Decoration contract

The latest version of the "Beijing City Family Room Decoration Project Construction Contract> BF - 2003 - 0203

Beijing family room decoration project construction contract

Contractor:

Contractor:

Contract No:

Beijing Municipal Administration for Industry and Commerce

Revised in March 2004

Instructions for use

1. This contract text is applicable to the decoration and decoration of family rooms in the administrative area of ​​this Municipality. This version of the contract text is applicable until the release of the new contract text.

2. The contractor of the project shall have the business license issued by the administrative department for industry and commerce and the qualification certificate for the construction enterprise issued by the construction administrative department.

3. If Party A and Party B directly sign this contract, they shall make two copies in duplicate, and each party to the contract shall hold one copy; any contract signed in each market of this Municipality shall be in triplicate.

4. Construction: After the completion of the preliminary work of the design plan, the first phase of the project, and the completion of the engineering and technical work, the materials and construction personnel will start to operate at the construction site and start to work.

5. Completion: The project contents agreed in the contract are all completed, and the acceptance by the contractor, the supervision unit and the contractor is deemed to be completed.

6. Acceptance of acceptance: The contractor, the supervision unit, and the contractor shall sign and seal the “Completion Acceptance Checklist” or not accept the acceptance procedure, but the contractor has already checked in and accepted it.

7. Delay in construction period: It means that the project schedule will be extended accordingly after the project schedule is affected due to Party B’s responsibility. In the case of a delay in the construction period, Party B shall not be liable for breach of contract.

Post stamp duty office

Beijing Family Room Decoration Project Construction Contract Agreement Clause

Contractor:

Attorney: Nationality:

Address: ID number:

Contact number: Mobile number:

Contractor:

Business License No:

residence:

Legal representative: Contact number:

Attorney: Contact number:

Building qualification level certificate number:

The designer of this project: Contact number:

Construction team leader: Contact number:

In accordance with the "Contract Law of the People's Republic of China" and other relevant laws and regulations, combined with the characteristics of the decoration and decoration of the family room in this city, Party A and Party B shall contract Party B's family room on the basis of equality, voluntariness and consensus. Regarding the matters related to the decoration and renovation project, the following agreement was reached:

The first project overview

1.1 Project location:

1.2 Engineering decoration area:

1.3 Project type:

1. 4 project content and practices;

1.5 Project contracting, adopt the following first method:

Party B shall contract and cover all materials.

Party B shall contract and cover some materials, and Party A shall provide the rest of the materials.

1.6 project deadline date;

Date of commencement of work;

Completion date year, month and day.

1. 7 engineering and quotation

Project cost: The cost of this contract project is

Amount of capital:

The quotation shall be based on the "Beijing Home Decoration Project Reference Price" as the reference. According to the rules of market economy operation, the principle of high quality and good price shall be agreed by both parties as an auxiliary file of this contract.

The quotation shall be taken together with the material quality standard and the production and safety process as the basis for determining the project price.

Article 2 Engineering Supervision

If the project is supervised by the project, Party A shall sign the “Construction Supervision Contract” separately with the project supervision company approved by the construction administrative department, and notify Party B of the name, unit, contact information of the supervision engineer and the duties of the supervision engineer. .

Article 3 Construction drawings and pre-evaluation calculation of indoor environmental pollution control

3.1 Construction drawings are provided in the following manner:

If Party A designs it by itself, it shall provide three copies of the construction drawings and pre-evaluation calculations for indoor environmental pollution control. Party A shall hold one copy and Party B shall hold two copies.

If Party A entrusts Party B to design, Party B shall provide three copies of the construction drawings and pre-evaluation calculations for indoor environmental pollution control, Party A shall hold one copy and Party B shall hold two copies.

3.2 The construction drawings and indoor environmental pollution control pre-evaluation calculation documents provided by both parties must meet the requirements of the “Code for Indoor Environmental Pollution Control of Civil Building Engineering”.

3.3 Both parties shall sign and confirm the construction drawings and pre-evaluation calculations for indoor environmental pollution control.

3.4 The parties shall not copy or transfer the construction drawings and design plans provided by the other party to a third party without authorization, nor may they be used for projects other than this contract.

Article 4 Party A's work

4.1 Before the start of construction, it is necessary to create conditions for the construction of Party B before the start of construction, so as not to affect the construction principle.

4.2 Free supply of water, power and winter heating during construction.

4.3 Responsible for the commencement of the property management department and the relevant fees that should be paid by the owner.

4.4 Obey the rules and regulations of the property management department.

4.5 Responsible for coordinating the relationship between Party B's construction personnel and the neighborhood.

4.6 The following acts shall not be allowed:

Feel free to change the main body of the house and the load-bearing structure.

Open the window, door or enlarge the size of the original door and window on the outer wall, and remove the wall of the door and window of the connected balcony.

Spread more than one centimeter of stone in the room, build a wall, and increase the ground load on the building.

Destroy the waterproof layer of the kitchen and toilet floor and dismantle the hot, warm, gas and other pipeline facilities.

Other acts that force Party B to work in violation of regulations.

4.7 Where it is necessary to refer to the contents listed in paragraph 4.6, Party A shall submit an application to the housing management department, and the original design unit or the design unit with the corresponding qualification level shall verify the safety use of the modification plan and issue a written certificate, and then the house shall be issued. Management approval.

4.8 If Party A still needs to use the room partially during construction, Party A shall be responsible for coordinating with Party B to do security and fire protection work.

4.9 Participate in the supervision of the project quality construction progress, participate in the acceptance of engineering materials, concealed project acceptance, completion acceptance.

Article 5 Party B's work

5.1 Strict implementation of construction specifications, quality standards, safety operation procedures, fire prevention regulations during construction, safety, quality assurance, and completion of the project content agreed in this contract.

5.2 Strictly implement the construction site management regulations of the municipal construction administrative department:

There is no approval formalities and reinforcement drawings for the housing management department. The main building and load-bearing structure within the project shall not be demolished. The ground load of the building shall not be added, and the existing hot, warm, gas and other pipeline facilities shall not be altered.

Do not disturb the people and pollute the environment. No decoration or decoration activities such as knocking, chiseling, planing, drilling, etc., shall be carried out between 12:00 and 14:00, and between 18:00 and 8:00.

Party B shall be responsible for repair and loss compensation for the blockage, leakage, water stoppage and power outage of adjacent residential houses due to decoration and decoration.

Responsible for the protection of finished products, equipment and living room furniture.

Ensure that the indoor and sewer pipes are open and the bathroom is clean.

Ensure that the construction site is clean and tidy, and clean the construction site after daily completion.

5.3 Provide Party A with the conditions for the inspection of various standards, specifications, calculations, reference prices and other written materials involved in the signing and performance of this contract by means of the notification website and unified publicity.

5.4 Party A is a minority, and Party B shall respect its national customs and habits during the construction process.

Article 6 Engineering Changes

If the project content agreed upon in the contract needs to be changed during the construction period, both parties shall agree. A written change agreement is signed by both parties to the contract, and the relevant engineering fees and construction period are adjusted. The project change agreement is used as the basis for the completion settlement and the extension of the construction period.

Article 7 Material Supply

7.1 Provided according to the feeding method and content as stipulated in Party B's “Construction Materials and Equipment List” prepared by Party B.

Party A shall notify Party B of the materials and equipment provided by Party A before the materials and equipment arrive at the construction site. Both parties will jointly accept the materials, equipment quality and environmental protection standards and handle the handover procedures.

Party B shall notify Party A of the materials and equipment provided by Party B before the materials and equipment arrive at the construction site. Both parties shall jointly accept the materials, equipment quality and environmental protection standards, and Party A shall confirm the record.

The building decoration materials provided by both parties must comply with the “Limited Standards for Hazardous Substances in Interior Decoration” issued by the General Administration of Quality Supervision, Inspection and Quarantine, and have a test report issued by a professional testing agency approved by the relevant administrative department.

If one party disagrees with the materials provided by the other party and needs to conduct re-examination, the inspection fee shall be paid by the advance; if the materials are indeed unqualified, the inspection costs shall be borne by the other party.

Party B shall bear the responsibility for the custody and quality control of the materials and equipment provided by Party A after Party B's acceptance and confirmation of the completion of the handover procedures.

Article 8 Delay in construction period

8.1 Delay in completion of the following reasons for the completion of the following reasons, confirmed by Party A, the construction period should be postponed:

Engineering quantity change or design change;

force majeure;

Party A agrees with other circumstances in which the construction period is postponed.

8.2 The date of completion is delayed for the following reasons, and the construction period shall be postponed:

Party A fails to complete the work that it should be responsible for in accordance with the contract and affects the construction period;

Party A fails to pay the construction cost according to the contract and affects the normal construction;

Other circumstances in which the construction period is delayed due to Party A’s responsibility.

8.3 If Party B’s responsibilities cannot be completed on schedule, the construction period will not be postponed; Party B will bear the rework costs due to Party B’s reasons for the quality of the project, and the construction period will not be postponed.

8.4 Judgment of the delay in the construction period is based on the “text agreement between the two parties” as the basis for determining the responsibilities of both parties.

Article 9 Quality Standards

9.1 The indoor environmental pollution control of decoration shall be strictly carried out in accordance with the standards of the “Code for Indoor Environmental Pollution Control of Civil Building Engineering”.

9.2 The construction quality of the project shall be implemented in accordance with the following criteria:

"Beijing Family Room Decoration Engineering Quality Acceptance Standard";

"Quality Acceptance Standard for Beijing Advanced Building Decoration Engineering".

9.3 When the two parties dispute the quality of the project and the indoor air quality during the completion acceptance, they shall apply for certification by the professional testing agency approved by the relevant administrative department; the relevant expenses for the certification process shall be paid by the applicant and ultimately by the responsible party.

Article 10 Project Acceptance

10.1 In the construction process, the following aspects shall be used to jointly check the quality of the project:

Material acceptance;

Concealed project acceptance;

Completion acceptance.

10.2 After the completion of the project, Party B shall notify Party A of the acceptance, and Party A shall organize the acceptance within three days after receiving the completion acceptance notice. After the acceptance is passed, the two parties shall handle the handover procedures, settle the final payment, and sign the warranty. Party B shall submit to Party A the hydropower transformation map of its construction part.

10.3 Before the completion of the completion acceptance, Party B shall be responsible for protecting the entire safety of the finished product and the project site.

10.4 The two parties have not gone through the formalities of acceptance, Party A shall not be allowed to stay. If Party A arbitrarily enters into the same inspection and acceptance, the losses caused by Party A shall be borne by Party A.

10.5 Completion Acceptance In the case of project quality, indoor air quality and economic aspects, if there are individual problems that do not involve major problems, the two parties may also sign the “Agreement on Resolving the Legacy Problems of Completion Acceptance” after negotiation.

10.6 The warranty period of the interior decoration project under normal use conditions is two years from the date of signing the qualified two parties. The warranty period for the kitchen and bathroom anti-leakage project with waterproof requirements is five years.

Article 11 Payment method of construction funds

11.1 After the contract signature is effective, Party A shall direct Party B to pay the construction cost according to the agreement in the list:

Payment time payment time, project payment ratio, payment amount

50% before the first three days of construction

The second project progressed more than half of the 45%

The third completion acceptance is 5%

11.2 The progress of the project is more than half, which means that the water and electric pipelines in the project are all laid, the wall and top base layers are all completed according to the process requirements, and the basic safety of the doors, windows and fine wood enamel products is the standard for defining more than half of the project.

11.3 After the project is qualified, Party A shall review the project settlement statement submitted by Party B. If there is no objection within two days from the date of submission, Party A shall be deemed to have agreed to pay the final payment of Party B's project.

11.4 After all the project funds have been settled, Party B shall issue a formal unified invoice to Party A as the settlement certificate for the project.

Article 12 Liability for breach of contract

12.1 If a party fails to perform its contractual obligations to the other party in accordance with the contract, it shall be liable for compensation; if it is punished for violating relevant laws and regulations, the ultimate responsibility shall be borne by the responsible party.

12.2 If a party is unable to continue to perform the contract, it shall promptly notify the other party, and the responsible party shall bear the losses caused by the termination of the contract.

12.3 Party A fails to pay the second and third construction funds in accordance with the contractual deadline without any justifiable reasons. For each day of delay, Party B shall pay Party B a penalty of delay of 2% of the construction cost.

12.4 Due to the delay of Party B's responsibility, Party B shall pay Party A a penalty of 2% of the construction cost of this contract for each day of delay.

12.5 Due to the unsatisfactory quality of the project and the indoor air quality caused by Party B's responsibility, Party B shall carry out rework and repair, comprehensive treatment and payment according to the following agreements:

Party B must carry out thorough rework and repair for parts that are unqualified in engineering quality. The delayed delivery of the project due to rework is regarded as a delay in the project, and the liquidated damages are paid according to the standard of 12.4.

If the indoor air quality is unqualified, Party B must conduct comprehensive management. The delayed delivery of the project due to governance is considered as a delay in the project, and the liquidated damages are paid according to the standard of 12.4.

If the indoor air quality is still not up to standard and is the responsibility of Party B, Party B shall return the full price of the contract to Party A; if Party A is also responsible for the non-compliance, Party B may reduce the return ratio accordingly.

Article 13 Dispute Resolution

In case of disputes arising under this contract, both parties shall negotiate or apply to the market organizer, consumer association, etc. for mediation, and if the negotiation or mediation fails, they shall file a lawsuit with the people's court or apply for arbitration in accordance with a separate arbitration clause or arbitration agreement.

Article 14 Supplementary Provisions

14.1 This contract shall become effective upon signature by both parties.

14.2 The project may not be subcontracted after the signing of this contract.

14.3 The parties may change or supplement this contract in writing, but if the change or supplement is mitigated or exempted from the liability of Party B, the contract shall prevail.

14.4 If the reasons for the non-attributable to both parties affect the performance of the contract or cause losses, the two parties shall resolve the matter in accordance with the principle of fairness.

14.5 If Party B withdraws from the market, the market sponsor shall first assume the liability for compensation; after the organizer assumes responsibility, it shall have the right to recover from Party B.

14.6 This contract is automatically terminated upon completion of performance.

Article 15 Other agreed matters

person A person B:

Legal representative:

Attorney:

Year, month, day, month, day

Market organizer:

Legal representative:

Attorney:

contact number:

year month day

Schedule I

Engineering quotation

sequence

Number of units, unit price, total amount, process, process description

Party A's representative: Party B's representative:

Remarks: Enterprises with more usage of this table can copy and copy as an attached file of the contract.

Schedule 2

Party A supplies engineering materials and equipment list

sequence

No. Material Name Unit Variety Specification Quantity Supply Time Supply Acceptance Location

Party A's representative: Party B's representative:

Remarks: The materials and equipment supplied must have a test report issued by a professional inspection unit approved by the administrative department.

Schedule 3

Party B supplies engineering materials and equipment list

sequence

No. Material Name Unit Variety Specification Quantity Supply Time Supply Acceptance Location

Party A's representative: Party B's representative:

Remarks: The materials and equipment supplied must have a test report issued by a professional inspection unit approved by the administrative department.

Schedule IV

Project completion acceptance form

Acceptance time: year, month and day

project name:

construction place:

Completion acceptance

See the signature of Party A:

Signature of the supervision unit:

Signature of Party B:

Remarks: In the completion acceptance, there is still no problem affecting the overall project quality. The two parties can agree to stay, but the agreement on the remaining problems after completion must be signed as the basis for solving the remaining problems after the stay.

Schedule 5

Home improvement project warranty

Party A

Party A's agent contact number

Party B

Legal representative contact number

Home improvement project address

Start date of completion

Warranty period from year, month, day to year

Party A's representative: Party B's representative:

Remarks:

1. From the date of completion acceptance, the warranty period for decoration and decoration is two years, and the warranty period for kitchen and bathroom anti-leakage projects with waterproof requirements is five years;

2. During the warranty period, due to the construction and decoration quality problems caused by Party B's construction and improper materials, Party B shall promptly and unconditionally carry out maintenance;

3. During the warranty period, due to improper use or maintenance by Party A, the finish may be damaged or cannot be used normally. Party B shall charge for repairs as appropriate;

4. This warranty will take effect after the signature and seal of both Party A and Party B.