About the construction contract of the family room decoration project

Contractor: Contractor: Qualification level: According to the laws of China, both parties shall sign this decoration contract after reviewing the decoration qualification of Party B. The specific terms are as follows:

1. Project Overview:

2. Project name: ____ location ____ contracting scope _____ contracting method ____ contracting content

3, construction period

4. Engineering quality standards:

5. Project cost:

6. Payment method: After the contract takes effect, Party A will pay the construction cost directly to Party B in the following ways:

7. After the project is qualified, Party B shall submit the project settlement to Party A and send the relevant materials to Party A. If Party A receives the information and does not have any objection after ________, it shall be deemed to agree. Both parties shall fill in the project settlement statement and sign it. Party A shall settle the final payment of the project to Party B at the time of signing.

8. After all the construction funds have been settled, Party B shall issue a formal unified invoice to Party A.

9. Liability for breach of contract 1) If either party to the contract fails to perform the contract or violates national laws, regulations and relevant policies, the responsible party shall be liable for the penalty or economic loss to the other party and compensate the other party. If the economic loss caused does not cause any loss, it shall pay 5% of the total contract price as liquidated damages; 2) If the acceptance procedure is not completed, Party A shall be responsible for the loss caused by Party A's use in advance or unauthorized use of the finished product; If, for one reason, the contract cannot continue to be performed, the party shall promptly notify the other party to complete the contract termination procedure, and the responsible party shall compensate the other party for the corresponding economic loss; 4) Party A fails to pay the second construction payment on schedule. The payment of 1% of the total contract price to the other party for each day of delay is a liquidated damage; 5), due to Party B's reasons, the quality of the project does not meet the quality standards agreed by both parties, and Party B is responsible for repairs, and the construction period is not extended; 6) The reason is that the construction period is delayed, and 1% of the total contract price is paid to the other party for each delay as a penalty;

10. Settlement of contract disputes When disputes between the two parties are resolved, the following __________ methods shall be adopted: 1. Apply for arbitration to the Arbitration Commission of the locality of Party A; 2. Prosecute to the people's court of the place where the contract is signed.

11. Other specific regulations 1) The garbage generated by the construction of the project shall be transported out of the construction site by Party B, and shall be responsible for transporting the garbage to the designated ________________ location. Party A shall be responsible for paying the garbage clearance fee by ______ yuan; During the construction period, Party A shall hand over the key of the outhouse door to the responsible person of the construction team of Party B. After the project is completed and accepted, Party A is responsible for providing the new lock _____, which shall be installed and delivered by Party B on the spot.

3) During the construction period, Party B's daily working hours are: __________ points in the morning _______ points to ______ points _______ points; ______ points in the afternoon _______ points to ______ points _______ points .

12. Supplementary Provisions 1) This contract shall be signed by both Party A and Party B. The contract shall be in duplicate, and both Party A and Party B shall hold one copy. This contract shall become effective after being signed by both Party A and Party B.

2) After the signing of this contract, the project may not be subcontracted.

3) The contract is automatically terminated after it has been fulfilled.

4) The subsidiary file of this contract is an inseparable part of the contract and has the same legal effect as this contract.

Party A: Representative: Date of signing: Year, month and day