Construction and Decoration Engineering Construction Contract (Type B) (Demonstration Text)
Contractor:
Contractor:
In accordance with the "Economic Contract Law of the People's Republic of China" and the "Construction and Installation Contracts Regulations", the two parties reached the following agreement in light of the specific circumstances of the project.
Article 1, project overview
1.1 Project Name:
1.2 Project Location:
1.3 Contracting scope:
1.4 Contracting method:
1.5 Construction period: The project starts on the day of the year and is completed on the day of the month.
1.6 Project Quality:
1.7 contract price:
Article 2, Party A's work
2.1 The day before the commencement of construction, Party B shall provide Party B with the confirmed construction drawings or instructions for the implementation, and shall submit the on-site disclosure to Party B. All vacated or partially vacated houses will remove obstacles that affect construction. Take protective measures for furniture and furnishings that are left in houses that can only be partially vacated. Provide Party B with water, electricity, gas and telecommunications equipment required for construction, and explain the precautions for use. Handle various procedures and approvals involved in the construction.
2.2 Designated as the representative of Party A in the construction site, responsible for the performance of the contract. Supervise and inspect the quality and progress of the project, and handle the acceptance, change, registration procedures and other matters.
2.3 Entrusting the supervision company to carry out engineering supervision, the supervision company is appointed as the chief management engineer, and its duties shall be clearly defined in the supervision contract, and a copy of the contract shall be submitted to Party B.
2.4 Responsible for the protection of surrounding buildings and decoration, equipment pipelines, ancient and famous trees, green spaces, etc. are not damaged, and bear the corresponding costs.
2.5 If it is necessary to dismantle the original building structure or equipment pipeline, it is responsible for going through the relevant approval procedures to the relevant departments.
2.6 Coordinate relevant departments to do on-site security, fire protection, garbage disposal, etc., and bear corresponding costs.
Article 3, Party B's work
3.1 Participate in the on-site submission of the construction drawings or practices of Party A's organization, draw up the construction plan and progress plan, and submit it to Party A for approval.
3.2 Designated as the representative of Party B in the construction site, responsible for the performance of the contract. Organize the construction as required, guarantee the quality, quantity and complete the construction tasks on time, and solve all the matters that Party B is responsible for.
3.3 Strictly implement construction specifications, safety operation procedures, fire safety regulations, and environmental protection regulations. Carry out the construction in strict accordance with the drawings or practice instructions, and do a good job in all quality inspection records. Participate in the completion acceptance and prepare the project settlement.
3.4 Comply with the regulations of the construction site management of the national or local government and relevant departments, and properly protect the buildings, equipment pipelines and ancient and famous trees around the construction site from damage. Do a good job in construction site security and garbage disposal, and handle the problem of disturbing people due to construction and the relationship with surrounding units.
3.5 During the construction, the original building structure and various equipment pipelines shall not be arbitrarily changed without the consent of Party A or the approval of the relevant departments.
3.6 Before the completion of the project, Party A shall be responsible for the protection of all facilities and finished products on site.
Article 4, agreement on the duration of work
4.1 If Party A requires the completion of the work period earlier than the contract, Party B shall obtain the consent of Party B and pay the measures taken by Party B for the work.
4.2 Because Party A did not complete the work as agreed, affecting the construction period, the construction period will be postponed.
4.3 Due to the responsibility of Party B, it is not possible to start work on schedule or stop work without any reason, which will affect the construction period and the construction period will not be postponed.
4.4 Due to design changes or non-party B reasons for power outages, water cuts, gas outages and force majeure factors, the work will be stopped for more than 8 hours, and the construction period will be postponed accordingly.
Article 5, Agreement on Project Quality and Acceptance
5.1 The construction and acceptance criteria formulated by the State, such as construction drawings, method descriptions, design changes, and “Code for Construction and Acceptance of Building Decoration Engineering” and “Unified Standard for Quality Inspection and Evaluation of Building Installation Engineering”, are the quality assessment acceptance criteria.
5.2 The quality of the project should meet the national quality assessment eligibility criteria. When Party A requests that some or all of the projects meet the good standards, Party B shall pay Party B the additional fees.
5.3 Both Party A and Party B shall promptly handle the inspection and acceptance procedures for concealed works and intermediate works. Party A shall not participate in the concealed works and intermediate works acceptance on time, and Party B may accept the goods on its own, and Party A shall acknowledge it. If Party A requests re-inspection, Party B shall conduct re-inspection as required. If the re-inspection is qualified, Party A shall bear the cost of re-inspection, resulting in suspension of work, and the construction period shall be postponed; if the re-inspection is unqualified, the re-inspection and rework expenses shall be borne by Party B, but the construction period shall be postponed.
5.4 Due to the unqualified quality of materials and equipment provided by Party A, the quality of the project will be affected. The rework cost will be borne by Party A and the construction period will be postponed.
5.5 Due to the quality accident caused by Party B, the rework cost shall be borne by Party B, and the construction period will not be postponed.
5.6 After the completion of the project, Party B shall notify Party A of the acceptance. Party A shall organize the acceptance and acceptance within the day of receiving the acceptance notice, and shall go through the formalities of acceptance and handover. If Party A fails to organize the inspection and acceptance within the specified time, Party B shall be notified in time to determine the acceptance date. However, Party A shall acknowledge the date of completion and bear the costs of supervision and related expenses of Party B.
Article 6, Agreement on the price of the project and settlement
6.1 The parties agree to adopt the first type of the price of this contract:
Fixed price.
Fixed price plus % dry risk factor calculation. The risk of inclusion includes content.
Adjustable price: Calculate the cost according to the relevant national engineering pricing regulations, and adjust and complete the settlement according to relevant regulations.
6.2 After the contract comes into effect, Party A shall pay the project payment according to the following agreement, and settle the settlement once the completion of the settlement.
---------------------------
| Appropriation in arrears | Grants % | Gold Amount |
|----------|-------|------|
| | | |
|----------|-------|------|
| | | |
|----------|-------|------|
| | | |
---------------------------
6.3 After the project is completed and accepted, Party B shall submit the project settlement and send the relevant materials to Party A. Party A shall complete the review within the above-mentioned data and fail to file a protest at the expiration date. And within the day, settle the final paragraph.
Article 7, Agreement on the supply of materials
7.1 The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements and shall be supplied to the site on time. Where Party B agrees to pick up the goods, Party A shall hand over the delivery procedures to Party B, and Party B shall bear the transportation expenses. The materials and equipment supplied by Party A have quality problems or differences in specifications, causing losses to the project, and responsibility shall be borne by Party A. The materials supplied by Party A shall be custody by Party B after acceptance by Party B. Party A shall pay the storage fee of % of the material value. Party B shall be responsible for compensation for the loss caused by improper storage by Party B.
7.2 All materials and equipment purchased by Party B shall be prohibited if they do not meet the quality requirements or specifications. If it has been used, Party B shall be responsible for the losses caused to the project.
Article 8, Agreement on Safety Production and Fire Prevention
8.1 The construction drawings or practices provided by Party A shall comply with the Fire Services Regulations of the People's Republic of China and relevant fire protection design codes.
8.2 Party B shall strictly abide by the "Safety Technical Regulations for Building Installation Engineering", "Safety Operation Procedures for Construction and Installation Workers", "Fire Regulations of the People's Republic of China" and other relevant regulations and norms during construction.
8.3 Party A shall bear all economic losses arising from the occurrence of safety or fire accidents due to violation of relevant safety operation rules, fire regulations and fire protection design specifications due to the drawings or practices confirmed by Party A.
8.4 As Party B violates relevant safety operation rules and fire regulations during the construction and production process, resulting in safety or fire accidents, Party B shall bear all economic losses caused by this.
Article 9, Responsibility and Liability for Breach of Contract
9.1 Due to the delay of construction or the suspension of work due to Party A's reasons, Party A shall compensate Party B for the losses caused by work stoppage and work. Party A shall pay Party B for each day of work or work. Party A does not make payments according to the contractual agreement. For each one-day delay, the late payment fee is paid according to the % of the payment.
9.2 Due to Party B's reasons, Party B shall pay Party A's liquidated damages for each day overdue. Party A requires early completion, in addition to paying the rushing measures, Party A pays Party B every one day in advance as a reward.
9.3 If Party B meets the requirements of Party A and all or part of the project meets the excellent standards, Party A shall pay Party B as a reward, in addition to increasing the premium price in accordance with paragraph 5.2 of this contract.
9.4 Party B shall properly protect the equipment provided by Party A and the furniture, furnishings and finished products piled up on site. If losses are caused, compensation shall be made according to the price.
9.5 Party A has not gone through any formalities and has agreed to dismantle the original building structure or equipment pipeline without authorization. Party A shall be responsible for and bear the loss.
9.6 Without the consent of Party A, Party B shall dismantle the original building structure or equipment pipeline without authorization, and Party B shall be responsible for and bear the loss caused by the loss or accident.
9.7 If the acceptance procedure is not completed, Party A shall use it in advance or use it automatically, and Party A shall be responsible for the loss.
9.8 If the contract cannot continue to be performed due to one reason, the other party shall be notified to handle the contract termination agreement, and the responsible party shall compensate the other party for the economic losses caused thereby.
Article 10, Dispute or Dispute Resolution
10.1 During the performance of this contract, if there is a dispute between the two parties, the two parties may resolve the dispute or ask the relevant departments to mediate without affecting the progress of the project.
10.2 If the parties are unwilling to resolve through negotiation or mediation, or if the mediation fails, the parties to the dispute arising from the execution of this contract shall agree to be arbitrated by the Arbitration Commission.
Article 11, other agreements
Article 12, Supplementary Provisions
12.1 When the project requires warranty or insurance, an agreement shall be made.
12.2 The original of this contract is two copies, each party holds one copy. A copy of the copy, Party A, and Party B.
12.3 This contract is automatically terminated upon completion of performance.
12.4 Attached Files
Construction drawings or practices
Project list
Project budget
Party A provides the list of goods
Minutes of the meeting
Design changes
other
person A person B:
Legal representative: legal representative:
Agent: Agent:
Unit address: unit address:
Phone: Phone:
Fax: Fax:
Postal code: Postal code:
Bank of deposit: Bank of deposit:
Account Name: Account Name:
Account number: Account number:
Year, month, day, month, day
Schedule 1: List of XXX Engineering Party A Supply Materials and Equipment
------------------------------------------
| Order | Materials or Equipment | Specifications | Single | Number | | Supply | Delivery |
| | | | | | Price | | |Remarks|
| No. | Name | Model | Bit | Volume | | Time | Location |
|---|-----|----|---|---|----|----|----|--|
| | | | | | | | | |
|---|-----|----|---|---|----|----|----|--|
| | | | | | | | | |
|---|-----|----|---|---|----|----|----|--|
| | | | | | | | | |
------------------------------------------ Ministry of Construction / State Administration for Industry and Commerce
Contractor:
In accordance with the "Economic Contract Law of the People's Republic of China" and the "Construction and Installation Contracts Regulations", the two parties reached the following agreement in light of the specific circumstances of the project.
Article 1, project overview
1.1 Project Name:
1.2 Project Location:
1.3 Contracting scope:
1.4 Contracting method:
1.5 Construction period: The project starts on the day of the year and is completed on the day of the month.
1.6 Project Quality:
1.7 contract price:
Article 2, Party A's work
2.1 The day before the commencement of construction, Party B shall provide Party B with the confirmed construction drawings or instructions for the implementation, and shall submit the on-site disclosure to Party B. All vacated or partially vacated houses will remove obstacles that affect construction. Take protective measures for furniture and furnishings that are left in houses that can only be partially vacated. Provide Party B with water, electricity, gas and telecommunications equipment required for construction, and explain the precautions for use. Handle various procedures and approvals involved in the construction.
2.2 Designated as the representative of Party A in the construction site, responsible for the performance of the contract. Supervise and inspect the quality and progress of the project, and handle the acceptance, change, registration procedures and other matters.
2.3 Entrusting the supervision company to carry out engineering supervision, the supervision company is appointed as the chief management engineer, and its duties shall be clearly defined in the supervision contract, and a copy of the contract shall be submitted to Party B.
2.4 Responsible for the protection of surrounding buildings and decoration, equipment pipelines, ancient and famous trees, green spaces, etc. are not damaged, and bear the corresponding costs.
2.5 If it is necessary to dismantle the original building structure or equipment pipeline, it is responsible for going through the relevant approval procedures to the relevant departments.
2.6 Coordinate relevant departments to do on-site security, fire protection, garbage disposal, etc., and bear corresponding costs.
Article 3, Party B's work
3.1 Participate in the on-site submission of the construction drawings or practices of Party A's organization, draw up the construction plan and progress plan, and submit it to Party A for approval.
3.2 Designated as the representative of Party B in the construction site, responsible for the performance of the contract. Organize the construction as required, guarantee the quality, quantity and complete the construction tasks on time, and solve all the matters that Party B is responsible for.
3.3 Strictly implement construction specifications, safety operation procedures, fire safety regulations, and environmental protection regulations. Carry out the construction in strict accordance with the drawings or practice instructions, and do a good job in all quality inspection records. Participate in the completion acceptance and prepare the project settlement.
3.4 Comply with the regulations of the construction site management of the national or local government and relevant departments, and properly protect the buildings, equipment pipelines and ancient and famous trees around the construction site from damage. Do a good job in construction site security and garbage disposal, and handle the problem of disturbing people due to construction and the relationship with surrounding units.
3.5 During the construction, the original building structure and various equipment pipelines shall not be arbitrarily changed without the consent of Party A or the approval of the relevant departments.
3.6 Before the completion of the project, Party A shall be responsible for the protection of all facilities and finished products on site.
Article 4, agreement on the duration of work
4.1 If Party A requires the completion of the work period earlier than the contract, Party B shall obtain the consent of Party B and pay the measures taken by Party B for the work.
4.2 Because Party A did not complete the work as agreed, affecting the construction period, the construction period will be postponed.
4.3 Due to the responsibility of Party B, it is not possible to start work on schedule or stop work without any reason, which will affect the construction period and the construction period will not be postponed.
4.4 Due to design changes or non-party B reasons for power outages, water cuts, gas outages and force majeure factors, the work will be stopped for more than 8 hours, and the construction period will be postponed accordingly.
Article 5, Agreement on Project Quality and Acceptance
5.1 The construction and acceptance criteria formulated by the State, such as construction drawings, method descriptions, design changes, and “Code for Construction and Acceptance of Building Decoration Engineering” and “Unified Standard for Quality Inspection and Evaluation of Building Installation Engineering”, are the quality assessment acceptance criteria.
5.2 The quality of the project should meet the national quality assessment eligibility criteria. When Party A requests that some or all of the projects meet the good standards, Party B shall pay Party B the additional fees.
5.3 Both Party A and Party B shall promptly handle the inspection and acceptance procedures for concealed works and intermediate works. Party A shall not participate in the concealed works and intermediate works acceptance on time, and Party B may accept the goods on its own, and Party A shall acknowledge it. If Party A requests re-inspection, Party B shall conduct re-inspection as required. If the re-inspection is qualified, Party A shall bear the cost of re-inspection, resulting in suspension of work, and the construction period shall be postponed; if the re-inspection is unqualified, the re-inspection and rework expenses shall be borne by Party B, but the construction period shall be postponed.
5.4 Due to the unqualified quality of materials and equipment provided by Party A, the quality of the project will be affected. The rework cost will be borne by Party A and the construction period will be postponed.
5.5 Due to the quality accident caused by Party B, the rework cost shall be borne by Party B, and the construction period will not be postponed.
5.6 After the completion of the project, Party B shall notify Party A of the acceptance. Party A shall organize the acceptance and acceptance within the day of receiving the acceptance notice, and shall go through the formalities of acceptance and handover. If Party A fails to organize the inspection and acceptance within the specified time, Party B shall be notified in time to determine the acceptance date. However, Party A shall acknowledge the date of completion and bear the costs of supervision and related expenses of Party B.
Article 6, Agreement on the price of the project and settlement
6.1 The parties agree to adopt the first type of the price of this contract:
Fixed price.
Fixed price plus % dry risk factor calculation. The risk of inclusion includes content.
Adjustable price: Calculate the cost according to the relevant national engineering pricing regulations, and adjust and complete the settlement according to relevant regulations.
6.2 After the contract comes into effect, Party A shall pay the project payment according to the following agreement, and settle the settlement once the completion of the settlement.
---------------------------
| Appropriation in arrears | Grants % | Gold Amount |
|----------|-------|------|
| | | |
|----------|-------|------|
| | | |
|----------|-------|------|
| | | |
---------------------------
6.3 After the project is completed and accepted, Party B shall submit the project settlement and send the relevant materials to Party A. Party A shall complete the review within the above-mentioned data and fail to file a protest at the expiration date. And within the day, settle the final paragraph.
Article 7, Agreement on the supply of materials
7.1 The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements and shall be supplied to the site on time. Where Party B agrees to pick up the goods, Party A shall hand over the delivery procedures to Party B, and Party B shall bear the transportation expenses. The materials and equipment supplied by Party A have quality problems or differences in specifications, causing losses to the project, and responsibility shall be borne by Party A. The materials supplied by Party A shall be custody by Party B after acceptance by Party B. Party A shall pay the storage fee of % of the material value. Party B shall be responsible for compensation for the loss caused by improper storage by Party B.
7.2 All materials and equipment purchased by Party B shall be prohibited if they do not meet the quality requirements or specifications. If it has been used, Party B shall be responsible for the losses caused to the project.
Article 8, Agreement on Safety Production and Fire Prevention
8.1 The construction drawings or practices provided by Party A shall comply with the Fire Services Regulations of the People's Republic of China and relevant fire protection design codes.
8.2 Party B shall strictly abide by the "Safety Technical Regulations for Building Installation Engineering", "Safety Operation Procedures for Construction and Installation Workers", "Fire Regulations of the People's Republic of China" and other relevant regulations and norms during construction.
8.3 Party A shall bear all economic losses arising from the occurrence of safety or fire accidents due to violation of relevant safety operation rules, fire regulations and fire protection design specifications due to the drawings or practices confirmed by Party A.
8.4 As Party B violates relevant safety operation rules and fire regulations during the construction and production process, resulting in safety or fire accidents, Party B shall bear all economic losses caused by this.
Article 9, Responsibility and Liability for Breach of Contract
9.1 Due to the delay of construction or the suspension of work due to Party A's reasons, Party A shall compensate Party B for the losses caused by work stoppage and work. Party A shall pay Party B for each day of work or work. Party A does not make payments according to the contractual agreement. For each one-day delay, the late payment fee is paid according to the % of the payment.
9.2 Due to Party B's reasons, Party B shall pay Party A's liquidated damages for each day overdue. Party A requires early completion, in addition to paying the rushing measures, Party A pays Party B every one day in advance as a reward.
9.3 If Party B meets the requirements of Party A and all or part of the project meets the excellent standards, Party A shall pay Party B as a reward, in addition to increasing the premium price in accordance with paragraph 5.2 of this contract.
9.4 Party B shall properly protect the equipment provided by Party A and the furniture, furnishings and finished products piled up on site. If losses are caused, compensation shall be made according to the price.
9.5 Party A has not gone through any formalities and has agreed to dismantle the original building structure or equipment pipeline without authorization. Party A shall be responsible for and bear the loss.
9.6 Without the consent of Party A, Party B shall dismantle the original building structure or equipment pipeline without authorization, and Party B shall be responsible for and bear the loss caused by the loss or accident.
9.7 If the acceptance procedure is not completed, Party A shall use it in advance or use it automatically, and Party A shall be responsible for the loss.
9.8 If the contract cannot continue to be performed due to one reason, the other party shall be notified to handle the contract termination agreement, and the responsible party shall compensate the other party for the economic losses caused thereby.
Article 10, Dispute or Dispute Resolution
10.1 During the performance of this contract, if there is a dispute between the two parties, the two parties may resolve the dispute or ask the relevant departments to mediate without affecting the progress of the project.
10.2 If the parties are unwilling to resolve through negotiation or mediation, or if the mediation fails, the parties to the dispute arising from the execution of this contract shall agree to be arbitrated by the Arbitration Commission.
Article 11, other agreements
Article 12, Supplementary Provisions
12.1 When the project requires warranty or insurance, an agreement shall be made.
12.2 The original of this contract is two copies, each party holds one copy. A copy of the copy, Party A, and Party B.
12.3 This contract is automatically terminated upon completion of performance.
12.4 Attached Files
Construction drawings or practices
Project list
Project budget
Party A provides the list of goods
Minutes of the meeting
Design changes
other
person A person B:
Legal representative: legal representative:
Agent: Agent:
Unit address: unit address:
Phone: Phone:
Fax: Fax:
Postal code: Postal code:
Bank of deposit: Bank of deposit:
Account Name: Account Name:
Account number: Account number:
Year, month, day, month, day
Schedule 1: List of XXX Engineering Party A Supply Materials and Equipment
------------------------------------------
| Order | Materials or Equipment | Specifications | Single | Number | | Supply | Delivery |
| | | | | | Price | | |Remarks|
| No. | Name | Model | Bit | Volume | | Time | Location |
|---|-----|----|---|---|----|----|----|--|
| | | | | | | | | |
|---|-----|----|---|---|----|----|----|--|
| | | | | | | | | |
|---|-----|----|---|---|----|----|----|--|
| | | | | | | | | |
------------------------------------------ Ministry of Construction / State Administration for Industry and Commerce
recommended article
- Maintenance contract
- LOGO Design Registration Agreement
- Parking contract
- Contract
- Mud painting contract
- Jingmen City residential decoration and construction project construction contract
- Lighter processing installation contract
- Computer maintenance agreement
- Contract (including transportation)
- International tanker charter contract
- House demolition entrustment contract
- Car maintenance contract
popular articles
- Weibo's famous sayings
- Space mood phrase
- Philosophical words 2019
- Construction and installation engineering construction contract
- Commissioned production contract model
- Blessing phrase
- Print production contract
- Grateful mother's words
- Encourage words 2019
- Life motto
- What I said to my father 2019
- Repair repair contract
- Distressed sentence 2019
- Contract
- Motivate employees
- Good sentence excerpt 2019
- Non-mainstream sentence 2019
- Pump repair contract
- Spring Festival blessing
- Not afraid of failure
- Respect the teacher's famous words
- Relieved words
- Sample of the processing agreement (light industry)
- Legal maxim
- Hyun dance family impression sentence
- About building a ship contract
- Processing contract model
- 2014 motivational phrase
- Parental love
- Decoration contract demonstration text