B shall provide Party A with the following files 10 days before the acceptance:

1. Increase or decrease the change file and other negotiation records;

2. Concealed project acceptance records and intermediate delivery acceptance records;

3. After the completion of the project, the as-built drawings shall be drawn. The construction unit shall make a description of the construction change on the original construction drawing and submit it to the construction unit for filing. If the project changes greatly, the construction unit may draw or commission the design unit or the construction unit to draw the as-built drawings.

7. After the completion and acceptance of the individual project, Party B shall belong to the industrial construction project within 15 days after the completion of the acceptance of the civil construction project. The completion settlement shall be sent to Party A for review within 30 days after the completion acceptance. Party A shall, after receiving the completion settlement, within 15 days of civil construction, the industrial construction shall be reviewed within 20 days. If no objection is filed at the expiration date, the appropriation bank shall approve the appropriation.

8. After the project is completed and accepted, Party B shall be responsible for one year's warranty on the quality of the civil works for construction, and the first heating period for the heating project. During the warranty period, Party B shall be responsible for free repairs due to quality accidents such as roof leakage, pipeline leakage, air leakage and blockage caused by the responsibility of the construction unit.

9. If the project is not experienced, Party A shall use it in advance or use it automatically. Party A shall be responsible for the quality or other problems arising therefrom.

Article 7 Liability for breach of contract and arbitration

1. Since Party B's liability is not completed according to the date stipulated in this contract, every one day overdue shall be repaid to Party A for overdue liquidated damages of one ten-thousandth of the budget; for those who are not covered by the contractor, they shall be repaid to each other for one day. Overdue liquidated damages of two thousandths of the budget labor costs.

2. Party A and Party B shall not owe all kinds of payables for any reason, such as delaying payment, and repaying the default payment of overdue payment according to the bank's short-term loan interest rate.

3. If the rationalization proposal award and the advance completion award are implemented, both parties shall agree separately according to the relevant policies.

4. In the event of a dispute over the contract for the construction and installation project, both parties shall consult in time. If the negotiation fails, either party may apply to the urban and rural construction committee at all levels or the competent department of the higher authorities at both levels for mediation; if it cannot be resolved, the following may be selected. Item handling: Apply to the Arbitration Commission of the building where the building is located for arbitration and directly file a lawsuit with the people's court.

Article 8 Supplementary Provisions

1. In the case of budget review, the construction unit shall submit the construction and installation project contract to the municipal construction project contract budget review office for review. If it is required for attestation, it may go to the district or county administration for industry and commerce at the location where the building is located for verification.

2. Before the signing of this contract, the construction preparation contract signed by both parties may be used as an auxiliary file of this contract.

3. The bidding project shall be signed in accordance with the “Temporary Measures for Bidding and Tendering of Construction Projects in XX City”.

4. Other matters agreed by the parties:

Article 9 Contract Attachment File

First, the list of engineering projects.

Second, all construction drawings.

Third, the construction drawing budget.

4. A list of materials and equipment that Party A is responsible for supplying.

V. Relevant agreements:

6. Relevant supplementary contract:

Article 10 Copies and Validity Period

1. This contract is a ____ copy, and both parties shall submit one copy and submit a copy to the competent authorities of both parties.

2. This contract shall become effective on the date of signing by both parties. It expires after all projects have been completed and accepted and settled.

Construction unit:____________________

Project leader: ____________________________

____year month day

Construction unit: ____________________

Project leader: ____________________________

____year month day

Part 3: Engineering Contracting Agreement

I. Project Overview

Construction scope: roof waterproof construction

Main contents of construction:

1. Remove the aging waterproof layer that partially foams and falls off;

2. Install the venting hole;

3. Make modified asphalt waterproofing membrane;

4, the daughter wall to do polyurethane waterproof coating.

Second, the preparation instructions:

Basis for preparation: According to Party A’s intention.

Building Party B Quality Management Regulations XX Edition

According to the national gt19250-XX standard

Construction Engineering Project Management Specification g/t50326—XX

"Consolidation Standard for Construction Engineering Quality Inspection and Evaluation" cg301-88 safety regulations and regulations.

Third, construction deployment:

Construction preparation

The project leader and the five major members will form the backbone construction volume. The special roofing waterproofing personnel have a wealth of various waterproof construction skills and practical experience. They are familiar with the specific technology and scope, and have strong modern management awareness and legal concepts. It can be carefully constructed with the project manager of Party A as the core, achieving the goal of quality, speed and safety.

Formulate a strict management system: the construction force is prepared, and according to the principle of separation of labors in the project management group, our company assigns management personnel with rich experience in construction management to the project, and draws skilled workers from the company to form skilled workers. The hard-working construction team will sign the labor contract to clarify the responsibilities, rights and interests of both parties; promote a multi-functional, multi-job, and ensure the smooth construction of the project.

Material preparation: Before the project starts, our company prepares qualified products that meet the requirements of quality environment and occupational health and safety.

Labor force preparation:

1) Construction mobilization and delivery, we make full use of the pre-commissioning time before the start of construction, and carry out the pre-construction mobilization and technical delivery work for the construction personnel, management personnel and staff of this project. After the mobilization and delivery, the construction personnel understand the basic construction. The situation, clear construction characteristics, and precautions, do a good job in mind, improve thinking and understanding, and work hard to ensure that tasks are completed according to quality.

2) Labor implementation, guarantee measures

1 According to the construction plan and implementation requirements, implement the arrangement and organize the labor force in advance, and establish the corresponding organization leadership system and management guarantee system.

2 After the implementation of the above-mentioned demand plan, the construction labor arrangement plan should be prepared separately, so that it can be called at any time when necessary, as a necessary measure to ensure the contract period.

3 Make full consideration of the living and logistics conditions of the construction personnel, including accommodation, communication, food, accommodation, and seasonal changes in the sanitation, so as to ensure that they are fully engaged in the work to ensure the construction progress and management needs.

Construction sequence and treatment:

Remove the local foaming, the falling waterproof layer to repair the roof cracking and the installation of the vent hole in the artificial damage to clean the roofing brush base treatment agent once to do the modified asphalt waterproof membrane daughter wall to make polyurethane waterproof coating.

Inspection and acceptance of roof waterproofing engineering quality:

After the construction of the waterproof layer is completed, it is necessary to carry out inspections. There must be no bulging, wrinkling, glue falling and large shelling. The surface layer is beautiful and practical to achieve a good waterproof effect and ensure the waterproof life of the project.

Fourth, finished product protection:

The construction personnel should carefully protect the completed waterproof layer and prevent the construction equipment and building materials from damaging the waterproof layer.

Do not allow dust and debris to block the size of the nozzle and drainage parts to ensure unimpeded drainage.

V. Quality Assurance Measures:

It is necessary to check the roof waterproofing layer for damage and puncture. It is especially important to note that once it is damaged, it must be replaced or repaired according to the damage program, and no hidden dangers will be left.

It is necessary to strengthen the awareness and skills of the finished product protection. During the construction, attention should be paid to the finished product protection at all times.

The construction site must be equipped with fire-fighting facilities and the fire-fighting roads are smooth.

VI. Construction period: The roof waterproofing is 15 days, which is calculated from the date when the Party project notice has conditional construction.

Seven, project quality:

Ensure that you are qualified and strive for excellence.