Processing contract (1)
Processing contract
Enter into the contract:
Contractor: __________________
Fixed party: __________________
The contracting party entrusts the contractor to process ________________, and the parties have fully negotiated this contract in order to comply with it.
The first processed product:
┌──────┬─────┬──────┬───────┬──────┐
│Product Name│Specification│Unit│Quantity│Remarks│
├──────┼─────┼──────┼───────┼──────┤
│ │ ││ ││
├──────┼─────┼──────┼───────┼──────┤
│ │ ││ ││
└──────┴─────┴──────┴───────┴──────┘
The second quality requirement for processed products: _______________________________________________________________________________________.
Article 3: Methods and specifications for the supply of raw materials, quantity, quality: ___________________________________________________________________________________ Date calculation, refer to the provisions of Article 7. )
Article 4: Technical information, drawings and methods: ____________________________________________________________________________________________
Article 5 Price or Remuneration: ________________________________________________________________________________________
Article 6 Acceptance criteria and methods: __________________________________________
________________
Article 7 Time and place of delivery: ___________________________________________________________________________________________ The fixed crop period shall be performed in accordance with the contract. Any party requesting the early or late payment of the crop shall reach an agreement with the other party in advance and shall be executed in accordance with the agreement. 2. Calculation of the date of the crops: If the contractor delivers the fixed crops, the date of the stamp received by the ordering party shall prevail; if the transportation is entrusted to the transport department, the date of the stamp issued by the carrier shall be the date; If the crop is to be raised, the date of the notification of the contractor shall prevail, but the contractor shall leave the necessary time for the given party in the notice of the withdrawal of the fixed crop; if otherwise agreed by the parties, the contract shall be calculated according to the agreed method. . )
Article 8 Packaging Requirements and Cost Burden: ____________________________________________________
Article 9 Transportation Methods and Cost Burden: ____________________________________________________
Article 10 Settlement Method and Term: ____________________________________________________
Article 11 Other: ________________________________________________________
Article 12: Contractor’s liability for breach of contract:
1. If the fixed crops are not delivered according to the quality stipulated in the contract or the work is completed, if the contractor agrees to use the materials, the quality shall be priced according to the quality; if they do not agree to the use, they shall be responsible for the repair or exchange, and shall bear the responsibility for overdue delivery; after the repair or exchange Afterwards, if the contract does not meet the requirements of the contract, the ordering party has the right to refuse, and the losses caused by the contractor shall be compensated by the contracting party.
Second, if the quantity of fixed crops or completed work is less than the contractual provisions, if the ordering party still needs it, it shall be filled in according to the number, and the supplementary part shall be delivered according to the overdue delivery; if the part of the fixed party is no longer needed, the right to cancel The contract, the resulting loss is compensated by the contractor.
3. If the fixed crops are not packaged in accordance with the contract and need to be repaired or repackaged, they shall be responsible for repairing or repackaging, and shall bear the expenses thus incurred. If the ordering party does not require repair or repackaging and claims compensation for the loss, the contractor shall reimburse the ordering party that the unqualified packaging is lower than the value of the qualified packaging. If the package does not conform to the contract and the crop is damaged or lost, the contractor shall compensate the loss.
4. If the fixed crop is overdue, the liquidated damages shall be reimbursed to the fixed party for ________ yuan; for each day overdue, one-thousandth of the total amount of the overdue delivery shall be repaid for liquidated damages.
If the fixed crop is agreed without the consent of the author, the ordering party has the right to reject it.
5. If the fixed crop cannot be delivered or the work cannot be completed, the _____% of the total value of the work part or the _____% liquidated damages of the total amount of the work may not be paid.
Sixth, the fixed crops delivered in different places do not meet the contract provisions, and when temporarily reserved for custody, they shall pay the custody and maintenance fees actually paid by the ordering party.
Seventh, the implementation of fixed crops for delivery or delivery, the wrong place to arrive or the receiving unit, in addition to being transported to the designated place or receiving unit according to the contract, and bear the burden of overpayment and overdue delivery of fixed crops.
8. If the raw materials, equipment, packaging materials and other items provided by the ordering party are damaged or lost due to improper storage, the losses caused by the ordering party shall be reimbursed.
9. If the raw materials provided by the ordering party are not inspected according to the method and time limit stipulated in the contract, or if the raw materials are found to be inconsistent with the requirements, and the fixed party is not notified according to the time limit specified in the contract, the contractor shall work on the work. Quality, quantity is responsible.
10. If the raw materials or repair parts provided by the ordering party are exchanged without authorization, the ordering party shall have the right to refuse, and the contracting party shall compensate the contracting party for the losses caused thereby. If the ordering party requests re-work or re-repair, it shall be handled as required by the ordering party and bear the responsibility for overdue delivery.
Article 13: The defaulting party’s liability for breach of contract:
First, the quantity, specification, quality or design of the fixed crops shall be changed in the middle, and the losses caused by the contractor shall be compensated.
Second, the contract is abolished in the middle, and the contractor provides the raw materials, and pays the contractor’s ____% of the total value of the unexecuted part of the price; if the contractor does not provide the raw materials, the reimbursement party shall not pay the part of the total remuneration _ _________% penalty.
3. If the raw materials, technical materials, packaging materials, etc. are not provided to the contractor or the necessary auxiliary work and preparation work are not completed according to the time and requirements stipulated in the contract, the contractor has the right to terminate the contract, and the ordering party shall compensate the contractor for the result. Loss; if the contractor does not request the cancellation of the contract, the ordering party shall reimburse the contractor for the loss of the material to be discharged, except for the date of delivery of the fixed crop.
4. If the fixed crops are received within the time limit specified in the contract, the deposits and maintenance fees actually paid by the contractor shall be borne in addition to the payment of liquidated damages in accordance with the provisions of paragraph 5 of this Article. If the contractor does not receive the fixed crop within six months of the collection period, the contractor has the right to sell the fixed crop, and the proceeds will be returned to the fixed party after deducting the remuneration, storage and maintenance fees; When the storage and maintenance costs are met, the ordering party shall also compensate for the insufficient part; if the fixed crop cannot be sold, the contractor’s losses shall be compensated.
5. If the payment exceeds the date specified in the contract, the contractor shall pay the liquidated damages in accordance with the provisions of the People's Bank of China on deferred payment; in the case of remuneration, one-thousandth of the total amount of the remuneration shall be repaid in liquidated damages.
6. If you refuse to receive the fixed crop without reason, you shall compensate the contractor for the damage caused and the fine of the transportation department.
7. Change the delivery of the fixed crop location or receiving unit and bear the expenses incurred as a result.
Article 14: Force Majeure: In the period of performance stipulated in the contract, if the fixed crop or raw material is damaged or lost due to force majeure, the contracting party may be exempted from liability for breach of contract after obtaining legal proof, but active measures shall be taken to minimize losses. If it occurs outside the performance period specified in the contract, the liability shall not be waived; if the fixed party accepts the delay or accepts it during the period of unreasonable rejection, the ordering party shall be liable and compensate the contractor for the losses caused thereby.
Article 15 Handling of Disputes: When a dispute arises in the processing contract, the parties shall settle the dispute through negotiation; if the negotiation fails, either party may apply to the contract management authority for mediation or arbitration, or directly to the people's court.
This contract shall become effective on the date of ________________________________________________________________________________________________________________ During the execution of this contract, the parties shall not arbitrarily change or cancel the contract. If the contract has any unfinished matters, the parties shall jointly negotiate and make additional provisions, and the supplementary provisions shall have the same effect as this contract.
The original of this contract is in duplicate, and the contractor and the contractor each hold one copy; the copy of the contract is ____ copies, and each _______ is retained.
Fixed party: ____________________
Representative: ____________________
address:________________________________
phone:________________________________
Bank of deposit: ____________________________
account number:______________________________
Contractor: __________________________
Representative: __________________________
address:_________________________
phone:_________________________
Bank of deposit: _____________________
account number:_________________________
IX _____ years _______ month ______ day order
Enter into the contract:
Contractor: __________________
Fixed party: __________________
The contracting party entrusts the contractor to process ________________, and the parties have fully negotiated this contract in order to comply with it.
The first processed product:
┌──────┬─────┬──────┬───────┬──────┐
│Product Name│Specification│Unit│Quantity│Remarks│
├──────┼─────┼──────┼───────┼──────┤
│ │ ││ ││
├──────┼─────┼──────┼───────┼──────┤
│ │ ││ ││
└──────┴─────┴──────┴───────┴──────┘
The second quality requirement for processed products: _______________________________________________________________________________________.
Article 3: Methods and specifications for the supply of raw materials, quantity, quality: ___________________________________________________________________________________ Date calculation, refer to the provisions of Article 7. )
Article 4: Technical information, drawings and methods: ____________________________________________________________________________________________
Article 5 Price or Remuneration: ________________________________________________________________________________________
Article 6 Acceptance criteria and methods: __________________________________________
________________
Article 7 Time and place of delivery: ___________________________________________________________________________________________ The fixed crop period shall be performed in accordance with the contract. Any party requesting the early or late payment of the crop shall reach an agreement with the other party in advance and shall be executed in accordance with the agreement. 2. Calculation of the date of the crops: If the contractor delivers the fixed crops, the date of the stamp received by the ordering party shall prevail; if the transportation is entrusted to the transport department, the date of the stamp issued by the carrier shall be the date; If the crop is to be raised, the date of the notification of the contractor shall prevail, but the contractor shall leave the necessary time for the given party in the notice of the withdrawal of the fixed crop; if otherwise agreed by the parties, the contract shall be calculated according to the agreed method. . )
Article 8 Packaging Requirements and Cost Burden: ____________________________________________________
Article 9 Transportation Methods and Cost Burden: ____________________________________________________
Article 10 Settlement Method and Term: ____________________________________________________
Article 11 Other: ________________________________________________________
Article 12: Contractor’s liability for breach of contract:
1. If the fixed crops are not delivered according to the quality stipulated in the contract or the work is completed, if the contractor agrees to use the materials, the quality shall be priced according to the quality; if they do not agree to the use, they shall be responsible for the repair or exchange, and shall bear the responsibility for overdue delivery; after the repair or exchange Afterwards, if the contract does not meet the requirements of the contract, the ordering party has the right to refuse, and the losses caused by the contractor shall be compensated by the contracting party.
Second, if the quantity of fixed crops or completed work is less than the contractual provisions, if the ordering party still needs it, it shall be filled in according to the number, and the supplementary part shall be delivered according to the overdue delivery; if the part of the fixed party is no longer needed, the right to cancel The contract, the resulting loss is compensated by the contractor.
3. If the fixed crops are not packaged in accordance with the contract and need to be repaired or repackaged, they shall be responsible for repairing or repackaging, and shall bear the expenses thus incurred. If the ordering party does not require repair or repackaging and claims compensation for the loss, the contractor shall reimburse the ordering party that the unqualified packaging is lower than the value of the qualified packaging. If the package does not conform to the contract and the crop is damaged or lost, the contractor shall compensate the loss.
4. If the fixed crop is overdue, the liquidated damages shall be reimbursed to the fixed party for ________ yuan; for each day overdue, one-thousandth of the total amount of the overdue delivery shall be repaid for liquidated damages.
If the fixed crop is agreed without the consent of the author, the ordering party has the right to reject it.
5. If the fixed crop cannot be delivered or the work cannot be completed, the _____% of the total value of the work part or the _____% liquidated damages of the total amount of the work may not be paid.
Sixth, the fixed crops delivered in different places do not meet the contract provisions, and when temporarily reserved for custody, they shall pay the custody and maintenance fees actually paid by the ordering party.
Seventh, the implementation of fixed crops for delivery or delivery, the wrong place to arrive or the receiving unit, in addition to being transported to the designated place or receiving unit according to the contract, and bear the burden of overpayment and overdue delivery of fixed crops.
8. If the raw materials, equipment, packaging materials and other items provided by the ordering party are damaged or lost due to improper storage, the losses caused by the ordering party shall be reimbursed.
9. If the raw materials provided by the ordering party are not inspected according to the method and time limit stipulated in the contract, or if the raw materials are found to be inconsistent with the requirements, and the fixed party is not notified according to the time limit specified in the contract, the contractor shall work on the work. Quality, quantity is responsible.
10. If the raw materials or repair parts provided by the ordering party are exchanged without authorization, the ordering party shall have the right to refuse, and the contracting party shall compensate the contracting party for the losses caused thereby. If the ordering party requests re-work or re-repair, it shall be handled as required by the ordering party and bear the responsibility for overdue delivery.
Article 13: The defaulting party’s liability for breach of contract:
First, the quantity, specification, quality or design of the fixed crops shall be changed in the middle, and the losses caused by the contractor shall be compensated.
Second, the contract is abolished in the middle, and the contractor provides the raw materials, and pays the contractor’s ____% of the total value of the unexecuted part of the price; if the contractor does not provide the raw materials, the reimbursement party shall not pay the part of the total remuneration _ _________% penalty.
3. If the raw materials, technical materials, packaging materials, etc. are not provided to the contractor or the necessary auxiliary work and preparation work are not completed according to the time and requirements stipulated in the contract, the contractor has the right to terminate the contract, and the ordering party shall compensate the contractor for the result. Loss; if the contractor does not request the cancellation of the contract, the ordering party shall reimburse the contractor for the loss of the material to be discharged, except for the date of delivery of the fixed crop.
4. If the fixed crops are received within the time limit specified in the contract, the deposits and maintenance fees actually paid by the contractor shall be borne in addition to the payment of liquidated damages in accordance with the provisions of paragraph 5 of this Article. If the contractor does not receive the fixed crop within six months of the collection period, the contractor has the right to sell the fixed crop, and the proceeds will be returned to the fixed party after deducting the remuneration, storage and maintenance fees; When the storage and maintenance costs are met, the ordering party shall also compensate for the insufficient part; if the fixed crop cannot be sold, the contractor’s losses shall be compensated.
5. If the payment exceeds the date specified in the contract, the contractor shall pay the liquidated damages in accordance with the provisions of the People's Bank of China on deferred payment; in the case of remuneration, one-thousandth of the total amount of the remuneration shall be repaid in liquidated damages.
6. If you refuse to receive the fixed crop without reason, you shall compensate the contractor for the damage caused and the fine of the transportation department.
7. Change the delivery of the fixed crop location or receiving unit and bear the expenses incurred as a result.
Article 14: Force Majeure: In the period of performance stipulated in the contract, if the fixed crop or raw material is damaged or lost due to force majeure, the contracting party may be exempted from liability for breach of contract after obtaining legal proof, but active measures shall be taken to minimize losses. If it occurs outside the performance period specified in the contract, the liability shall not be waived; if the fixed party accepts the delay or accepts it during the period of unreasonable rejection, the ordering party shall be liable and compensate the contractor for the losses caused thereby.
Article 15 Handling of Disputes: When a dispute arises in the processing contract, the parties shall settle the dispute through negotiation; if the negotiation fails, either party may apply to the contract management authority for mediation or arbitration, or directly to the people's court.
This contract shall become effective on the date of ________________________________________________________________________________________________________________ During the execution of this contract, the parties shall not arbitrarily change or cancel the contract. If the contract has any unfinished matters, the parties shall jointly negotiate and make additional provisions, and the supplementary provisions shall have the same effect as this contract.
The original of this contract is in duplicate, and the contractor and the contractor each hold one copy; the copy of the contract is ____ copies, and each _______ is retained.
Fixed party: ____________________
Representative: ____________________
address:________________________________
phone:________________________________
Bank of deposit: ____________________________
account number:______________________________
Contractor: __________________________
Representative: __________________________
address:_________________________
phone:_________________________
Bank of deposit: _____________________
account number:_________________________
IX _____ years _______ month ______ day order
recommended article
- Parking contract
- Jingmen City residential decoration and construction project construction contract
- House demolition entrustment contract
- International tanker charter contract
- Computer maintenance agreement
- LOGO Design Registration Agreement
- Maintenance contract
- Contract
- Lighter processing installation contract
- Contract (including transportation)
- Mud painting contract
- Car maintenance contract
popular articles
- About building a ship contract
- Processing contract model
- Repair repair contract
- Grateful mother's words
- Life motto
- Print production contract
- Parental love
- Spring Festival blessing
- Non-mainstream sentence 2019
- Weibo's famous sayings
- Not afraid of failure
- Commissioned production contract model
- Relieved words
- Philosophical words 2019
- Motivate employees
- What I said to my father 2019
- Pump repair contract
- Blessing phrase
- Respect the teacher's famous words
- Encourage words 2019
- Construction and installation engineering construction contract
- Space mood phrase
- 2014 motivational phrase
- Legal maxim
- Good sentence excerpt 2019
- Distressed sentence 2019
- Decoration contract demonstration text
- Hyun dance family impression sentence
- Contract
- Sample of the processing agreement (light industry)