Shanxi Province Family Room Decoration Project Construction Contract

Shanxi Provincial Administration for Industry and Commerce, Shanxi Provincial Construction Department

Instructions for use

1. The text of this contract is a model text and can also be used as a contract. Before signing the contract, the contractor and the contractor shall carefully read the contents of this contract. If the contract terms and professional terms are inconsistent, they may consult the local construction administrative department and the building decoration association.

2. The term "residential decoration and decoration" as used in this contract refers to the construction activities in which the owner of the house or the user of the house decorates the interior of the house.

3. In order to reflect the voluntary principle of both parties to the contract, there are blank lines after the relevant clauses in the text of this contract, for the parties to agree or supplement the agreement. The parties may modify, add or delete the content of the text terms. After the contract is signed into effect, the unprinted text printed text is deemed to be the content of mutual consent.

4. The choices and contents to be included in the text of this contract are given priority by handwritten items.

5. The content selected in the contract text [ ], the blank space, and other contents that need to be deleted or added shall be determined by both parties through negotiation. Select the content in [], select it by stroke; if the actual situation does not occur or the buyer and the seller do not make an agreement, you should use the space in the space to delete it.

6. Before signing the contract, if the contractor is the owner of the house, the contractor shall be required to present the house ownership certificate or other legal title certificate of the house; if the party is the owner of the house, the contractor shall be required to show the lawful use of the house. And the right to have a certificate of proof of the decoration of the house.

7. Before signing the contract, if the contractor is an enterprise, it shall present its “Construction Enterprise Qualification Certificate” to the contractor; if the contractor is an individual, it shall present the individual decoration and decoration practitioner's certificate to the contractor.

8. The term “contracting party” as used in this contract refers to the owner of the house and the owner of the right to entrust others to modify the residential house. The term "contractor" as used in this contract refers to the units and individuals who accept the commissioning of the construction of residential houses.

9. Construction: After the completion of the preliminary work of the design plan, the first phase of the project, and the engineering technology, the materials and construction personnel will be allowed to start operation at the site.

10. Completion: The project contents agreed in the contract are all completed, and the acceptance of both Party A and Party B is deemed to be completed.

11. Qualified for acceptance: The contractor, the contractor and the supervising party shall sign and seal the "construction completion acceptance form" or not accept the acceptance procedure, but Party A has already checked in and accepted it.

12. The extension of the construction period means that after the project progress is affected due to the responsibility of Party B, the project period will be extended accordingly, and Party B will not be liable for breach of contract.

13. The terms of this contract are explained by the Shanxi Provincial Administration for Industry and Commerce, the Shanxi Provincial Construction Department and the Shanxi Provincial Building Decoration Association.

Employer: _______________________

Resident Identity Number: ____________________________________

address:_________________________________________

Contact number: ______________ Postal code: ___________

Attorney: ____________ Resident Identity Number: _______

address:_________________________________________

Contact number: ______________ Postal code: ___________

Contractor:_______________________

[Business License No.] [Resident Identity Number]: _________________

[Unit of residence] [Personal address]: __________________

[Unit legal representative]: __________________________

[Construction Enterprise Qualification Certificate Number]: ___________________

[Individual decoration and decoration practitioners' certificate number]: __________

Contact number: ______________ Postal code: ___________

Attorney: ____________ Resident Identity Number: _______

address:_________________________________________

Contact number: ______________ Postal code: ___________

In accordance with the "Contract Law of the People's Republic of China" and other relevant laws and regulations, combined with the characteristics of family room decoration and decoration, Party A and Party B shall, on the basis of equality, voluntariness and consensus, revise and decorate the family room of Party B. For matters related to the project, the following agreement was reached:

The first project overview

1.1 Project detailed address: ________________________________

1.2 The structure of the project: ________ room ________ hall ________ kitchen ________ ________ balcony.

Building area of ​​residential houses: ________________ square meters.

1.3 Project scope, content and practices: ________________________.

The second project contracting method

2.1 Project contracting adopts the following ________ methods

Party B shall contract and cover all materials.

Party B shall contract and cover some materials, and Party A shall provide the rest of the materials.

Party B's contractor and Party A package all materials

Article 3 Project Cost

3.1 The project cost adopts the following ________ methods

The fixed project cost method, that is, in the case of determining the scope of the project contracting and the contracting method, the project cost will be determined once and for all, and no increase or decrease will be made. The cost is ________________________.

The unit price of the fixed project, that is, the unit price of the project in the fixed schedule quotation is unchanged, and the project cost is calculated according to the actual amount of the project completed. The cost of the floating project is to determine the project cost in the case of determining the scope of the project contracting and the contracting method. After the completion of the project, the cost of the design change will be increased or decreased according to the actual occurrence and the attached quotation. The current cost of the project before the design change is

other methods:________________________

3.2 The quotation shall refer to the “Reference Price of Shanxi Family Room Decoration Project”. It shall be agreed by Party A and Party B as the subsidiary file of this contract according to the principle of market economy operation and the principle of high quality and good price.

3.3 The quotation shall cover the material quality standard and the preparation of the safety and technology process, and jointly serve as the basis for determining the project price.

The fourth period

4.1 The construction period of this project is ________ days. Start date ________ years ________ month ________ days. Completion date ________ years ________ month ________ days.

4.2 During the construction period, Party B's daily construction time is:

________ points ________ points to ________ points ________ points

________ points ________ points to ________ points ________ points

4.3 In any of the following circumstances, the time limit shall be postponed as determined by both parties:

If the amount of work increases or the design changes, it is necessary to delay the construction period;

Party A fails to complete the work that it should be responsible for in accordance with the contract and affects the construction period;

Party A fails to pay the construction cost according to the contract and affects the normal construction;

The unqualified quality of materials and equipment provided by Party A affects the construction of the project;

Other circumstances in which the construction period is delayed due to Party A's responsibility;

Party A agrees to other circumstances in which the construction period is postponed;

force majeure.

4.4 If the responsibility of Party B cannot be completed on time, the construction period will not be postponed.

4.5 The rework cost of the project quality caused by Party B shall be borne by Party B, and the construction period shall not be postponed;

4.6 Judging the delay in the construction period is based on the “written agreement between the parties” as the basis for determining the responsibilities of both parties.

4.7 Other appointments: ________________________

Article 5 Construction Drawings

5.1 Construction drawings are provided in the following _______

Party A design or Party A entrusts others to design, Party A shall provide construction drawings in triplicate, Party A shall hold one copy, and Party B shall hold two copies;

Party A entrusts Party B to design, Party B shall provide three copies of the construction drawings, Party A shall hold one copy, and Party B shall hold two copies;

5.2 Both parties shall sign and confirm the construction drawings in writing;

5.3 The parties shall not copy or transfer the construction drawings and design plans provided by the other party to a third party without authorization or use it for projects other than this contract.

5.4 The drawing designer shall have the qualifications for the design of the project.

5.6 If Party A provides drawings, Party A shall be responsible for the design content and quality of the drawings; if Party B provides drawings, Party B shall be responsible for the design content and quality of the drawings.

5.7 The following contents shall not be included in the drawings.

The design plan is proposed without the original design unit or the design unit with the corresponding qualification level, and the building main body and the load-bearing structure are changed;

Change the room or balcony without waterproof requirements to the bathroom and kitchen room;

Expand the original size of doors and windows on the load-bearing wall, and remove the brick and concrete walls of the connected balcony;

Damage to the original energy-saving facilities of the house and reduce energy-saving effects;

Other behaviors that affect building structure and safety.

The above-mentioned building main body refers to the structural structure of the building entity, including the roof, the floor, the beam, the column, the support, the wall, the connecting joint and the foundation.

The above-mentioned load-bearing structure refers to the main structural members and their connecting joints that directly transfer their own weight and various applied forces to the foundation foundation, including load-bearing walls, poles, columns, frame columns, buttresses, Floor slabs, beams, roof trusses, suspension cables, etc.

5.8 If the following contents are included in the drawings, they shall be approved by the relevant departments:

Building buildings and structures;

Change the facade of the house and open the doors and windows on the non-load-bearing exterior wall;

Demolition of heating pipes and facilities;

Demolition of gas pipelines and facilities.

The items listed above and the first item shall be approved by the administrative department of city planning; the first item shall be approved by the heating management unit; the first item shall be approved by the gas management unit.

5.9 If the residential interior decoration in the drawings exceeds the design standard or the specification increases the floor load, the design plan shall be submitted by the original design unit of the house or the design unit with the corresponding qualification level; if the waterproof layer of the bathroom or kitchen is changed, it shall be The design proposal was proposed in accordance with the waterproof standard, and the requirements for the closed water test were proposed.

5.10 The decoration items involved in Article 5.8.5.9 of this contract shall be handled and approved by Party A in accordance with the law.

Article 6 Engineering Changes

6.1 If Party A changes the design, Party B shall send a written notice to Party B 7 days prior to the construction of the changed project.

6.2 All design changes and engineering quantity increase and decrease, Party A shall go through the signing confirmation procedure as the calculation basis for the project cost.

6.3 Due to the design change of Party A, Party B's rework costs and corresponding losses shall be borne by Party A.

6.4 Due to design changes, the backlog of Party B's materials will be handled by both parties.

6.5 Party B shall make reasonable suggestions based on the actual situation on the site, involving the change of design and replacement of the original materials, as well as the increase of the amount of work, must be approved and signed by Party A. Without the confirmation of Party A, Party B will arbitrarily change the design or replace the raw materials, Party A will not recognize it, and the expenses incurred or the losses caused by Party B shall be borne by Party B.

6.6 For Party B's infeasible design changes, Party B is obliged to inform Party A of the quality problems and consequences arising therefrom, otherwise the losses caused by Party B shall be borne by Party B. If Party A still insists on making changes, the quality problems and consequences of the project will be borne by Party A.

6.7 Other appointments: ________________________

Article 7 Material Supply

7.1 Materials and equipment that should be provided by Party A, Party A shall notify Party B before the materials and equipment arrive at the construction site. Both parties shall jointly accept the materials, equipment quantity, specifications, varieties, brand and quality, and environmental protection standards, and handle the handover procedures.

7.2 Materials and equipment that should be provided by Party B, Party B shall notify Party A before materials and equipment arrive at the construction site. Both parties shall jointly accept the materials, equipment quantity, specifications, varieties, brands and external sensory quality, and Party A shall confirm the record. Party A's acceptance of the materials does not affect Party A's claim that the engineering quality caused by the intrinsic quality of the materials provided by Party B does not meet the requirements.

7.3 After the materials and equipment provided by Party A have been accepted and confirmed by Party B, and the completion of the handover procedures, the responsibility for the custody and quality control during construction and use shall be borne by Party B.

7.4 The building decoration materials provided by Party A and Party B must comply with the “Limited Standards for Hazardous Substances in Interior Decoration” issued by the General Administration of Quality Supervision, Inspection and Quarantine, and have the inspections issued by professional testing agencies approved by the relevant administrative authorities. Qualification report.

7.5 If one party disagrees with the materials provided by the other party, it needs to be tested, and the testing fee is prepaid by its first payment. If the material is indeed unqualified, the testing cost shall be borne by the material supplier.

7.6 Other appointments: ________________________

Article 8 Quality Standards

8.1 The quality grade standard of this project is: ________________________

8.2 The construction quality control of this project shall be carried out in accordance with the following ________ items

"Code for Construction of Residential Decoration Projects".

"Code for the Acceptance of Quality of Building Decoration Engineering".

________________________________________________

8.3 At the time of completion acceptance, if the two parties dispute the quality of the project, they shall apply to the relevant engineering quality appraisal department for appraisal of the project quality. The appraisal department is determined by mutual agreement.

The appraisal fee is prepaid by Party A. After the appraisal, if the quality of the project does not meet the contractual standards, the appraisal fee shall be borne by Party B; if the project quality meets the standards stipulated in the contract, Party A shall be responsible for the appraisal expenses.

8.4 The quality level standards and quality control standards agreed by both parties shall not violate the national mandatory regulations.

8.5 Other Agreements ________________________

Article 9 Indoor Environmental Quality and Construction Requirements

9.1 After completion of the project, the indoor air quality of the house shall comply with national standards.

The acceptance criteria for indoor environmental quality of this project shall be implemented the “Code for Indoor Environmental Pollution Control of Civil Building Engineering”.

9.2 After the completion of the project, the indoor environmental quality acceptance shall be tested by the corresponding testing institutions determined by both parties. The inspection fee is prepaid by Party A.

9.3 After the completion of the project, Party B shall notify Party A of the acceptance. The indoor environmental quality acceptance shall be carried out at least 7 days after the completion of the project and before the project is delivered for use. Party A shall organize the parties involved in the construction to accept the acceptance within ________ days after receiving the acceptance notice. If Party A cannot organize the acceptance within the specified time, Party B shall be notified in time to determine the acceptance date.

9.4 If the indoor environmental quality acceptance test is qualified, the inspection cost shall be borne by Party A. If the indoor environmental quality inspection and testing fails, both Party A and Party B shall take measures to rectify and rectify and accept them separately after rectification; the rectification costs and testing costs shall be borne by the responsible party, which shall be the responsibility of Party A, and the construction period shall be postponed, which shall be the responsibility of Party B and the construction period shall not be postponed.

9.5 After the completion of the project, the indoor environmental quality has not been reviewed and accepted by both parties, and Party A’s claim for unqualified indoor environmental quality caused by Party B’s reasons is not affected.

9.6 After the indoor environmental quality acceptance, both parties shall go through the formalities of acceptance and handover.

9.7 Party B shall not clean the construction equipment with organic solvents indoors; benzene, industrial benzene, petroleum benzene, heavy benzene and mixed benzene shall not be used as diluents and solvents; asphalt anticorrosive and moisture-proof treatment agents shall not be used; Class A inorganic non-metallic building materials, decoration materials, E1 artificial wood panels and veneered artificial wood panels.

9.8 Party B shall actively cooperate with Party A to purchase products that prevent pollution from decoration.

9.9 Other appointments: ________________________

Article 10 Project Acceptance

10.1 The project is subject to the following stages to check the quality of the project.

Material acceptance;

Concealed project acceptance and mid-term project acceptance;

Completion acceptance;

10.2 Acceptance of materials shall be carried out in accordance with the provisions of Article 7 of this Contract.

10.3 Projects in which both Party A and Party B must conduct concealed works and medium-term project acceptance include: water and electric line engineering; waterproof engineering; ceiling engineering; door and window engineering; Party B shall notify Party A 48 hours in advance of any concealed project and mid-term project acceptance. If Party A does not arrive on time, Party A shall be deemed to have passed the acceptance.

10.4 After the completion of the project, Party B shall notify Party A to complete the acceptance check, and Party A shall organize the acceptance within three days after receiving the completion acceptance notice. Fill in the project acceptance form after completion acceptance.

10.5 Before the completion of the completion acceptance, Party B shall be responsible for protecting the entire safety of the finished product and the project site;

10.6 If both parties fail to go through the acceptance procedures, Party A shall not be allowed to stay. If Party A arbitrarily enters into the same inspection and acceptance, the losses caused by Party A shall be borne by Party A;

10.7 Other Agreements ________________________

Article 11 Project Delivery and Warranty

11.1 After the acceptance of this project is passed, both parties shall handle the handover procedures and sign the warranty;

11.2 This project implements the following ________ warranty period:

The warranty period for indoor decoration and decoration works under normal use conditions is two years from the date of signing by both parties. The kitchen and bathroom anti-leakage engineering with waterproof requirements is guaranteed for five years.

Other appointments: ________________________

Article 12 Payment method of construction funds

12.1 Party A shall pay Party B the construction cost according to the following ________

Instalment payment

First time: __________% of the total cost of the project paid three days before the start of construction

The second time: the project progressed more than half of the total cost of the project ________%

The third time: ________% of the total cost of the project

More than half of the above-mentioned project progress means that all the hydropower pipelines have been laid, the wall and top pipelines have all been laid, and the basic safety of doors, windows and fine wood chalk products has been completed.

other methods:________________________

12.2 After the payment of the project payment, Party B shall issue a valid and valid receipt certificate to Party A.

Article 13 Project Supervision

If the project is supervised by the project, Party A shall sign the “Construction Supervision Contract” separately with the project supervision company approved by the construction administrative department, and notify the name, unit, contact information and the duties of the supervision engineer of the supervision engineer. Party B.

Article 14 Party A matters

14.1 On the ________ day before the commencement of work, Party A shall create conditions for the construction of Party B's entrance, including: moving out the indoor furniture, furnishings or furniture, furnishings, and coverings that are difficult to move indoors, so as not to affect the construction principle. ;

14.2 Party A shall provide the water source and power source for the construction to ensure that it meets the construction needs;

14.3 Before the commencement of the project, Party A shall report the decoration registration to the property management enterprise or the housing management agency, and shall be responsible for handling the commencement procedures of the property management department and the relevant expenses that shall be paid by the owner;

14.4 Party A is responsible for coordinating the relationship between Party B's construction personnel and the neighbors;

14.5 Party A shall abide by the rules and regulations of the property management unit;

14.6 Party A shall abide by the relevant provisions of the State on residential decoration and shall not require Party B to carry out renovations involving the contents of Article 5.7 of this contract.

14.7 Party A shall not require Party B to carry out the decoration involving the contents of Article 5.8.5.9 of this contract without approval and review, and shall not require Party B to arbitrarily pierce the wall of the load-bearing wall and remove the wall of the balcony window. Body, enlarge the original door and window size or build other doors and windows, Party B shall not be required to increase the static load on the floor, install the wall or overload ceiling in the room, install large lamps and ceiling fans; Party B shall not be required to arbitrarily plan the top plate without directly wearing the pipe. Bundle or reroute the wire; Party B shall not be required to destroy or dismantle the ground waterproof layer of the kitchen or toilet and water, heating, electricity, gas and other supporting facilities; Party B shall not be required to use flammable decorative materials in large quantities.

14.9 If Party A forces Party B to violate the state regulations or violates the contract, Party A shall bear all responsibility.

14.9 If Party A still needs to use part of the house during construction, it shall be responsible for coordinating with Party B to do security and fire protection work;

14.10 Party A shall promptly participate in the supervision of the project quality construction progress, participate in the acceptance of engineering materials, concealed project acceptance, completion acceptance;

14.11 Party A is responsible for providing legal and appropriate decoration of the garbage at the other party's location, and paying Party B's garbage clearance fee by _______ yuan;

14.12 Party A shall not require Party B to occupy public space or damage the public parts and facilities of the house during construction.

14.13 Other Agreement: ________________________

Article 15 Party B matters

15.1 Party B shall review the design drawings before construction. If there is any violation of the contents of Article 5.7 of this contract in the drawings, it shall be explained to Party A, and the relevant contents shall not be constructed before the drawings are corrected. If there is any item in the drawing that refers to the contents of Article 5.8.5.9 of this contract, it shall check whether there is relevant approval and review procedures, and explain to Party A that Party B shall not construct before Party A obtains approval and review procedures.

If Party A forces Party B to violate the state regulations or violates the contract, Party A has no right to request Party B to assume the responsibility arising therefrom.

15.2 Party B shall strictly follow the design drawings.

15.3 Party B shall strictly implement the relevant national construction specifications, quality standards, safety operation procedures and fire prevention regulations during construction, and complete the project contents as stipulated in this contract on time, with safety, quality assurance and on time;

15.4 Party B shall abide by the construction safety operation rules and take necessary safety protection and fire-fighting measures in accordance with the regulations to ensure the safety of the operators, neighboring residents and surrounding houses and property, and shall not use the open flame and welding operations automatically.

15.5 Party B shall strictly implement the construction site management regulations of the provincial and municipal construction administrative departments, and shall not disturb the people and pollute the environment. No decoration or decoration activities such as knocking, chiseling, planing, drilling, etc., shall be carried out between 12:00 and 14:00 and 19:00 to 8:00 every day;

15.6 Ensure that the indoor and sewage pipes in the residential area are not cleaned and the toilets are cleaned due to construction; Party B shall be responsible for repair and loss compensation for the blockage, leakage, water stoppage and power outage of the adjacent residential houses due to construction.

15.7 Ensure that the construction site is clean and tidy, and clean the construction site after daily completion.

15.8 Responsible for the protection of finished products, equipment and living room furniture.

15.9 If Party A is a minority, Party B shall respect its national customs and habits during the construction process.

15.10 Party B shall not subcontract this project without the consent of Party A.

15.11 The garbage generated by the construction of the project shall be transported by the Party B to the construction site and transported to the legal designated place.

15.12 Other Agreement: ________________________

Article 16 Liability for breach of contract

16.1 If a party fails to perform its contractual obligations as agreed to cause losses to the other party, it shall be liable for compensation; if it is punished or caused losses in violation of relevant laws and regulations, the ultimate responsibility shall be borne by the responsible party;

16.2 If a party is unable to continue to perform the contract, it shall promptly notify the other party, and the responsible party shall bear the losses caused by the termination of the contract;

16.3 If Party A fails to pass the acceptance procedure and Party A uses the finished product in advance or automatically uses the finished product to cause losses, Party A shall be responsible;

16.4 If Party A fails to pay the construction cost without the due date, the company shall pay Party B a penalty for delaying part of the project payment for each day of delay;

16.5 As Party B's liability delays the construction period, Party B shall pay Party A a penalty for the construction project price of each contract for each day of delay.

16.6 Party B shall perform thorough rework and repair for the parts that fail to pass the quality inspection of the project. The delayed delivery of the project due to rework shall be regarded as the delay of the project, and Party B shall bear the liability for breach of contract.

16.7 If the indoor air quality is unqualified, Party B must conduct comprehensive management. Due to the delay caused by the delay in the delivery of the project due to the treatment, Party B shall bear the liability for breach of contract. 16.8 If the indoor air quality is still not up to standard and is the responsibility of Party B, Party B shall return the full price of the contract to Party A; if Party A is also responsible for the non-compliance, Party B may reduce the return ratio accordingly.

Article 17 Dispute Resolution

17.1 The disputes arising under this contract shall be settled by the parties themselves or by applying to the relevant departments for mediation. If the negotiation or mediation cannot be resolved, the following ________ methods are adopted:

Prosecuted in the ________________ People’s Court,

Arbitration to the ________________ Arbitration Commission.

Article 18 Other agreed matters ________________________

Article 19 Supplementary Provisions

19.1 The subsidiary files, drawings, visa forms and related files signed by both parties are part of this contract and have the same legal effect as this contract.

19.2 The attached file of this contract is

Attached file one: residential decoration and decoration project price list

Attached file 2: Party A provides decoration materials and equipment list

Attached file 3: Party B provides decoration and decoration materials and equipment list

Attached file four: residential decoration and decoration engineering design drawings

Attached file five: decoration and decoration project change order

Subsidiary File 6: Engineering Acceptance Form

Subsidiary File 7: Project Statement

Subsidiary File 8: Engineering Warranty

19.3 The matters not covered in this contract are supplemented by the agreement between the two parties, and the supplementary agreement has the same legal effect as this contract.

19.4 This contract is in one form, and Party A shall hold it and Party B shall hold it.

19.5 This contract is effective as of the date of signing.

person A person B:________________

Attorney: __________ Legal representative: __________

________________year month day