Home decoration project contract

Employer: ________________________
residence:______________________
phone:____________
fax:____________
Attorney: ________________________
phone:____________
fax:____________
contractor:________________________
residence:______________________
phone:____________
fax:____________
Legal representative: ________________________
phone:____________
The project designer: ________________________
phone:____________
Construction team leader: ________________________
phone:____________
In accordance with the "Contract Law of the People's Republic of China" and relevant laws and regulations, on the basis of equality, voluntariness and consensus, both parties shall reach the following agreement on matters concerning the decoration and decoration of the family's homes:
Article 1 Project Overview
1. Project Name: __________________________________.
2. Project location: __________________________________.
3. Contracting scope: Please refer to the budget statement of the subsidiary file of the contract.
4. Project contracting method: The two parties agree to adopt the following ____________ kinds of contracting methods: contractor's contract work and materials; contractor contract work, package part auxiliary materials, and the contractor provides the main materials for decoration; contractor contractor and contractor package.
Article 2 The construction drawings of the construction drawings shall be provided by the following ____________ methods: the contractor shall design and provide the construction drawings, the drawings shall be in duplicate, one for the contractor and the contractor; the contractor shall entrust the contractor to design the construction drawings. The design fee is ____________ yuan and is paid by the contractor.
After the construction drawings have been confirmed by both parties, the provider shall be responsible for obtaining confirmation or approval from the relevant department within ____________ before the agreed start date.
The construction drawings shall be in duplicate, and each party shall hold one copy as the subsidiary file of this contract.
Article 3 Party A's work
1. Before the start of construction _______ days, all vacated or partially vacated houses, clear obstacles, take protective measures for the furniture and furnishings of houses that have not been fully vacated, and prepare for the contractor to enter the market.
2. Handling various applications and approvals required for the construction of the project to ensure that Party B can smoothly enter the construction site, except for the procedures that should be handled by Party B in accordance with laws, regulations and rules.
3. Provide water source and power source that meet the construction requirements, and coordinate the relationship between the neighborhood and the management organization.
4. Participate in the supervision of project quality and construction progress, and be responsible for material entry and completion acceptance confirmation.
5. If part of the house is still needed during construction, it shall be responsible for the protection of the construction site, etc., and should pay attention to provide various convenient conditions for construction.
6. Pay the engineering fee according to the agreed time limit, and pay various taxes and fees that should be borne by the company according to the regulations.
Article 4 Party B's work
1. Participate in the relevant construction drawings or practice instructions meeting or on-site disclosure, and draw up the construction plan and plan to submit the confirmation to the Party A.
2. Strictly implement safety construction sweeping specifications, fire protection regulations, construction specifications and quality standards during construction, and complete the project on schedule.
3. The original building structure and various equipment pipelines shall not be arbitrarily demolished without the consent of Party A or the approval of the relevant department.
4. Protect the furniture, furnishings and water and electricity pipelines in the original room to ensure the smoothness of the indoor and sewer pipes.
5. If Party A needs to confirm the relevant matters during the construction process, it shall promptly and give it the necessary preparation time.
6. Strictly implement the regulations on construction site management, and must not disturb the people and pollute the environment; ensure the cleanliness of the construction site, and clean the construction site after the project is completed.
7. Before the project is completed and not handed over to Party A, it is responsible for protecting the facilities and finished products on site.
Article 5 About the construction period
1. Project deadline ___________ days, start date __________ years ____________ months ____________ days, completion date _______ years _______ months _______ days.
2. If the construction period is delayed due to reasons of Party A and its agents, the construction period will be postponed. If the construction period is delayed due to reasons of Party B and its agents, the construction period will not be postponed.
3. If the work cannot be completed due to the following factors, the construction period will be postponed, and the two parties will not bear responsibility for each other: encountering force majeure such as bad weather, water stoppage, power outage, natural disaster, war, riot, etc., which seriously affects the construction; Changes and design changes; engineering delays due to third parties not related to Party A and Party B. Third-party factors include, but are not limited to, the unreasonable behavior of the regulatory agencies and neighbors in the region; new materials or new The delay of the construction period caused by the adoption of the process or the waste of the test time; other situations in which the contractual agreement is extended by both parties.
Article 6 on the supply and storage of materials
1. The materials and equipment that any party is responsible for shall be qualified products that meet the requirements of laws and regulations, and must also meet the standards and design requirements stipulated in this contract. The supplier shall deliver the materials and equipment to the construction site on time and in quantity, and notify the other party of the acceptance and signature confirmation.
2. If any materials and equipment provided by one party are inconsistent with the quality requirements or specifications, the other party has the right to request replacement, and the provider shall replace it. The resulting increase in costs is partly borne by the provider.
3. After the materials and equipment enter the site, Party B shall be responsible for the custody and use. If it is not wasted, damaged or lost due to improper storage or improper use, Party B shall be responsible for it, except for the normal consumption during the construction process.
Article 7 on quality and acceptance
1. The project is based on construction drawings, method descriptions, design changes, and the National Standard of the People's Republic of China, “Construction Specifications for Residential Decoration Engineering” as the quality assessment acceptance criteria.
2. Both Party A and Party B shall promptly handle the inspection and acceptance procedures for concealed works and intermediate works; if Party A does not participate in the acceptance on time, the construction period shall be postponed.
3. Party A shall be responsible for the quality of the project caused by Party A's unauthorized directing of Party B's personnel or third party personnel. If Party B is responsible for rework, Party A shall be responsible for the rework costs.
4. After the completion of the project, Party B shall notify Party A of the acceptance, and Party A shall organize the acceptance and acceptance within _______ days after receiving the acceptance notice, and go through the formalities of acceptance and acceptance.
5. At the time of acceptance, when the project qualification rate reaches ____________%, the repair or rework of other non-conforming items will not affect the establishment of the completion date, and Party A shall confirm this.
6. Party B promises to guarantee the project for _______ years from the date of completion. Damages, improper use, vandalism, and damage from non-engineering reasons are not covered by the warranty. If the state administrative department or industry organization has issued a specific warranty period or exemption for the individual engineering project or material before the signing of this contract, the provisions of the state administrative department or industry organization shall prevail.
7. Other warranty or warranty-free conditions agreed by Party A and Party B: _________________________.
8. If the project is not accepted, Party A shall not use it first.
Article 8 About the project price and settlement
1. The parties agree to pay the construction cost in the following ____________ manner:
After the contract takes effect, the contractor pays the contractor directly the construction cost as follows:
Payments ____________ Payment phase or time ____________ The amount of payment is _________________________ for the first time ____________ yuan;
The second ______________________ payment ____________ yuan;
The third ______________________ payment ____________ yuan;
After the fourth ____________ project acceptance, _______ days will pay 5% of the total project cost, about ____________ yuan.
Other payment methods: ______________________.
2. Both parties agree that the settlement method of the project will be settled according to the following ____________ categories:
Fixed price, the total price of the project is ____________ yuan;
The unit price is the same, calculated according to the actual quantity plus the loss rate, but the total price cannot exceed ____________ yuan.
a. Latex paint and paint are: wall area + top area + 6% × mosaic area;
b. The area of ​​the tile is: actual area + 6% × actual area;
c. The area of ​​solid wood floor is: actual area +6% × actual area, mosaic area +10% × mosaic area;
d. The area of ​​woodworking wardrobes is: actual area;
e. Other items are calculated by item;
f. Other items calculated in square meters are: actual area + 6% × actual area;
g. The specific items are quoted after the measurement project is measured;
h. The project purchased by Party A is purchased at the cost of the budget and can be adjusted with the consent of Party A.
3. Special fee agreement:
During the construction process, Party A shall be responsible for all water and electricity costs incurred at the construction site.
During the construction process, if the party's factors violate the rules and are fined by the law enforcement agency or the administrative agency, the fine shall be paid by Party B. If Party B's behavior is caused by Party A's forced request or command, Party A shall be responsible for the fine.
Taxes and fees are not listed in the budget record of the subordinated archives. The taxes and fees shall be paid by Party A to the relevant departments according to the actual amount of taxation; if the taxes and fees have already been specified, Party B shall be responsible for paying the taxes.
If the property management agency collects transportation costs beyond the normal residential area, Party A shall be responsible for negotiating or subsidizing the difference to Party B.
4. Party B shall execute the budget attached file project signed by both parties. If Party A adds a new project, the contract will be signed separately. Involving the amount, Party A shall pay Party B to Party B before the project acceptance according to the method of prepayment 50% and project completion 50%. If the material payment is greater than 50% of the project, Party A shall pay Party B the materials according to the actual proportion.
5. After the project is qualified, Party B shall send the relevant materials to Party A, and the two parties shall settle the project. If the contractor has no objection within the day after receiving the information, it shall be deemed to agree to settle the project according to the data. Both parties shall fill in the project settlement statement and sign it. Party A shall pay the Party's construction cost in accordance with the aforementioned time limit.
Article 9 The project budget file belongs to the subsidiary file of this contract. The listed projects shall not be added, changed or deleted at will, except with the consent of both parties.
Article 10 Responsibilities and Penalties
1. Party B shall be responsible for matters such as construction dispatching and safety management, and other personnel including Party A shall not interfere unreasonably. Party A arbitrarily directs the workers or performs any operations in person, and Party A is fully responsible for the losses and accidents caused.
2. If the construction period is delayed due to the reasons of Party B and its agents, Party A shall pay Party A a penalty of ____________ for each day of delay.
3. If the construction period is delayed due to the reasons of Party A and its agents, Party B shall compensate Party B for the loss of labor expenses.
4. If Party A fails to pay Party B's project payment in full according to the agreed time limit, Party B shall pay Party B a deferred payment liquidated damages in accordance with ____________.
5. If the acceptance procedure is not completed, Party A shall be responsible for the loss caused by Party A in advance or by unauthorized use of the finished product.
6. If, for one reason, the contract cannot be continued, the party shall promptly notify the other party to complete the contract termination procedure and the responsible party shall compensate the other party for the corresponding economic loss.
7. If Party B encounters force majeure to affect construction, it shall take timely measures to avoid loss expansion and notify Party A of the relevant situation. Otherwise, it shall be liable for the expansion of the damage caused.
Article 11 If a dispute arises between the two parties on the execution of the contract, it shall be settled through friendly negotiation: if the negotiation is invalid, it may be submitted to the people's court for litigation.
Article 12 Supplementary Provisions
1. This contract is made in two copies, each party holds one copy and has the same legal effect.
2. This contract is automatically terminated upon completion of performance.
Party A: ________________________ Party B: ____________
On-site representative: ___________________ On-site representative: ____________
Document Name: ______________________ Document Name: ______________________
Authority: ______________________ Authority: ______________________
ID number: ______________________ ID number: ______________________
__________ Year ____________________________________________________________