Commission for construction
The contract of the contractor is x x x and the construction party x x x, the contract of the real estate signing of the contract is subject to the terms of the agreement between the two parties, as follows:
Article 1 Landmark: This contract house is located in the x x district x x area land named "x x Ming Palace", and is temporarily numbered in the A building x x building.
Article 2 Area of the House: The area of the contract includes xx square meters of indoor facilities such as indoors, balconies and walkways, stairwells, roofing basements, and elevators. The two parties agree to record the ownership of the building improvement. The area plus the area of public facilities allocated in the preceding paragraph is equivalent to the area recorded in this contract. If there is any increase or decrease, and the difference between the areas is less than 2%, neither party may protest. If the increase or decrease of the area error exceeds the percentage In the second semester, the error exceeds the percentage of the second part, that is, the average unit price at the time of sale of the household is used as the calculation basis, and the two parties compensate each other.
Article 3 The roof of the building shall be provided with Party B's investment and planning, except for water tanks and stairwells. Party B shall provide Party A with preferential services to the general public.
Article 4 The property rights registration of the basement of the building is shared by all the owners of the building. In addition to the mechanical and electrical equipment in the basement, the rest of the venues shall be opened as public shelters in the event of air strikes. The basement is usually used as a parking lot and managed by the management committee of the building. Details are contained in the management charter of the Management Committee of the Building.
Article 5 The indoor compartment decoration and equipment engineering of the house ordered by Party A shall be constructed according to the construction license drawings approved by the xx municipal government xx Bureau. If Party A requests to change or increase or decrease, Party B shall seek the consent of Party B. However, the entire installation of the building shall not be deleted. The changed construction cost shall be agreed upon by both parties, but it shall be paid in a lump sum to Party B at a time not less than the construction cost specified in this contract. Party A shall not pay the increased construction cost before Party B. Construction shall not be carried out. If the parties fail to reach an agreement on the changed construction project or Party A refuses or delays the delivery of the additional changes, it shall be deemed that Party A cancels the change or increase or decrease, and Party B still works according to the original project of this contract.
Article 6 Project Duration: This contract construction project shall be commenced within three months after the signing of this contract. It shall be completed within 700 working days from the date of commencement of construction, and the application for the license shall be completed as the date of completion. However, if one of the following circumstances is not exceeded, Party B shall not be liable for delay in completion.
Party A did not pay the price according to the agreed payment method.
Party A requested to change the internal compartment and design, resulting in delay in completion.
Due to force majeure reasons such as natural disasters or man-made disasters or laws and regulations, etc., it is not attributable to Party B's reasons, so that the project cannot be carried out as scheduled.
The drainage ditch and roadway laying works outside the project are not subject to the time limit for completion of this Treaty, and the connection and supply of water and electricity shall be determined by the utility operation program.
Article 7 Warranty Period: From the date of receipt of the contract to the use of the license, Party B shall be responsible for the warranty for one year for the construction of the contract, but the damage caused by the natural disaster or the reasons for the damage to Party B shall not be exceeded.
Article 8 The total price of Party A's order for the purchase of this property is RMB x仟x佰x, x000x仟, including the following house and decoration land price.
The price of the house and the decoration is RMB x 佰 x x x x 仟.
The land price is RMB x 佰 x x x 10,000 x 仟 yuan, including construction base, road land and land compensation, land improvement fees, land for public facilities and other expenses.
Article 9 Payment Method: The total price of the premises of this contract is RMB x仟x佰x, x仟元元, divided into self-supplied RMB x佰x, x thousand x yuan, whole concession loan RMB x佰x pickup x If the bank loan is RMB x 佰 x and x 10,000 yuan, Party A shall, according to the following progress, pay the amount on the installment payment form to Party B within the payment period by Party B, without delay. Short owe.
Article 10 Loan Measures: If Party A of this contract is required to apply for a bank loan, it shall sign a contract with the Party to entrust a loan agreement and a letter of appointment to handle the loan.
Article 11 If Party A fails to perform the agreed payment of the progress of the project as stipulated in this contract, Party A shall be willing to calculate the late payment fee by one-thousandth of the daily payment from the fifth day after the date of payment of the notice. If the payment is late, the payment will be paid to Party B. If it is overdue for 15 days, if Party B still refuses to deliver the goods, Party B will be deemed to be in breach of contract. Party B shall not cancel this contract and the proxy for the loan. , the escrow seal power of attorney and other agreements with this contract, Party A agrees to confiscate the cash portion of the paid money, and thinks that the damage suffered by Party B will be compensated. Party B has to separately purchase the premises ordered by Party A. If the seller sells it with a third party or for other disciplinary actions, Party A will never complain. If Party A pays the bill according to the payment regulations stipulated in the preceding article, Party A guarantees the cash payment. If there is any refund, it is deemed that Party A has not paid. The payment shall be handled in accordance with the aforementioned agreement.
Article 12 If Party B fails to pay the house due to the circumstances of Article 5, it shall calculate the liquidated damages and Party A for each one-thousandth of the total price of the purchase and purchase. If Party B fails to perform the house due to its own factors, In the event that the dispute arises and cannot be sold in the middle of the journey, the amount of the payment shall be refunded to Party A in full, and the damages of the same amount shall be compensated to Party A as Party B's total damages for failure to perform this contract. If the government fails to blame Party B for reasons such as the ban on the construction of the ban, the parties agree to terminate the contract, and Party B shall refund the interest paid by Party A to Party A.
Article 13 The house of this contract has been registered in the name of Party A. If Party A refuses to pay the payment in default, Party A agrees that the name shall be changed to the person designated by Party B or Party B, and Party A shall not otherwise Requirements.
Article 14 Party A shall be responsible for ordering the land of the house, and the registration of the property rights of the house and the transfer of the property rights of the base. Party B shall be responsible for the completion of the construction of the house, the license issued by the competent government unit, and Party A’s performance of its obligations. Party B shall be responsible for hiring a letter of proxy and Party A to jointly entrust the co-ordination. Party A shall, in accordance with the time notified by Party B, seal the documents to be submitted and the relevant files, together with the various taxes and the written or entrusted letter of Party B. Handle. The expenses that Party A and Party B should bear are as follows:
The building registration fee, land registration fee, stamp duty, deed tax, supervision fee and the registration fee of the agency shall be borne by Party A.
Party B shall pay the land price before the transfer of the contract land and the value-added tax incurred when transferring the transfer.
The mortgage registration of the contract and the mortgage of the pledge loan shall be set to register the transfer fee, and the official deed, stamp duty, insurance premium and agency fee shall be borne by Party A.
The housing tax, land price tax, and project benefit fee incurred from the date of receipt of the license shall be paid by Party A and shall not be disobeyed, regardless of whether Party A has moved in or raised it to either party.
If the above fees are to be borne by Party A, if Party B advances or pays, Party A shall return the amount as necessary.
Article 15 Registration of Property Rights: The registration of real estate rights in this contract shall be designated by Party B as the agent, and shall handle the procedures for land transfer registration, construction property registration and loan mortgage registration.
Article 16 In the contract premises, Party B guarantees that the property rights are clear, and there is no dispute or any other rights. If there is any dispute, Party B shall be responsible for cleaning up and shall not damage Party A's interests.
Article 17 Party A agrees to pay the following fees from the date of completion of the house and the connection of water and electricity, regardless of whether the documents listed are headed by any party:
The basic cost of water and electricity for the household.
The house is subject to the housing tax from the date of license.
The water and electricity expenses that should be shared by all households in the public use of this house.
For the maintenance, operation and maintenance of the building's cleaning and maintenance, public facilities and equipment, the management expenses shall be shared by all households.
The sharing of public management expenses related to this house.
Article 18 After the construction of the contract is completed and the license is issued by the competent authority, Party A shall pay the following taxes and fees, and Party B shall deliver the house to the house. If Party A fails to co-organize or delays the overdue, it will affect the contract. The registration of property rights or the progress of construction shall be deemed to be a breach of contract, and shall be responsible for compensation for all losses of Party B.
Pay the taxes payable in accordance with the first, third and fourth items of Article 14 of this Agreement.
Charge the property registration and agency loan, and prepay Party B's interest for four months.
Pay the late payment due to late payment.
Pay all the concessional loans for this home.
Article 19: Notice of Advice: All matters relating to consultation, negotiation or notification handled by both parties shall be mailed in writing in accordance with the address enclosed in this Agreement. If there is any rejection or failure to deliver, the first post will be delivered by post. The date is the date of delivery.
If Party A’s address changes, it shall be obligated to notify Party B.
Article 20 Other matters.
If Party A requests half-way change of design in this contract, it must be entrusted to Party B in writing with the consent of Party B. After the required project cost is negotiated by both parties, the difference will be paid by Party A at the same time, but it will not be reduced. The fixed price is the principle. If Party A fails to pay within the agreed period, Party B shall regard Party A as canceling the design change request. Party B shall, in order to avoid affecting the progress of the project, submit the construction according to the original contract. Party A shall not protest. .
Before Party B informs the delivery of the house and gives proof of the move, Party A will never carry out the decoration of the house itself.
This contract is to be settled by the Party B at the same time as the payment of the payment for the settlement of the house, and the registration of the land transfer. Party A collects the ownership, and this contract and the contract and subsidiary files of the contract have been revoked by Party A.
Article 21 The binding and effect of this contract:
Party A shall not transfer the rights and obligations of this contract premises to others without paying the land price and without the consent of Party B. However, with the consent of both parties, the matters agreed in this contract shall be legal to the assignee of the rights and obligations of both parties. The heirs are equally binding.
The subsidiary file of this contract is considered to be part of this contract and has the same effect as this contract. If the subsidiary file is not specified, it shall be in accordance with the provisions of this contract.
Article 22 Matters not covered: If there are any unfinished matters in this contract, it shall be negotiated by both parties.
Article 23: Separation of Contracts: The above-mentioned contractual matters, with the consent of both parties, may not be verbally. The Teliben contract is in duplicate, and both parties are responsible for each other, and they are effective from the date of signing. The stamp duty is self-supplied by both parties.
Article 24 In relation to the right to this contract, the parties agree to use the x x x court as the court of jurisdiction.
Contractor:
Party A:
Legal representative:
address:
identification number:
phone:
Party B:
Address:
identification number:
phone:
x x x x years x months x days
Article 1 Landmark: This contract house is located in the x x district x x area land named "x x Ming Palace", and is temporarily numbered in the A building x x building.
Article 2 Area of the House: The area of the contract includes xx square meters of indoor facilities such as indoors, balconies and walkways, stairwells, roofing basements, and elevators. The two parties agree to record the ownership of the building improvement. The area plus the area of public facilities allocated in the preceding paragraph is equivalent to the area recorded in this contract. If there is any increase or decrease, and the difference between the areas is less than 2%, neither party may protest. If the increase or decrease of the area error exceeds the percentage In the second semester, the error exceeds the percentage of the second part, that is, the average unit price at the time of sale of the household is used as the calculation basis, and the two parties compensate each other.
Article 3 The roof of the building shall be provided with Party B's investment and planning, except for water tanks and stairwells. Party B shall provide Party A with preferential services to the general public.
Article 4 The property rights registration of the basement of the building is shared by all the owners of the building. In addition to the mechanical and electrical equipment in the basement, the rest of the venues shall be opened as public shelters in the event of air strikes. The basement is usually used as a parking lot and managed by the management committee of the building. Details are contained in the management charter of the Management Committee of the Building.
Article 5 The indoor compartment decoration and equipment engineering of the house ordered by Party A shall be constructed according to the construction license drawings approved by the xx municipal government xx Bureau. If Party A requests to change or increase or decrease, Party B shall seek the consent of Party B. However, the entire installation of the building shall not be deleted. The changed construction cost shall be agreed upon by both parties, but it shall be paid in a lump sum to Party B at a time not less than the construction cost specified in this contract. Party A shall not pay the increased construction cost before Party B. Construction shall not be carried out. If the parties fail to reach an agreement on the changed construction project or Party A refuses or delays the delivery of the additional changes, it shall be deemed that Party A cancels the change or increase or decrease, and Party B still works according to the original project of this contract.
Article 6 Project Duration: This contract construction project shall be commenced within three months after the signing of this contract. It shall be completed within 700 working days from the date of commencement of construction, and the application for the license shall be completed as the date of completion. However, if one of the following circumstances is not exceeded, Party B shall not be liable for delay in completion.
Party A did not pay the price according to the agreed payment method.
Party A requested to change the internal compartment and design, resulting in delay in completion.
Due to force majeure reasons such as natural disasters or man-made disasters or laws and regulations, etc., it is not attributable to Party B's reasons, so that the project cannot be carried out as scheduled.
The drainage ditch and roadway laying works outside the project are not subject to the time limit for completion of this Treaty, and the connection and supply of water and electricity shall be determined by the utility operation program.
Article 7 Warranty Period: From the date of receipt of the contract to the use of the license, Party B shall be responsible for the warranty for one year for the construction of the contract, but the damage caused by the natural disaster or the reasons for the damage to Party B shall not be exceeded.
Article 8 The total price of Party A's order for the purchase of this property is RMB x仟x佰x, x000x仟, including the following house and decoration land price.
The price of the house and the decoration is RMB x 佰 x x x x 仟.
The land price is RMB x 佰 x x x 10,000 x 仟 yuan, including construction base, road land and land compensation, land improvement fees, land for public facilities and other expenses.
Article 9 Payment Method: The total price of the premises of this contract is RMB x仟x佰x, x仟元元, divided into self-supplied RMB x佰x, x thousand x yuan, whole concession loan RMB x佰x pickup x If the bank loan is RMB x 佰 x and x 10,000 yuan, Party A shall, according to the following progress, pay the amount on the installment payment form to Party B within the payment period by Party B, without delay. Short owe.
Article 10 Loan Measures: If Party A of this contract is required to apply for a bank loan, it shall sign a contract with the Party to entrust a loan agreement and a letter of appointment to handle the loan.
Article 11 If Party A fails to perform the agreed payment of the progress of the project as stipulated in this contract, Party A shall be willing to calculate the late payment fee by one-thousandth of the daily payment from the fifth day after the date of payment of the notice. If the payment is late, the payment will be paid to Party B. If it is overdue for 15 days, if Party B still refuses to deliver the goods, Party B will be deemed to be in breach of contract. Party B shall not cancel this contract and the proxy for the loan. , the escrow seal power of attorney and other agreements with this contract, Party A agrees to confiscate the cash portion of the paid money, and thinks that the damage suffered by Party B will be compensated. Party B has to separately purchase the premises ordered by Party A. If the seller sells it with a third party or for other disciplinary actions, Party A will never complain. If Party A pays the bill according to the payment regulations stipulated in the preceding article, Party A guarantees the cash payment. If there is any refund, it is deemed that Party A has not paid. The payment shall be handled in accordance with the aforementioned agreement.
Article 12 If Party B fails to pay the house due to the circumstances of Article 5, it shall calculate the liquidated damages and Party A for each one-thousandth of the total price of the purchase and purchase. If Party B fails to perform the house due to its own factors, In the event that the dispute arises and cannot be sold in the middle of the journey, the amount of the payment shall be refunded to Party A in full, and the damages of the same amount shall be compensated to Party A as Party B's total damages for failure to perform this contract. If the government fails to blame Party B for reasons such as the ban on the construction of the ban, the parties agree to terminate the contract, and Party B shall refund the interest paid by Party A to Party A.
Article 13 The house of this contract has been registered in the name of Party A. If Party A refuses to pay the payment in default, Party A agrees that the name shall be changed to the person designated by Party B or Party B, and Party A shall not otherwise Requirements.
Article 14 Party A shall be responsible for ordering the land of the house, and the registration of the property rights of the house and the transfer of the property rights of the base. Party B shall be responsible for the completion of the construction of the house, the license issued by the competent government unit, and Party A’s performance of its obligations. Party B shall be responsible for hiring a letter of proxy and Party A to jointly entrust the co-ordination. Party A shall, in accordance with the time notified by Party B, seal the documents to be submitted and the relevant files, together with the various taxes and the written or entrusted letter of Party B. Handle. The expenses that Party A and Party B should bear are as follows:
The building registration fee, land registration fee, stamp duty, deed tax, supervision fee and the registration fee of the agency shall be borne by Party A.
Party B shall pay the land price before the transfer of the contract land and the value-added tax incurred when transferring the transfer.
The mortgage registration of the contract and the mortgage of the pledge loan shall be set to register the transfer fee, and the official deed, stamp duty, insurance premium and agency fee shall be borne by Party A.
The housing tax, land price tax, and project benefit fee incurred from the date of receipt of the license shall be paid by Party A and shall not be disobeyed, regardless of whether Party A has moved in or raised it to either party.
If the above fees are to be borne by Party A, if Party B advances or pays, Party A shall return the amount as necessary.
Article 15 Registration of Property Rights: The registration of real estate rights in this contract shall be designated by Party B as the agent, and shall handle the procedures for land transfer registration, construction property registration and loan mortgage registration.
Article 16 In the contract premises, Party B guarantees that the property rights are clear, and there is no dispute or any other rights. If there is any dispute, Party B shall be responsible for cleaning up and shall not damage Party A's interests.
Article 17 Party A agrees to pay the following fees from the date of completion of the house and the connection of water and electricity, regardless of whether the documents listed are headed by any party:
The basic cost of water and electricity for the household.
The house is subject to the housing tax from the date of license.
The water and electricity expenses that should be shared by all households in the public use of this house.
For the maintenance, operation and maintenance of the building's cleaning and maintenance, public facilities and equipment, the management expenses shall be shared by all households.
The sharing of public management expenses related to this house.
Article 18 After the construction of the contract is completed and the license is issued by the competent authority, Party A shall pay the following taxes and fees, and Party B shall deliver the house to the house. If Party A fails to co-organize or delays the overdue, it will affect the contract. The registration of property rights or the progress of construction shall be deemed to be a breach of contract, and shall be responsible for compensation for all losses of Party B.
Pay the taxes payable in accordance with the first, third and fourth items of Article 14 of this Agreement.
Charge the property registration and agency loan, and prepay Party B's interest for four months.
Pay the late payment due to late payment.
Pay all the concessional loans for this home.
Article 19: Notice of Advice: All matters relating to consultation, negotiation or notification handled by both parties shall be mailed in writing in accordance with the address enclosed in this Agreement. If there is any rejection or failure to deliver, the first post will be delivered by post. The date is the date of delivery.
If Party A’s address changes, it shall be obligated to notify Party B.
Article 20 Other matters.
If Party A requests half-way change of design in this contract, it must be entrusted to Party B in writing with the consent of Party B. After the required project cost is negotiated by both parties, the difference will be paid by Party A at the same time, but it will not be reduced. The fixed price is the principle. If Party A fails to pay within the agreed period, Party B shall regard Party A as canceling the design change request. Party B shall, in order to avoid affecting the progress of the project, submit the construction according to the original contract. Party A shall not protest. .
Before Party B informs the delivery of the house and gives proof of the move, Party A will never carry out the decoration of the house itself.
This contract is to be settled by the Party B at the same time as the payment of the payment for the settlement of the house, and the registration of the land transfer. Party A collects the ownership, and this contract and the contract and subsidiary files of the contract have been revoked by Party A.
Article 21 The binding and effect of this contract:
Party A shall not transfer the rights and obligations of this contract premises to others without paying the land price and without the consent of Party B. However, with the consent of both parties, the matters agreed in this contract shall be legal to the assignee of the rights and obligations of both parties. The heirs are equally binding.
The subsidiary file of this contract is considered to be part of this contract and has the same effect as this contract. If the subsidiary file is not specified, it shall be in accordance with the provisions of this contract.
Article 22 Matters not covered: If there are any unfinished matters in this contract, it shall be negotiated by both parties.
Article 23: Separation of Contracts: The above-mentioned contractual matters, with the consent of both parties, may not be verbally. The Teliben contract is in duplicate, and both parties are responsible for each other, and they are effective from the date of signing. The stamp duty is self-supplied by both parties.
Article 24 In relation to the right to this contract, the parties agree to use the x x x court as the court of jurisdiction.
Contractor:
Party A:
Legal representative:
address:
identification number:
phone:
Party B:
Address:
identification number:
phone:
x x x x years x months x days
recommended article
- Construction Engineering Design Contract (3)
- Engineering construction supervision commission
- Demonstration text of commercial housing contract
- Qingdao Construction Project Construction Contract
- Demonstration text of construction project contract (2)
- Shanghai Housing Sublease Contract Sample
- Shanghai housing rental (commercial housing pre-leasing)
- Shanghai Participatory Housing Agreement
- Urban residential area owner management committee charter
- Construction project demolition house contract
- Room decoration commission
- Construction engineering technical consulting contract
popular articles
- Construction project construction contract (general)
- Weibo's famous sayings
- Construction project entrusted supervision contract (Chinese and English)
- Life motto
- Grateful mother's words
- What I said to my father 2019
- Motivate employees
- 2014 motivational phrase
- Relieved words
- Legal maxim
- Contract conditions for construction of water conservancy and hydropower civil engineering
- Space mood phrase
- Ministry of Construction, State Administration for Industry and Commerce
- Encourage words 2019
- Non-mainstream sentence 2019
- Construction project demolition house contract (official model
- Blessing phrase
- Distressed sentence 2019
- Hyun dance family impression sentence
- Real estate mortgage loan contract
- Temporary wall construction agreement
- Qingdao Construction Project Construction Contract
- Parental love
- Team construction contract (construction team)
- Good sentence excerpt 2019
- Not afraid of failure
- Philosophical words 2019
- Spring Festival blessing
- Construction engineering survey contract
- Respect the teacher's famous words