[Boutique] engineering construction agreement

Part 1: Engineering Construction Agreement

Contracting unit: Tuanfeng County Shili Middle School

Contractor: Hubei Hengsheng Construction and Installation Engineering Co., Ltd.

Party A entrusts the construction project to Party B. In order to clarify the safety production responsibility of both parties and ensure the safety of the construction, both parties sign this agreement at the same time as the construction project contract, and both parties must strictly implement it.

First, the project overview:

1. Project Name: Renovation of Student Dormitory in Shili Middle School of Tuanfeng County

2. Project address: within the Tenli Middle School

3. Scope and content of subcontracted projects: student dormitory renovation and ancillary projects

4. Subcontracted form: labor and materials

Second, the project duration:

It will be completed from April 30, XX, to July 26, XX.

Third, the content of the agreement:

1. Both Party A and Party B must conscientiously implement the guidelines and policies on safety production and fire protection issued by the state and superior labor protection and safety production authorities, and strictly enforce relevant labor protection laws, regulations and regulations.

2. Both Party A and Party B should have a safety management organization system, including leaders in charge of safety production, full-time and part-time safety officers at all levels; safety operation rules for each type of work, certification and assessment system for special workers, and safety production at all levels. Post responsibility system and regular safety inspection system.

3. Both Party A and Party B must carefully survey the site before construction:

The project shall be prepared by Party A for the construction organization;

Party B shall prepare the construction organization design according to the requirements of Party A, and formulate targeted safety technical measures. Party B shall strictly follow the construction organization design requirements.

4. The leaders of both Party A and Party B must conscientiously educate their employees on the safety production system and safety technology knowledge, enhance the legal system concept, improve the workers' awareness of safety production and self-protection, and urge employees to consciously abide by safety disciplines and regulations.

5. Before construction, Party B shall organize an on-site safety production education meeting and notify Party A to appoint relevant personnel to attend the meeting. Introduce the rules, regulations and requirements related to safety and fire prevention during construction. Party B must inspect and supervise the construction personnel to strictly abide by and implement them conscientiously.

6. During the construction period, Party B assigns comrades to be responsible for the safety and fire prevention work of the project; Party A assigns comrades to contact and assist to urge Party B to implement relevant safety and fire prevention regulations. Party A should always contact each other. The project assists in checking the safety and fire prevention work in the project and jointly preventing accidents.

7. Party B must strictly implement and comply with Party A's various regulations on fire production management of safety production during construction, and accept the supervision, inspection and guidance of Party A. Party A has the obligation to assist Party B to do a good job in fire prevention management of safety production and to supervise regular inspections. Party B must restrict rectification for the detection of hidden dangers. Party B has the right to require Party A to rectify if Party A violates safety production regulations and systems.

8. In the process of production and operation, personal safety protection products shall be taken care of by all parties. Both Party A and Party B shall urge the construction site personnel to consciously wear safety protection articles.

9. The personnel of Party A and Party B must carefully check the construction area, operating environment, operating facilities, tools and tools, etc., and discover hidden dangers. The construction should be stopped immediately, and the relevant units should implement the rectification and construction. Once construction, the construction unit confirms that the construction site, operating environment, facilities, tools and tools meet safety requirements and are in a safe state. The construction unit is solely responsible for the consequences of the construction process.

10. The mechanical equipment, scaffolding and other equipment provided by Party B shall be inspected and accepted together with Party B in accordance with the regulations before being put into use and installed, and shall be inspected and delivered. It is strictly forbidden to put into use without unexperienced acceptance or unqualified acceptance, otherwise the consequences will be borne by the unauthorized user.

11. All kinds of equipment and tools used by Party B during the construction period shall be prepared by Party B. If both parties are required to borrow and lease from each other, the relevant personnel of both parties shall handle the borrowing procedures. The lender should ensure that the equipment and tools being borrowed meet the security requirements, but the borrower must do their best to verify it. Upon receipt by the user, the storage and maintenance of the equipment and tools, as well as the failure or damage caused by the failure of the equipment and tools, shall be borne by the borrower and shall be liable for compensation.

12. The personnel of both Party A and Party B shall not dismantle or change the scaffolding, various safety protection measures, safety signs and warning signs on the construction site without authorization. If it is determined that the need to remove the change, it must be approved by the person in charge of the construction site and the safety officer appointed by both parties, and take necessary and reliable safety measures before dismantling. The personnel of any party and the consequences of unauthorized removal shall be borne by the personnel and their units.

13. Special operations must implement the “Administrative Measures for the Safety and Technical Training of Special Operators” formulated by the State. After the training and assessment of the special operation safety technical assessment stations of the provinces, municipalities and regions, they will be certified to work and regularly audited according to regulations; The operators of small machinery must do the "fixing and fixing" and the permitting operation according to the regulations; the lifting and hoisting personnel must abide by the "ten no hanging" regulations, prohibit illegal and unlicensed operations; strictly do not understand electrical and mechanical equipment. People, unauthorized use of electrical and mechanical equipment.

14. Both Party A and Party B must strictly implement various fire and explosion prevention systems. Smoking and use of open flames are strictly prohibited in inflammable and explosive places. Fire-fighting equipment is not allowed to be used for other purposes. It is not allowed to use arbitrary equipment and damage theft. The use of open flames requires three levels of fire approval procedures, and the establishment of fire prevention guards, the issuance of guardianship work, and the implementation of guardianship measures. Welders must work with valid documents and are strictly prohibited from operating without a license. In the living facilities, it is strictly forbidden to use electric stoves. It is strictly forbidden to use iodine-tungsten lamps to heat and bake clothes. It is not allowed to use liquefied petroleum gas privately. It is not allowed to pull the wire socket privately, and it is not allowed to smoke in bed. Electric appliances such as rice cookers and electric woks should be used in a designated area designated by Party A. Party A should create conditions to facilitate the use of Party B.

15. Party B shall use the electrical equipment provided by Party A to conduct the test before use. If it does not meet the safety requirements, it shall promptly submit it to Party A. Party A shall actively rectify and rectify and pass the test, and violate this regulation or not. With the permission of Party A, the consequences of unauthorized pulling of electrical lines are the responsibility of the perpetrator unit.

16. Follow the principle of pre-contracting construction. Party A shall not assign Party B personnel to engage in construction tasks outside the contract. Party B shall refuse the construction tasks outside the contract, otherwise the relevant parties shall be responsible for all the consequences.

17. During the construction of Party A and Party B, attention should be paid to the protection of underground pipelines and high and low voltage overhead lines. Party A shall pay a detailed account of the underground pipelines and obstacles. Party B shall implement the requirements for the payment of the balance. If there is any situation, it shall promptly contact Party A and relevant departments to take protective measures.

18. After signing the construction contract, Party B shall consciously go through the temporary residence registration procedures with the public security dispatched office of the temporary residence, and establish the security supervision and inspection department of the labor security bureau and the construction registration formalities with the labor bureau.

19. Implementing the principle of who is responsible for safety, Party B personnel during the construction period, causing casualties, fires, fires, machinery and other accidents, Party A has the obligation to assist in emergency rescue of the wounded, Party B is responsible for accident reporting, economic compensation and aftercare . The loss of the accident and the cost of the aftermath shall be settled by negotiation according to the responsibility.

20. Other:

21. This Agreement shall become effective upon signature by the representatives of both parties: the agreement shall be in quadruplicate as the subsidiary file of the original contract, and Party A and Party B shall each hold two copies, one for each of the security supervision station and the central school.

A method is representative: B method is representative:

Party A Security Officer: Party B Security Responsible:

Part 2: Engineering Construction Agreement

Contractor: Contractor:

For the field road project of the land consolidation project of Paiji Town, the following agreement was reached on the principle of equality and mutual benefit:

I. Responsibilities of the contractor: The contractor shall remove the obstacles in the construction area before entering the site, and provide the contractor with the temporary level and the location and depth of the underground pipeline within the project.

2. Contractor's responsibilities: In the existing roadbed, the road width is 4m, 16cm thick c25砼, and the project reaches the level 4 road standard.

3. Construction method requirements:

1. Equipped with mixing equipment and vibration beams, vibrating rods, channel steel, trowel, generator and pulper required for construction.

2. The ratio of the ratio is required to meet the standard.

3. The vibrating beam and the vibrating rod must be operated in accordance with the standard, and it is forbidden to use and cope with the construction.

4. The pulper and trowel should be smeared on the road surface for 3-4 times. It is forbidden to smear and grout the cement on the road surface.

5. The end of the pulping process is finished.

6. The seaming operation must be carried out within 72 hours after the pouring of the concrete. The cutting seam is required to reach 5cm every 5 meters.

7. If the above does not meet the requirements, the Employer has the right to refuse to pay the construction cost.

4. According to the actual project quantity and on-site visa settlement.

5. The contractor plans to start construction on March 26.

6. The contractor shall carry out the construction according to the technical specifications of the earthwork construction and carry out the construction according to the construction procedures and construction requirements provided by the contractor.

7. When the project structure exceeds the provisions of Article 3, the contractor shall give an on-site visa as the basis for future settlement.

8. For every 10,000 square meters of engineering work completed, 80% of the corresponding project payment will be paid; 80% of the total construction cost will be paid after the completion of the project, and the project payment will be paid after the project is qualified. Responsibilities of both parties: The contractor must ensure that the obstacles within the scope of the project are cleaned up on time and the construction progress of the contractor cannot be delayed.

This agreement is in triplicate and no further matters are agreed upon.

Employer: Contractor:

March 25, 2019

Part 3: Engineering Construction Agreement

Employer: ________________________________

Address: ____________ Postal Code ____________ Phone____________

Legal representative: ____________ Position ____________

Contractor:________________________________

Address: ____________ Postal Code ____________ Phone____________

Legal representative: ____________ Position ____________

In accordance with the "Contract Law of the People's Republic of China" and the relevant provisions of the ________ city, this contract was signed by both parties and was strictly implemented.

First project

First, the project name: ________________

Second, the project location: ________________

Third, the project number: ________________

4. Project scope and content: The total construction area of ​​the project is ________ square meters.

V. Project cost: The construction cost of all construction drawings is RMB ________ yuan, of which: labor costs ________ yuan.

Second project deadline

I. Date of completion: According to the quota of the period of time promulgated by the State, the contract completion date is as follows:

All projects were started from ________________________________________________________________________________________________________________________________________________________________________

2. The preparatory work before the construction shall be completed by the parties in accordance with the provisions of Article 3 of the Engineering Agreement.

3. During the construction process, the construction period may be extended in the following cases. The extension of the time limit shall be negotiated by both parties in a timely manner, and the agreement shall be signed and reported to the relevant department for the record.

1. Those who are forced to stop working due to irresistible human resources;

2. If Party A changes the plan or changes the construction drawing, it cannot continue the construction;

3. Because Party A cannot supply drawings, supplies, equipment or required materials, equipment is not suitable, and is forced to stop work or can not smoothly construct.

Article 3 Material supply

1. The materials required for all projects shall be handled in accordance with the following first supply methods:

1. Special materials, integrated pipe materials and mechanical and electrical products of the Department of Distribution are all purchased by Party A and supplied to the designated place of Party B. Other materials are purchased and supplied by Party B.

2. For the overall distribution and departmental materials, Party B shall be responsible for handling the application, ordering, adjustment and use, special materials and mechanical and electrical products of the department and department, and Party A shall be responsible for purchasing and supplying to the designated place of Party B. Other materials shall be purchased by Party B. supply.

3. The contractor does not include the project, and all materials and equipment are purchased and supplied by Party A to the site or designated processing location.

4. Other ways:

2. Party A shall be responsible for the variety, specifications, quantity and entry period of materials and equipment, as detailed in Party A's supply materials and equipment list.

3. For complete sets of equipment and non-standard equipment, Party A shall be responsible for handling the application, ordering and processing, and Party A shall be responsible for the inspection before the introduction of complete sets of equipment is delivered to Party B.

4. The materials required for the project, if the specifications, varieties or materials of the supply department cannot meet the engineering requirements and must be replaced or processed by other specifications and varieties, the original design unit and Party A shall obtain the prior consent and be signed by the three parties. . The amount difference, price difference and processing fee incurred due to substitution or processing shall be settled according to the current regulations.

5. Any material that should be accompanied by a certificate of conformity must be verified by the supplier when entering the site; if there is no certificate of conformity, it must be used after the supplier has passed the test, and the test cost shall be borne by the supplier. As the construction unit or design unit requires retesting the materials with the factory certificate of conformity, the test cost shall be borne by Party A.

6. If the materials and equipment that Party A is responsible for supplying, if it is not delivered on time or the specifications and quality do not meet the requirements, it will not be solved by the efforts of both parties. Therefore, Party B’s losses shall be borne by Party A.

Article 4 Settlement of construction funds

1. The settlement method of all project cost. According to the following provisions:

1. Settle the budget of the construction plan after the review plus the increase or decrease of the change budget.

2. According to the construction drawing budget plus the dry-coefficient coefficient, the package cost is settled, and the expenses outside the scope of the package are covered;

3. According to the standard construction drawing, the unilateral cost will be settled, and the expenses outside the scope of the package will be paid according to the relevant regulations.

4. The contractor does not include the project, and the labor fee is set according to the budget quota.

5. The project of bidding shall be settled according to the price of the winning bid.

2. The method of disbursement and settlement of project funds shall be handled in accordance with the current regulations.

Article 5 Construction and Design Changes

1. Party B shall organize the construction according to the construction acceptance specifications and quality inspection standards and design requirements issued by the State, and all shall be qualified.

Second, we must adhere to the construction according to the map, and no party may change the design at will. In the case of the following circumstances, the other party shall be responsible for the loss of work, rework, backlog of materials and components, construction strength and mechanical transfer, and shall be borne by the responsible party:

1. If any design is found to be wrong or seriously unreasonable during construction, Party B shall notify Party A in writing, and Party A shall agree with the original design unit within 7 days to propose to modify or change the design file, and sign the agreement between Party A and Party B. After that, the construction is accurate.

2. During construction, if the design change exceeds the original design standard or scale, it should be re-approved according to the approval procedure before construction. After reviewing the project budget by the review office, the bank will review the investment and the agreement will be signed by both parties. Can be constructed. Otherwise, no one may force the construction.

3. During the construction, if the construction is suspended or slowed down in the middle of the construction, both parties shall make a custom-made project to the safety site.

4. During the construction, if Party A is found to be under-invested, the project progress payment cannot be paid on time, and the construction will be suspended or slowed down, and the losses caused to Party B shall be borne by Party A.

3. Party B shall strictly implement the concealed project acceptance system. After the concealed project is completed, it must be recorded and accepted before proceeding to the next process. The general concealed project shall be inspected and accepted by Party B itself, and records shall be made. For major or complex concealed works, Party B shall notify Party A and the design unit in writing to jointly accept and accept the concealed works acceptance procedures. If Party A does not participate at that time, Party B may check and accept it by itself, and Party A shall acknowledge it.

4. Both Party A and Party B shall encounter construction projects in the course of construction and shall submit the approval according to the quota management method. The change budget attached to the change of the engineering agreement shall be sent to the bank in time for construction as the basis for settlement of the project.

Article 6 Completion Acceptance, Settlement and Warranty

1. Party B shall notify Party A of the acceptance date in writing 5 days before the completion of the individual project. If Party A fails to participate in the acceptance on time, Party B shall notify Party B in advance to obtain the consent of Party B, and the acceptance date shall be separately set, but Party A shall acknowledge the completion. If the date is not accepted, the management fees and losses incurred by Party A shall be borne by Party A. And pay the overdue liquidated damages of Party B to one-tenth of the daily cost of the budget.

2. The completion acceptance of the completed project shall be completed within 3 days from the date of acceptance. If Party A fails to take over as scheduled, causing losses in the project after acceptance, Party A shall bear the responsibility.

3. If the unit project in this project is to be handed over to Party A separately, at the time of handover, both parties shall go through the intermediate acceptance procedures as the basis for the acceptance of the completion project of the unit.

4. In the completion of the completion of the project, if the quality of the project is found to be inconsistent with the regulations, Party B shall be responsible for the repair or rework without compensation, and shall be completed within the agreed measures and deadlines. After the experience is accepted, the transfer will be made. If the project is overdue, Party B shall reimburse Party A for overdue liquidated damages of one-tenth of a million per day of the budget.

5. The project has been basically completed. If a certain material or equipment cannot be resolved, the project cannot be completed on schedule. With the consent of both parties, the project can be completed and reduced, and the completion and acceptance of the completed project will be completed. formalities.

6. Acceptance of completion projects shall be based on the construction acceptance specifications issued by the State, the technician inspection standards and the construction drawings. In the case of completion acceptance, Party B shall provide Party A with the following files 10 days before the acceptance:

1. Increase or decrease the change file and other negotiation records;

2. Concealed project acceptance records and intermediate delivery acceptance records;

3. After the completion of the project, the as-built drawings shall be drawn. The construction unit shall make a description of the construction change on the original construction drawing and submit it to the construction unit for filing. If the project changes greatly, the construction unit may draw or commission the design unit or the construction unit to draw the as-built drawings.

7. After the completion and acceptance of the individual project, Party B shall belong to the industrial construction project within 15 days after the completion of the acceptance of the civil construction project. The completion settlement shall be sent to Party A for review within 30 days after the completion acceptance. Party A shall, after receiving the completion settlement, within 15 days of civil construction, the industrial construction shall be reviewed within 20 days. If no objection is filed at the expiration date, the appropriation bank shall approve the appropriation.

8. After the project is completed and accepted, Party B shall be responsible for one year's warranty on the quality of the civil works for construction, and the first heating period for the heating project. During the warranty period, Party B shall be responsible for free repairs due to quality accidents such as roof leakage, pipeline leakage, air leakage and blockage caused by the responsibility of the construction unit.

9. If the project is not experienced, Party A shall use it in advance or use it automatically. Party A shall be responsible for the quality or other problems arising therefrom.

Article 7 Liability for breach of contract and arbitration

1. Since Party B's liability is not completed according to the date stipulated in this contract, every one day overdue shall be repaid to Party A for overdue liquidated damages of one ten-thousandth of the budget; for those who are not covered by the contractor, they shall be repaid to each other for one day. Overdue liquidated damages of two thousandths of the budget labor costs.

2. Party A and Party B shall not owe all kinds of payables for any reason, such as delaying payment, and repaying the default payment of overdue payment according to the bank's short-term loan interest rate.

3. If the rationalization proposal award and the advance completion award are implemented, both parties shall agree separately according to the relevant policies.

4. In the event of a dispute over the contract for the construction and installation project, both parties shall consult in time. If the negotiation fails, either party may apply to the urban and rural construction committee at all levels or the competent department of the higher authorities at both levels for mediation; if it cannot be resolved, the following may be selected. Item handling: Apply to the Arbitration Commission of the building where the building is located for arbitration and directly file a lawsuit with the people's court.

Article 8 Supplementary Provisions

1. In the case of budget review, the construction unit shall submit the construction and installation project contract to the municipal construction project contract budget review office for review. If it is required for attestation, it may go to the district or county administration for industry and commerce at the location where the building is located for verification.

2. Before the signing of this contract, the construction preparation contract signed by both parties may be used as an auxiliary file of this contract.

3. The bidding project shall be signed in accordance with the “Temporary Measures for Bidding and Tendering of Construction Projects in XX City”.

4. Other matters agreed by the parties:

Article 9 Contract Attachment File

First, the list of engineering projects.

Second, all construction drawings.

Third, the construction drawing budget.

4. A list of materials and equipment that Party A is responsible for supplying.

V. Relevant agreements:

6. Relevant supplementary contract:

Article 10 Copies and Validity Period

1. This contract is a ____ copy, and both parties shall submit one copy and submit a copy to the competent authorities of both parties.

2. This contract shall become effective on the date of signing by both parties. It expires after all projects have been completed and accepted and settled.

Construction unit:____________________

Project leader: ____________________________

____year month day

Construction unit: ____________________

Project leader: ____________________________

____year month day