Chengdu City Family Room Decoration Project Construction Contract

Contract number: _________
Construction contract contractor: _________
Address: _________
Contact information:_________
phone number:_________
Construction contract contractor: _________
Unit address: _________
Legal representative: _________
Project Supervisor: _________
contact number:_________
The project designer: _________
contact number:_________
Project Manager: _________
contact number:_________
In accordance with the "Contract Law of the People's Republic of China" and relevant laws and regulations, combined with the characteristics of the construction of the family room decoration and decoration project, the two parties on the basis of equality, voluntariness and consensus, on the related matters of Party A's family room decoration and decoration project , reached the following terms:
Article 1 Project Overview
1.1 Project location and area: _________
1.2 Project cost: ¥_________ yuan, uppercase: _________
1.3 Project contracting method: The two parties agree to adopt the following _________ kinds of contracting methods.
Party B shall contract and cover all materials.
Party B shall contract labor and part of the materials, and Party A shall provide some materials;
Party B shall contract labor and Party A shall complete all materials.
1.4 Project Duration _________ Days; Start Date ______________________________________________________________________________________________________________________________________________________________________________________________________________
Article 2 Project Supervision If the project is supervised by the project, Party A and the supervision company shall separately sign the “Construction Supervision Contract” and notify Party B of the name, unit, contact information of the supervision engineer and the duties of the supervision engineer.
Article 3 The construction drawings agreed upon by both parties to adopt the following ____________ methods:
3.1 Party A shall design and provide the construction drawings by themselves. The time for the submission shall be _________ month _________ day, the drawings shall be in triplicate, and Party A, Party B and the construction team shall each hold one copy. ;
3.2 Party A entrusts Party B to design the construction drawings. The drawings shall be in triplicate. Party A, Party B and the construction team shall each hold one copy, and the design fee shall be paid by Party A;
3.3 The construction drawings shall be effective after signing by both parties.
Article 4 Party A’s obligations
4.1 _________ days before the start of construction, to create conditions for Party B's admission. All vacated or partially vacated houses shall be removed from obstacles affecting construction; protective measures shall be taken for furniture and furnishings retained in houses that can only be partially vacated, so as not to affect construction. Party B's construction personnel shall carefully check and protect the animals at Party A's construction site, and both parties shall sign a “list of items”;
4.2 Remove the original telephone equipment before starting work; provide water source and power supply during construction, and explain the precautions for use;
4.3 Responsible for coordinating the relationship between the construction team and the neighbourhood;
4.4 It is forbidden to dismantle the indoor load-bearing structure. If it is necessary to dismantle or change the load-bearing, non-load-bearing structure of the building or move the kitchen and toilet position and equipment pipeline, it shall be responsible for handling the relevant examination and approval procedures at the relevant departments; Party has no right to request Party B to move or modify heating and gas pipelines;
4.5 Participate in the supervision of project quality, construction progress and acceptance of materials entering the project and completion of the project;
4.6 The construction deposit and various property management fees received by the property management department of the project shall be paid by Party A, and Party B shall assist in providing relevant materials required for property management.
Article 5 Obligation of Party B
5.1 Strictly implement the National Construction Code for Residential Decoration Engineering during construction to ensure the quality of the project and complete the project on schedule;
5.2 It is strictly forbidden to change the main body of the building, the load-bearing structure, the heating and gas pipelines before Party A has officially provided the approval documents of the relevant departments, otherwise the corresponding responsibilities shall be undertaken;
5.3 Strictly implement the regulations on construction site management in this Municipality, and shall not disturb the people and pollute the environment;
5.4 Protect the furniture and furnishings in the original room to ensure the smooth flow of the upper and lower pipes in the living room;
5.5 Ensure that the construction site is clean and tidy, and it is responsible for cleaning the construction site after the completion of the project;
5.6 Party B shall be responsible for the fines and compensations caused by Party B's violation of property management regulations during construction;
5.7 Party B's designers are responsible for providing consulting, design, quotation and other related services to Party A. After the contract is signed, Party B’s representative of the project construction will be the project manager sent by Party B. Party A shall contact Party B's project manager for matters related to the project to ensure unified command and management in the project.
Article 6 Engineering changes
6.1 In order to ensure the quality, duration and warranty service of Party A, if there is any change in the project or construction method after the contract is signed, the written agreement “Decoration and Decoration Project Change Order” shall be signed by both parties after negotiation, and the relevant project costs shall be adjusted. The construction period, verbal commitment or verbal agreement shall be deemed invalid; Party A shall directly assume the consequences caused by Party A's direct agreement with Party B's on-site staff to change the construction contents;
6.2 After the signing of the contract, Party A shall pay Party B a change fee of 8% of the total amount of the deduction if it exceeds 5% of the total project cost. If Party B's materials used for Party A's deduction are ordered or shipped to the site, Party A shall pay additional materials for return shipping, loss and return; if Party A requests the reduced construction project to be constructed, Party A shall pay Party B the construction of the project. Fees, materials, management fees and demolition fees;
6.3 If Party A pays for the construction after the second payment of the project, Party B shall construct the construction project after receiving 100% of the construction cost of Party A.
Article 7 Provision of materials
7.1 The materials and equipment provided by Party A shall meet the design requirements in terms of specifications and quality. Party A shall transport the materials and equipment to the construction site on time and notify Party B. The two parties shall jointly accept and handle the handover procedures; if Party A fails to provide the specifications and quality of the materials or materials on time, it does not meet the design requirements, thereby delaying the construction period or Affect the quality of the project, and the responsibility shall be borne by Party A;
7.2 If the materials and equipment provided by Party B shall be notified to Party A in advance of the materials and equipment delivered to the construction site, both parties shall jointly accept the goods; if the brand, specifications and quality of the materials supplied by Party B do not conform to the quotation, The party has the right to refuse to use, thereby delaying the construction period or affecting the quality of the project, and the responsibility is borne by Party B;
7.3 Party A shall determine the brand, specification, model or price standard of the material. Party B shall be responsible for the purchase of Party A, and shall be used after the materials are transported to the construction site and confirmed by Party A. Party B shall charge Party A's material purchasing fee as material mining pipe fee + material transportation fee; if the return, exchange, and thus the construction period due to material quality problems during the construction process, Party A shall be responsible;
7.4 Except as indicated in the contract, hardware, stone, ceramic tile, equipment, sanitary ware, lamps, etc., shall be purchased by Party A and delivered to the site on time; if Party B is required to purchase, the purchase fee of _________% of the purchased materials shall be added. And transportation costs.
Article 8 Delay in construction period
8.1 Delay in completion date for the following reasons, confirmed by Party A, the construction period shall be postponed accordingly:
Engineering volume changes and design changes;
force majeure;
Party A did not stop the work due to the stage acceptance at the time;
Party A agrees with other circumstances in which the construction period is postponed.
8.2 If Party A fails to complete its work in accordance with the agreement and affects the construction period, the construction period shall be postponed; if the quality of the materials and equipment provided by Party A is unqualified and affect the quality of the project, the rework expenses shall be borne by Party A, and the construction period shall be postponed;
8.3 Party A fails to pay the construction cost on time, and the contract period is postponed accordingly;
8.4 If the construction cannot be completed on time due to Party B's materials supply or construction, the construction period will not be postponed; if there is any problem in the quality of the project due to Party B's reasons, the rework costs shall be borne by Party B and the construction period will not be postponed.
Article 9 Quality Standards
9.1 The parties agree that the construction quality of the project shall be checked and accepted according to the following criteria:
"Gb50210-2001 Building Decoration Engineering Quality Acceptance Specification"
"Chengdu Family House Decoration and Decoration Project Quality Acceptance Regulations"
Other acceptance criteria: _________
9.2 When the two parties dispute the quality of the project during the construction process:
Can mediate complaints with the Chengdu Consumers Association Family Decoration Complaint Center or the Chengdu Building Decoration Association;
If the mediation is not accepted, the project quality inspection agency agreed by both parties shall determine the required expenses and the losses caused thereby, and the responsible party shall bear the responsibility. Both parties have responsibilities, which are borne by both parties in accordance with their responsibilities.
Article 10 Project acceptance and warranty
10.1 The parties agree to check the quality of the project in the following three stages during the construction process:
Acceptance of concealed works such as water, electric pipelines, waterproofing layers and suspended ceilings;
Acceptance of paint and surface coating before construction;
Completion acceptance. Party B shall notify Party A to check the acceptance of each stage two days in advance, and the project acceptance form shall be filled after the acceptance of each stage. If Party A receives the notice and fails to participate in the inspection and acceptance on time, Party B has the right to stop working, and Party B shall bear the delays and other losses caused to Party B;
10.2 After the completion of the project is completed and the balance of the project is settled, Party B shall go through the formalities for the transfer and complete the project warranty.
Article 11 Payment method of project payment
11.1 The parties agree to pay the construction cost in the following _________ manner:
After the contract takes effect, Party A shall pay the construction cost directly to Party B's finances according to the agreement in the following table:
Payment time payment time payment proportion of payment amount The first time the contract is signed on the date of the second concealed project acceptance, the other payment method within 4 days after the third completion acceptance test: _________
11.2 Within 2 days after the acceptance of the project, Party B shall submit the project settlement to Party A and send the relevant materials to Party A. If Party A has no objection within 2 days after receiving the information, both parties shall sign the project settlement statement, and Party A shall also settle the final payment to Party B at the same time.
11.3 Party A shall directly transfer the project funds to Party B's Finance Department. After all the project funds have been settled, Party B shall issue a formal unified invoice to Party A. If Party A causes the loss to be directly paid to Party B's construction personnel, Party A shall be responsible for the loss.
Article 12 Liability for breach of contract
12.1 After the signing of the contract, if either party proposes to terminate the contract or if the contract fails to perform due to any reason, it shall promptly notify the other party. After the parties have agreed to do so, they may terminate or postpone the performance of the contract. The defaulting party shall The observant party pays _________% of the project cost; if the loss is caused, the defaulting party shall compensate;
12.2 If the project is not accepted or has not been settled and has not been handed over, if Party A uses or arbitrarily uses the finished product, the project shall be deemed qualified, and Party A shall be responsible for the loss, and Party A shall automatically waive the warranty. And the right to repair and Party B still has the right to recover the final payment;
12.3 If Party A fails to pay the second project payment on time, Party B has the right to suspend the work, and Party B shall pay Party B a penalty of 2‰ of the total project cost for each delay;
12.4 Due to the reasons of Party B, the quality of the project will not meet the quality standards agreed by both parties, and Party B shall be responsible for the repair. The repair cost shall be borne by Party B and the construction period shall not be postponed.
12.5 Due to the delay of the construction period caused by Party A or Party B, each time the delay is delayed, the responsible party will pay 2% of the total project cost as liquidated damages.
Article 13 Settlement of Contract Disputes When disputes between the two parties are resolved, the following _________ methods shall be adopted:
Apply to the _________ Arbitration Commission for arbitration;
Prosecuted to the people's court
Article 14 Several specific provisions
14.1 For the decoration works outside the urban area of ​​the project site, Party B shall charge a remote construction fee of 3%-10% of the total construction cost;
14.2 For the garbage generated due to the construction of the project, Party B shall be responsible for the removal and transportation to the garbage dumping point prescribed by the government. Party A shall pay the garbage clearing fee for _________ yuan;
14.3 During the construction period, Party A shall hand over the key of the outhouse door to the construction authority of Party B _________ for custody. After the completion of the project handover, Party A shall be responsible for providing the new lock _________, and Party B shall be responsible for the installation and delivery of Party A on the spot;
14.4 During the construction period, Party B's daily working hours are: _________ points _________ points to _________ points _________ points; afternoon _________ points _________ points to _________ points _________ points .
Article 15 Supplementary Provisions
15.1 The project may not be subcontracted after the signing of this contract;
15.2 If Party A and Party B directly sign the contract, the contract shall be in duplicate and shall be effective upon signature by both parties. Party A and Party B shall each hold one copy;
15.3 Where the contract is signed in the home decoration and decoration market of this Municipality, this contract shall be made in triplicate, and both Party A and Party B and the relevant departments of the market shall take effect after signing, and each of the three parties shall hold one copy;
15.4 Automatic termination after the completion of the contract;
15.5 This contract implements the voluntary certification of the parties to protect the legitimate rights and interests of the parties to the contract.
15.6 The subordinate file of the contract is an integral part of this contract and has the same legal effect as this contract.
Article 16 Other agreed terms _________
person A person B:_________
Legal representative: _________ Attorney: ______
_________Year ____________________________________________________________________________________________________________________________________________________________________________________________
Attorney: _________
contact number:_________
_________ Year ________________ Contract Attachment:
Subsidiary File 1: Home Decoration Project Construction Project Confirmation Form Attachment File 2: Home Decoration Project Contents and Practice List Attachment File 3: Home Decoration Project Quotation Attachment File 4: Party A provides decoration and decoration materials list attached file 5: Party B provides a list of decorative materials and accessories. Attachment file 6: Home decoration project design drawings Attachment file 7: Decoration and decoration project change order subsidiary file 8: Project acceptance form subsidiary file IX: Project settlement form subsidiary file 10: Engineering warranty